Reso 2024-3644 - Laserfiche WebLink

Home Browse Search

Contract Clauses for Solicitation 470SMD20R0001 Refresh Number 19 Contract Number: GS -07F -0031W the requirements of this contract. The Government reserves the right to inspect or test any supplies or services that have been tendered for acceptance. The Government may require repair or replacement of nonconforming supplies or reperformance of nonconforming services at no increase in contract price. If repair/replacement or reperformance will not correct the defects or is not possible, the Government may seek an equitable price reduction or adequate consideration for acceptance of nonconforming supplies or services. The Government must exercise its post -acceptance rights — (1) Within a reasonable time after the defect was discovered or should have been discovered; and (2) Before any substantial change occurs in the condition of the item, unless the change is due to the defect in the item. (b) Assignment. The Contractor or its assignee may assign its rights to receive payment due as a result of performance of this contract to a bank, trust company, or other financing institution, including any Federal lending agency in accordance with the Assignment of Claims Act (31 U.S.C. 3727). However, when a third party makes payment (e.g., use of the credit card), the Contractor may not assign its rights to receive payment under this contract. (c) Changes. Changes in the terms and conditions of this contract may be made only by written agreement of the parties. (d) Disputes. This contract is subject to 41 U.S.C. chapter 71, Contract Disputes. Failure of the parties to this contract to reach agreement on any request for equitable adjustment, claim, appeal or action arising under or relating to this contract shall be a dispute to be resolved in accordance with the clause at Federal Acquisition Regulation (FAR) 52.233-1, Disputes, which is incorporated herein by reference The Contractor shall proceed diligently with performance of this contract, pending final resolution of any dispute arising under the contract. (e) Definitions. The clause at FAR 52.202-1, Definitions, is incorporated herein by reference. (f) Excusable delays. The Contractor shall be liable for default unless nonperformance is caused by an occurrence beyond the reasonable control of the Contractor and without its fault or negligence such as, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, unusually severe weather, and delays of common carriers. The Contractor shall notify the Contracting Officer in writing as soon as it is reasonably possible after the commencement of any excusable delay, setting forth the full particulars in connection therewith, shall remedy such occurrence with all reasonable dispatch, and shall promptly give written notice to the Contracting Officer of the cessation of such occurrence. (g) Invoice. (1) The Contractor shall submit an original invoice and three copies (or electronic invoice, if authorized) to the address designated in the contract to receive invoices. An invoice must include — (i) Name and address of the Contractor; (ii) Invoice date and number; (iii) Contract number, line item number and, if applicable, the order number; (iv) Description, quantity, unit of measure, unit price and extended price of the items delivered; (v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shipped on an Government bill of lading; (vi) Terms of any discount for prompt payment offered; Page: 169 of 216 256