Laserfiche WebLink
<br />City of Sunny Isles Beach <br /> <br />18070 Collins A venue, Sunny Isles Beach, Florida 33160 <br />(305) 947-0606 phone (305) 949-3113 Fax <br /> <br />b. Termination for Convenience of City. The City may, for its convenience and <br />without cause terminate the services then remaining to be performed by providing thirty (30) <br />days notice. <br /> <br />c. Termination for Insolvency. The City also reserves the right to terminate the <br />remaining services to be performed in the event the Contractor is placed either in voluntary or <br />involuntary bankruptcy or makes any assignment for the benefit of creditors. <br /> <br />11. ASSIGNMENTS. TRANSFERS. SUBCONTRACTING. The Contractor shall not <br />subcontract, assign or transfer any work under this agreement without the prior written consent <br />of the City. Should the Contractor subcontract any services under this agreement, it shall be <br />done with continued liability for the Contractor. The Contractor shall remain responsible for <br />services, responsibilities and liabilities of any person or entity acting under Contractor. <br /> <br />12. TIME OF COMPLETION. The services to be rendered by the Contractor shall be <br />commenced upon execution of this contract and shall be completed within the time specified in <br />Exhibit "A", if any time is indicated. A reasonable extension of time shall be granted in the <br />event the work of the Contractor is delayed or prevented by the City or by circumstances beyond <br />the reasonable control of the Contractor including weather conditions of acts of God which <br />render the performance of the Contractor's duty impracticable. <br /> <br />13. AUTHORITY TO PRACTICE. Contractor hereby represents and warrants that it has <br />and will continue to maintain all licenses and approvals required to conduct its business and that <br />it will at all times conduct its business activities in a reputable manner. Proof of such licenses <br />and approvals shall be submitted to the City prior to commencement of work under this <br />Agreement. <br /> <br />14. MODIFICATIONS OF WORK. The City reserves the right to make changes in the <br />work, including alterations, reductions or additions thereto. Upon receipt of the City's <br />notification of a contemplated change, the Contractor shall (1) if requested by the City, provide <br />an estimate for the increase or decrease in cost due to the contemplated change, (2) notify the <br />City of any estimated change in completion date, and (3) advise the City in writing if the <br />contemplated change shall affect the Contractor's ability to meet the completion dates or <br />schedules of this Agreement. <br /> <br />15. COORDINATION OF SERVICES. The City's representative/liaison during the <br />performance of this Agreement shall be the City Manager, telephone number 305/947-0606. <br />Contractor shall not respond to requests for services under this Agreement unless the request is <br />received directly from the City Manager, or designated personnel. Any requests received from <br />other City departments/divisions shall be referred to the City Manager's Department <br />representative designated above. Services performed without authorization by the City <br />Manager shall be considered unauthorized and shall not be compensated/paid by the City. <br /> <br />16. ARBITRATION. It is the intention of the parties that whenever possible, if a dispute or <br />controversy arises hereunder then such dispute or controversy shall be settled by arbitration in <br /> <br />Page 60f9 <br /> <br />.. _.S-~~ <br /> <br />Street Sweeping Agreement <br />