Reso 2003-519 - Laserfiche WebLink

Home Browse Search

LlIJ' OJ 3unny lSleS DeaCn 17070 Collins Avenue, Suite 250, Sunny Isles Beach, Florida 33160 (305) 947-0606 phone (305) 949-3113 Fax Contractor is delayed or prevented by the City or by circumstances beyond the reasonable control of the Contractor including weather conditions of acts of God which render the performance of the Contractor's duty impracticable, 13. AUTHORITY TO PRACTICE. Contractor hereby represents and warrants that it has and will continue to maintain all licenses and approvals required to conduct its business and that it will at all times conduct its business activities in a reputable manner, Proof of such licenses and approvals shall be submitted to the City prior to commencement of work under this Agreement. Contractor shall obtain and keep in force during the term of this Agreement all necessary licenses, registrations, certificates, permits and other authorizations as are required by law in order for Contractor to render the services required hereunder. 14. AS SPECIFIED. All items delivered must meet the specifications delineated in Bid Proposal No, 02-12-01, attached hereto as Exhibit "A." Items delivered not as specified will be .returned at no expense by the City, The City may return, for full credit, any used items received which fail to meet the City's performance standards, Replacement items meeting specifications must be submitted within a reasonable time after rejection of the non-conforming items. 15. MODIFICATIONS OF WORK. The City reserves the right to make changes in the work, including alterations, reductions or additions thereto, Upon receipt of the City's notification of a contemplated change, the Contractor shall (1) if requested by the City, provide an estimate for the increase or decrease in cost due to the contemplated change, (2) notify the City of any estimated change in completion date, and (3) advise the City in writing if the contemplated change shall affect the Contractor's ability to meet the completion dates or schedules of this Agreement. 16. COORDINATION OF SERVICES. The City's representative/liaison during the performance of this Agreement shall be James Watts, Director, Public Works, telephone number 305/947-0606. Contractor shall not respond to requests for services under this Agreement unless the request is received directly from James Watts or designated personnel. Any requests received from other City departments/divisions shall be referred to the City Manager's Department representative designated above, Services performed without authorization by James Watts, Director, Public Works, shall be considered unauthorized and shall not be compensated/paid by the City. 17. ARBITRATION. It is the intention of the parties that whenever possible, if a dispute or controversy arises hereunder then such dispute or controversy shall be settled by arbitration in accordance with the procedures, rules and regulations of the American Arbitration Association. The decision rendered by the Arbitrator shall be final and binding upon the parties and judgment upon the award rendered by the arbitrator may be entered in any court having jurisdiction, Arbitration shall be held in Miami-Dade County, Florida. The non-prevailing party shall pay all costs of arbitration and attorneys' fees incurred by the parties or, if neither party prevails on the whole, each party shall be responsible for a portion of the costs of arbitration and their respective attorneys' fees as may be determined by the court on confirmation, Professional Welding Fence Installation Agreement 6 Attorney/ Agreementslch