Reso 2006-901 - Laserfiche WebLink

Home Browse Search

City of Sunny Isles Beach 18070 Collins Avenue, Sunny Isles Beach, Florida 33160 (305) 947-0606 phone (305) 949-3113 Fax an estimate for the increase or decrease in cost due to the contemplated change, (2) notify the City of any estimated change in completion date, and (3) advise the City in writing if the contemplated change shall affect the Contractor's ability to meet the completion dates or schedules of this Agreement. 15. COORDINA TION OF SERVICES. The City's representative/liaison during the performance of this Agreement shall be James Watts, Public Works Director, telephone number 305/947-0606. Contractor shall not respond to requests for services under this Agreement unless the request is received directly from James Watts or designated personnel. Any requests received from other City depariments/divisions shall be referred to the City Manager's Department representative designated above. Services performed without authorization by James Watts, Public Works Director, shall be considered unauthorized and shall not be compensated/paid by the City. 16. ARBITRATION. It is the intention of the parties that whenever possible, if a dispute or controversy arises hereunder then such dispute or controversy shall be settled by arbitration in accordance with the procedures, rules and regulations of the American Arbitration Association. The decision rendered by the Arbitrator shall be final and binding upon the pariies and judgment upon the award rendered by the arbitrator may be entered in any court having jurisdiction. Arbitration shall be held in Miami-Dade County, Florida. The non-prevailing party shall pay all costs of arbitration and attorneys' fees incurred by the parties or, if neither pariy prevails on the whole, each party shall be responsible for a pOliion of the costs of arbitration and their respective attorneys' fees as may be determined by the court on confirmation. 17. CONFIDENTIAL INFORMATION. The Contractor shall not, either during the term of this Agreement or any time for a period of Ten (10) years subsequent to that date upon which the Contractor shall leave the employment of the City for any reason whatsoever, disclose to any person or entity, other than in the discharge of the duties of the Contractor under this Agreement, any information which the City designates in writing as "confidential." As a violation by the Contractor of the provisions of this Section could cause irreparable injury to the City and there is no adequate remedy at law for such violation, the City shall have the right, in addition to any other remedies available to it at law or in equity, to enjoin the Contractor in a couli of equity for violating such provisions. 18. NOTICES. All notices and communications hereunder shall be in writing and shall be deemed given when sent postage prepaid by registered or celiified mail, return receipt requested and, if intended for City to A. John Szerlag, City Manager, with a copy to Hans Ottinot, City Attorney, City of Sunny Isles Beach, 18070 Collins Avenue, Sunny lsles Beach, Florida 33160, and, if intended for Contractor, shall be addressed to Luke Facarazzo, President, Luke's Landscaping, Inc., 3920 NW 94th Avenue, Hollywood, Florida 33024. 19. GOVERNING LAW. The validity of this Agreement and the interpretation and performance of all of its terms shall be construed and enforced in accordance with the laws of the State of Florida, without regard to principles of conflict of laws thereof. The location of any action or proceeding commenced under or pursuant to this Agreement shall be in Miami-Dade County, in the State of Florida. Luke's Landscaping Supplemental Work Order # I Attorney/ Agrecments/pr 7 S\B