Reso 2025-3934 - Laserfiche WebLink

Home Browse Search

City of'Sunny Isles Beach 18070 Collins Avenue, Sunny Isles Beach, Florida 33160 (305) 947-0606 phone (305) 949-3113 Fax Such written notice and claim must be furnished within three (3) days after occurrence of the event, or the first appearance of the condition giving rise to the claim. 8.3.2 Pending final resolution of any claim of the Contractor, the Contractor shall diligently proceed with performance of this Contract and the City shall continue to make payments to the Contractor in accordance with this Contract. The resolution of any claim tinder this Paragraph 8.3 shall be reflected by a Change Order executed by the City, the City's Representative, and the Contractor. 8.3.3 Claims for Concealed and Unknown Conditions Should concealed and unknown conditions encountered in the performance of the Work (a) below the surface of the ground or (b) in an existing structure be at variance with the conditions indicated by this Contract, or should unknown conditions of an unusual nature differing materially from those ordinarily encountered in the area and generally recognized as inherent in Work of the character provided for in this Contract, be encountered, the Contract Price shall be equitably adjusted by Change Order upon the written notice and claim by either party made within three (3) days after the first observance of the condition. Asa condition precedent to the City having any liability to the Contractor for concealed or unknown conditions, the Contractor must give the City and the City's Representative written notice of, and an opportunity to observe, the condition prior to disturbing it. The failure by the Contractor to make the written notice and claim as provided in this Subparagraph shall constitute a waiver by the Contractor of any claim arising out of or relating to such concealed or unknown condition. 8.3.4 Claims for Additional Costs — Except as prohibited in Paragraph 8.3.5 herein below, if the Contractor wishes to make a claim for an increase in the Contract Price, as a condition precedent to any liability of the City therefore, the Contractor shall give the City's Representative and the City written notice of such claim within three (3) days after the occurrence of the event, or the first appearance of the condition, giving rise to such claim. Such notice must be given by the Contractor before proceeding to execute any additional or changed Work. The failure by the Contractor to give such notice and to give such notice prior to executing the Work shall constitute a waiver of any claim for additional compensation. ' 8.3.4.1 In connection with any claim by the Contractor against the City for compensation in excess of the Contract Price, any liability of the City for the Contractor's cost shall be strictly limited to direct costs incurred by the Contractor plus a reasonable mark-up of fifteen percent (15%) for overhead and profit consistent with Paragraph 10.3.3.4 below. Direct costs do not include the Contractor's home office overhead, loss of efficiency, consequential damages of the Contractor, or equipment costs in excess of actual equipment rental paid by the Contractor to a third party. The City shall not be liable to the Contractor for claims of third parties, including Subcontractors, unless and until liability of the Contractor has been established therefore in a court of competent, jurisdiction. 8.3.5 Claims for Additional Time —If the Contractor is delayed in progressing any task which at the time of the delay is then critical or which during the delay becomes critical, as the sole result of any act or neglect to act by the City or someone acting in the AUM CONSTRUCTION, INC. 22