Reso 2006-958 - Laserfiche WebLink

Home Browse Search

City of Sunny Isles Beach 18070 Collins Avenue, Sunny Isles tieach, Florida 33160 (305) 947-0606 phone (305) 949-3113 Fax it will at all times conduct its business activities in a reputable manner. Proof of such licenses and approvals shall be submitted to the City prior to commencement of work under this Agreement. 13. MODIFICA TIONS OF WORK. The City reserves the right to make changes in the work, including alterations, reductions or additions thereto. Upon receipt of the City's notification of a contemplated change, the Contractor shall: I) if requested by the City, provide an estimate for the increase or decrease in cost due to the contemplated change, (2) notify the City of any estimated change in completion date, and (3) advise the City in writing if the contemplated change shall affect the Contractor's ability to meet the completion dates or schedules of this Agreement. 14. COORDINATION OF SERVICES. The City's representative/liaison during the performance of this Agreement shall be James Watts, telephone number 305/947-0606. Contractor shall not respond to requests for Services under this Agreement unless the request is received directly from James Watts or Christopher J. Russo, City Manager, or designated personnel. Any requests received from other City departments/divisions shall be referred to the City Manager's department representative designated above. Services performed without authorization shall be considered unauthorized and shall not be compensated or paid by the City. 15. A TTORNEY'S FEES. If this matter is placed in the hands of an attorney for collection, or in the event a suit, action or legal proceeding is instituted to enforce any of the terms or conditions of this Agreement, the losing party shall pay to the prevailing party, in such suit or action in both trial court and appellate court, together with reasonable attorney's fees for the anticipated cost of collection and judgment enforcement. 16. CONFIDENTIAL INFORMATION. The Contractor shall not, either during the term of this Agreement or any time for a period of ten (10) years subsequent to that date upon which the Contractor shall leave the employment of the City, for any reason whatsoever, disclose to any person or entity, other than in the discharge of the duties of the Contractor under this Agreement, any information which the City designates in writing as "confidential." As a violation by the Contractor of the provisions of this Section could cause irreparable injury to the City and there is no adequate remedy at law for such violation, the City shall have the right, in addition to any other remedies available to it at law or in equity, to enjoin the Contractor in a court of equity for violating such provisions. 17. NOTICES. All notices and communications hereunder shall be in writing and shall be deemed given when sent postage prepaid by registered or certified mail, return receipt requested and, if intended for City to Christopher J. Russo, City Manager, with a copy to Hans Ottinot, City Attorney, City of Sunny Isles Beach, 18070 Collins Avenue, Sunny Isles Beach, Florida 33160, and, if intended for Contractor, shall be addressed to Nalepa Pool Rangers, Inc. 775 NE 113 th Street, Biscayne Park, FL 33161 (Phone No. 305-892-2471), Attention: Gary Nalepa. Page 6 of 10 Pool Rangers. Inc. Attorncyl Agrcemcnts/j b 7/20/2005 SIB S/8