Reso 2007-1055 - Laserfiche WebLink

Home Browse Search

City of SIIIIIIY Isles Beaell 18070 Collins A venue, Sunny Isles Beach, Florida 33160 (305) 947-0606 phone (305) 949-3113 Fax II. ASSIGNMENTS, TRANSFERS, SUBCONTRACTING. The Consultant shall not subcontract, assign or transfer any work under this agreement without the prior written consent of the City. Should the Consultant subcontract any services under this agreement, it shall be done with continued liability for the Consultant. The Consultant shall remain responsible for services, responsibilitics and liabilities of any person or entity acting under Consultant. 12, TIME OF COMPLETION. The services to be rendered by thc Consultant shall bc commenced upon execution of this contract and shall be complctcd within the time specified in Attachment "A", unless otherwise extended by written consent of the City. A reasonable extension of time shall be granted in the event the work of the Consultant is delayed or prevented by the City or by circumstances bcyond the reasonable control of the Consultant including weather conditions of acts of God which render the performance of the Consultant's duty impracticable. 13. AUTHORITY TO PRACTICE. Consultant hereby represents and warrants that it has and will continue to maintain alllicenscs and approvals required to conduct its business and that it will at all times conduct its business activities in a reputable manner. Proof of such licenses and approvals shall be submitted to the City prior to commencement of work under this Agreement. 14, MODIFICATIONS OF WORK. The City rcserves the right to make changes in the work, including alterations, reductions or additions thereto. Upon receipt of the City's notification of a contemplated change, the Consultant shall (I) if requested by the City, provide an estimate for the increase or decrease in cost due to thc contemplated change, (2) notify the City of any estimated change in completion date, and (3) advise the City in writing if the contemplated change shall affect the Consultant's ability to meet the completion dates or schedules of this Agreement. 15, COORDINATION OF SERVICES, The City's representative/liaison during the performance of this Agreement shall be JOI'ge L. Vera, Assistant City Manager, telephone number 305/947-0606. Consultant shall not respond to requests for services under this Agreement unless the rcqucst is received directly from Jorge L, Vera, Assistant City Manager, or designated personnel. Any requests received from other City departments/divisions shall be rcferred to the City Manager's Departmcnt rcpresentative designated above. Set'vices performed without authol'ization by, ,Ior'ge Vera, Assistant City Manager, shall be considered unauthol'ized and shall 1I0t be compensated/paid by the City, 16, ARBITRATION. It is the intention of the parties that whenever possible, if a dispute or controversy arises hereunder then such dispute or controversy shall be settled by arbitration in accordance with the procedures, rules and regulations of the American Arbitration Association, The decision rendered by the Arbitrator shall be final and binding upon the parties and judgment upon the award rendered by the arbitrator may be entered in any court having jurisdiction. Arbitration shall be held in Miami-Dadc County, Florida, The non-prevailing party shall pay all costs of arbitration and attorneys' fees inemred by the parties or, if neither party prevails on the whole, each party shall be responsible for a portion of the costs of arbitration and their respective attorneys' fees as may be determined by the court on confirmation. C0607-021CGA Engineering Design & Construction Engineering Inspection Services Agreement Page 6 01'9 SIB