Reso 2006-982 - Laserfiche WebLink

Home Browse Search

City of Sunny Isles Beach 18070 Collins A venue, Sunny Isles Beach, Florida 33160 (305) 947-0606 phone (305) 949-3113 Fax of services pursuant to that agreement and to that extent the Consultant shall pay such claims and losses and shall pay all such costs and judgments which may issue from any lawsuit arising from such claims and losses including wrongful telmination or allegations of discrimination or harassment, and shall pay all costs and attomeys' fees expended by the City in defense of such claims and losses including appeals. The patties agree that ten percent (10%) of the total compensation is a specific consideration from the City to the Consultant for this indemnity. 11. TERMINATION. The City may, for its convenience and without cause, terminate the services then remaining to be perfOlmed provided that the Consultant is given thirty (30) days notice. 12. ASSIGNMENTS. TRANSFERS. SUBCONTRACTING. The Consultant shall not subcontract, assign or transfer any work under this agreement without the prior written consent of the City. Should the Consultant subcontract any services under this agreement, it shall be done with continued liability for the Consultant. The Consultant shall remain responsible for services, responsibilities and liabilities of any person or entity acting under Consultant. 13, TIME OF COMPLETION. The services to be rendered by the Consultant shall be commenced upon execution of this contract and shall be completed by September 2], 2007. A reasonable extension of time shall be granted in the event the work of the Consultant is delayed or prevented by the City or by circumstances beyond the reasonable control of the Consultant including weather conditions or acts of God which render the performance of the Consultant's duty impracticable. 14. AUTHORITY TO PRACTICE. Consultant hereby represents and wan'ants that it has and will continue to maintain all licenses and approvals required to conduct its business and that it will at all times conduct its business activities in a reputable manner. Proof of such licenses and approvals shall be submitted to the City prior to commencement of work under this Agreement. 15. MODIFICATIONS OF WORK. The City reserves the right to make changes in the work, including alterations, reductions or additions thereto. Upon receipt of the City's notification of a contemplated change, the Consultant shall (1) if requested by the City, provide an estimate for the increase or decrease in cost due to the contemplated change, (2) notify the City of any estimated change in completion date, and (3) advise the City in writing if the contemplated change shall affect the Consultant's ability to'meet the completion dates or schedules of this Agreement. 16. COORDINATION OF SERVICES. The City's representative/liaison during the perfOlmance of this Agreement shall be Thomas Acquaro, Human Resources Director whose phone number is 305/792-] 708. Any requests received from other City depattments/divisions shall be refen'ed to Thomas Acquaro first for approval or if Thomas Acquaro is unavailable to the City Manager, A. John Szerlag for approval prior to the commencement of any work. Services performed without authorization by Thomas Acquaro, Human Resources Director, or the City Manager, A. John Szerlag, shall be considered unauthorized and shall not be compensated/paid by the City. 17. ARBITRATION. It is the intention of the parties that whenever possible, if a dispute or controversy arises hereunder then such dispute or controversy shall be settled by arbitration in accordance with the procedures, rules and regulations of the American Arbitration Association. The decision rendered by the Arbitrator shall be final and binding upon the parties and judgment upon the C0506-073 - Professional Services Agreement with The Mercer Group, Inc. 6 SIB