Reso 2006-927A - Laserfiche WebLink

Home Browse Search

City of Sunny Isles Beach 18070 Collins Avenue, Sunny Isles Beach, Florida JJ 160 (J05) 947-0606 phone (J05) 949-J II J Fax 11. ASSIGNMENTS, TRANSFERS, SUBCONTRACTING. The Consultant shall not subcontract, assign or transfer any work under th is agreement without the prior written consent of the City. Should the Consultant subcontract any services under this agreement, it shall be done with continued liability for the Consultant. The Consultant shall remain responsible for services, responsibilities and liabilities of any person or entity acting under Consultant. 12. TIME OF COMPLETION. The services to be rendered by the Consultant shall be commenced upon execution of this contract and shall be completed within the time specified in Exhibit "A", ifany time is indicated. A reasonable extension of time shall be granted in the event the work of the Consultant is delayed or prevented by the City or by circumstances beyond the reasonable control of the Consultant including weather conditions of acts of God which render the performance of the Consultant's duty impracticable. 13. AUTHORITY TO PRACTICE. Consultant hereby represents and warrants that it has and will continue to maintain all licenses and approvals required to conduct its business and that it will at all times conduct its business activities in a reputable manner. Proof of such licenses and approvals shall be submitted to the City prior to commencement of work under this Agreement. 14. MODIFICATIONS OF WORK. The City reserves the right to make changes in the work, including alterations, reductions or additions thereto. Upon receipt of the City's notification of a contemplated change, the Consultant shall (I) if requested by the City, provide an estimate for the increase or decrease in cost due to the contemplated change, (2) notify the City of any estimated change in completion date, and (3) advise the City in writing if the contemplated change shall affect the Consultant's ability to meet the completion dates or schedules of this Agreement. 15. COORDINATION OF SERVICES. The City's representative/liaison during the performance of this Agreement shall be A. John Szerlag, City Manager, telephone number 305/947-0606. Consultant shall not respond to requests for services under this Agreement unless the request is received directly from A. John Szerlag, City Manager, or designated personnel. Any requests received from other City departments/divisions shall be referred to the City Manager's Oepartment representative designated above. Set"vices performed without authorization by A. John Szerlag, City Manager, shall be considered unauthorized and shall not be compensated/paid by the City. 16. ARBITRATION. It is the intention of the parties that whenever possible, if a dispute or controversy arises hereunder then such dispute or controversy shall be settled by arbitration in accordance with the procedures, rules and regulations of the American Arbitration Association. The decision rendered by the Arbitrator shall be final and binding upon the parties and judgment upon the award rendered by the arbitrator may be entered in any court having jurisdiction. Arbitration shall be held in Miami-Oade County, Florida. The non-prevailing party shall pay all costs of arbitration and attorneys' fees incurred by the parties or, if neither party prevails on the whole, each party shall be responsible for a portion of the costs of arbitration and their respective attorneys' fees as may be determined by the court on confirmation. Town Center Park Restroom & Lighting Improvements. Doc 6 SIB