Reso 2019-3022 - Laserfiche WebLink

Home Browse Search

• City of Sunny Isles Beach 18070 Collins Avenue, Sunny Isles Beach, Florida 33160 (305) 947-0606 phone (305) 949-3113 Fax Sunny Isles Beach, FL 33106 AccountsPayable@sibfl.net Contractor shall make no other charges to the City for supplies, labor, taxes, licenses, permits, overhead or any other expenses or costs unless any such expense or cost is incurred by Contractor with the prior written approval of the City. If the City disputes any charges on the invoices, it may make payment of the uncontested amounts and withhold payment on the contested amounts until they are resolved by agreement with Contractor. Contractor shall not pledge the City's credit or make it a guarantor of payment or surety for any contract, debt, obligation,judgment, lien, or any form of indebtedness. The Contractor further warrants and represents that it has no obligation or indebtedness that would impair its ability to fulfill the terms of this Agreement. 6. LIQUIDATED DAMAGES. Failure to complete the Services in accordance with the specifications and to the satisfaction of the City within the time stated for substantial and/or final completion shall cause the Contractor to be subject to charges for liquidated damages for each and every calendar day the Services remain incomplete beyond these deadlines. The liquidated damages amount is five hundred dollars ($500.00) for each calendar day. As compensation due to the City for loss of use and for additional costs incurred by the City due to non-completion of the work in a timely manner, the City shall have the right to deduct the said liquidated damages from any amount due, or that may become due to the Contractor under this Agreement, or to invoice the Contractor for such damages if the costs incurred exceed the amount due to the Contractor. 7. INDEPENDENT CONTRACTOR RELATIONSHIP. The Contractor is an independent contractor and shall be treated as such for all purposes. Nothing contained in this Agreement or any action of the parties shall be construed to constitute or to render the Contractor an employee, partner, agent, shareholder, officer or in any other capacity other than as an independent contractor other than those obligations which have been or shall have been undertaken by the City. Contractor shall be responsible for any and all of its own expenses in performing its duties as contemplated under this Agreement. The City shall not be responsible for any expense incurred by the Contractor. The.City shall have no duty to withhold any Federal income taxes or pay Social Security services and that such obligations shall be that of the Contractor, other than those set forth in this Agreement. Contractor shall furnish its own transportation, office and other supplies as it determines necessary in carrying out its duties under this Agreement. 8. OWNERSHIP OF DOCUMENTS AND EQUIPMENT. All documents prepared by the Contractor pursuant to this Agreement and related Services to this Agreement are intended and represented for the ownership of the City only. Any other use by Contractor or other parties shall be approved in writing by the City. If requested, Contractor shall deliver the documents to the City within fifteen (15) calendar days. 9. INSURANCE. Contractor shall, at its sole cost and expense, during the period of any work being performed under this Agreement, procure and maintain the following minimum 2019-7291 G.Concrete Development,Inc. 3 I I