Laserfiche WebLink
it <br />LUNAcv <br />CONSTRUCTION GROUP r• <br />delays in reviewing TIAs and other Lunacon documentation. Lunacon is also seeking contract sums to the <br />extent they are unpaid. Remarkably and regrettably, the delay amounted to 1447 days, which Lunacon <br />cannot ignore. <br />PENDING <br />CASE NUMBER: CACE24006026 <br />DATE FILED: 05/01/2024 <br />PLAINTIFF: The School Board of Broward County <br />DEFENDANT: LUNACON ENGINEERING GROUP, CORP <br />CASE TYPE: Breach of Contract <br />PROJECT: Riverglades Lie mentary School <br />BASIS FOR CLAIM: Lunacon entered into a series of contracts with the School Board of Broward County. <br />On this project, as on the others listed, Lunacon is seeking additional costs as a result of the project being <br />extended for reasons beyond Lunacon's control. Lunacon has submitted TIAs (Time Impact Analysis) to <br />support its position and delays have often occurred as a result of the School Board's and consultant's <br />delays in reviewing TIAs and other Lunacon documentation. Lunacon is also seeking contract sums to the <br />extent they are unpaid. Remarkably and regrettably, the delay amounted to 1404 days, which Lunacon <br />cannot ignore. This matter is pending. <br />PENDING <br />CASE NUMBER: 2023 -019200 -CA -01 <br />DATE FILED: July 6, 2023 <br />PLAINTIFF: KELLY -JONES, JOHN <br />DEFENDANT: LUNACQN ENGINEERING GROUP, CORP. <br />ATTORNEY REPRESENTING THE PLAINTIFF: Corona, Ricardo R. <br />ADDRESS:6700 S.W. 38th Street, Miami, Florida 33155 <br />TELEPHONE NUMBER: 305-266-1150 <br />ATTORNEY REPRESENTING THE DEFENDANT: Rodriguez, Jackeline Sofia <br />ADDRESS: 150 Southeast Second Avenue, Suite 1200, Miami, Florida 33131-2332 <br />TELEPHONE NUMBER: 305-379-3686 <br />DESCRIPTION OF CLAIM/ ACTION/ LITIGATION: The Plaintiff collision with a vehicle on April 20, 2023, at <br />a construction site near Maurice Gibb Park in Miami Beach, FL. The lawsuit alleges that Lunacon's <br />installation of a temporary construction fence obstructed visibility and directly contributed to the <br />accident. However, the Plaintiff, despite being aware of the stop sign at the egress, negligently continued <br />to operate his electronic bicycle on the sidewalk of the opposing roadway without exercising due caution. <br />The Plaintiff failed to observe or yield to a vehicle lawfully exiting the parking area, resulting in his own <br />.D <br />injury. Lunacon's Insurance Company is handling this matter. <br />PENDING ^ <br />U <br />16890 South I3ixie Highway, Palmetto Bay, FL 33157 - [o] 786.293.DD35 - to 786.293.0333 <br />