Reso 2022-3307 - Laserfiche WebLink

Home Browse Search

47QSMD20R0001 Refresh: 0009 Section III A. Terms and Conditions Related to Schedule Contract Administration (iii) Materials means (A) Direct materials, including supplies transferred between divisions, subsidiaries, or affiliates of the contractor under a common control; (B) Subcontracts for supplies and incidental services for which there is not a labor category specified in the contract; (C) Other direct costs (e.g., incidental services for which there is not a labor category specified in the contract, travel, computer usage charges, etc.); (D) The following subcontracts for services which are specifically excluded from the hourly rate: Each order must list separately subcontracts for services excluded from the ESS Hourly Rates; and (E) Indirect costs specifically provided for in this clause. (iv) Subcontract means any contract, as defined in EAR sub aip -t 2.1, entered into with a subcontractor to furnish supplies or services for performance of the prime contract or a subcontract including transfers between divisions, subsidiaries, or affiliates of a contractor or subcontractor. It includes, but is not limited to, purchase orders, and changes and modifications to purchase orders. (t) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence. (g) Invoice. (1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include (i) Name and address of the Contractor; (ii) Invoice date and number; (iii) Contract number, line item number and, if applicable, the order number; (iv) Description, quantity, unit of measure, unit price and extended price of the items delivered; (v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on Government bill of lading; (vi) Terms of any discount for prompt payment offered; (vii) Name and address of official to whom payment is to be sent; (viii) Name, title, and phone number of person to notify in event of defective invoice; and (ix) Taxpayer Identification Number (TIN). The Contractor shall include its TIN on the Page: 89 of 141