Reso 99-148 - Laserfiche WebLink

Home Browse Search

I AGREEMENT BETWEEN OWNER AND ARCHITECT-ENGINEER THIS AGREEMENT made this 9" day of ..A-;;,,/! in the year Nineteen Hundred and Ninety Seven BY kVD BETWEEN THE DIVISION OF BUILDING CONSTRUCTION, DEPARTMENT OF MANAGEMENT SERVICES, STATE OF FLORIDA, THE OWNER, and SPILLIS CANDELA & PARTNERS. INC., A FLORIDA CORPORATION. 800 DOUGLAS ENTRANCE. CORAL GABLES. FLORIDA 33134. Fed~ral Tax r.D. Number: 59-1290432, the ARCHITECT-ENGINEER. ARTICLE 1 THE CONSTRUCTION TEAM AND EXTENT OF AGREEMENT 1.1 The Architect-Engineer accepts the relationship of trust and confidence established between it and the Owner by this Agreement. He covenants with the Owner to furnish his best skill and jUdgment and to cooperate with the Client Agency and the Contractor in furthering the interests of the Owner. He agrees to provide professional services and to use his best efforts to complete the project in the most expeditious and economical manner consistent with the interest of the Owner" 1.2 The Construction Team - The Contractor, the Owner, the Agent and the Architect-Engineer, called the "Construction Team", shall work from the beginning of planning through final construction completion and shall be available thereafter should additional services be required. The Architect-Engineer will provide leadership during the design phase with support from the Contractor, and the Contractor shall provide leadership to the Construction Team on all matters relating to construction. The specific representatives of the Construction Team are shown in the attached Exhibit A, which Exhibit A by reference and attachment hereto forms a part of this Agreement. 1.3 Extent of Aqreement - This Agreement for professional services for State Proiect Number TD-96063000 entitled "New Police Headquarters & Fire Station/EMS Facility, Davie, Florida", represents' the entire Agreement between the OWner and the Architect-Engineer, This Agreement shall not be superseded by any provisions of the documents for construction and may be amended only by written instrument signed by the Owner and the Architect-Engineer, 1,4 Definitions: Proiect - The Project is the total work to be performed under this Agreement, The Project consists of planning, design, construction and associated site work to build the component parts of the project. Owner - The State of Florida, Department of Management Services, Division of Building Construction, acting through its Secretary or those persons designated by the Secretary to act on his behalf, as Agent for the Town of Davie pursuant to Client Agency agreement dated December 6, 1996 as it may be amended from time to time. The entity that will occupy, use and o~ the project. upon substantial completion is the Town of Davie, Davie, Florida. The funds with which the compensation of the architects, engineers, contractors, etc., will be paid are under the control of the Town of Davie, Davie, Florida. Payments under this contract, as prescribed hereinabove, will be made by the Town of Davie, Davie, Florida, based on approval of each payment by the Division of Building Construction, Department of Management Services, State of Florida. All duties of Owner hereinafter shall be performed by the Division of Building Construction. 1 ...