Specifications - Laserfiche WebLink

Home Browse Search

I 12. ASSIGNMENTS. TRANSFERS. SUBCONTRACTING. The Contractor shall not subcontract, assign or transfer any work under this agreement without the prior written consent of the City. Should the Contractor subcontract any services under this agreement, it shall be done with continued liability for the Contractor. The Contractor shall remain responsible for services, responsibilities and liabilities of any person or entity acting under Contractor. 13. TIME OF COMPLETION. The services to be rendered by the Contractor shall be commenced upon execution of this contract and shall be completed by . A reasonable extension of time shall be granted in the event the work of the Contractor is delayed or prevented by the City or by circumstances beyond the reasonable control of the Contractor including weather conditions or acts of God which render the performance of the Contractor's duty impracticable. 14. AUTHORITY TO PRACTICE. Contractor hereby represents and warrants that it has and will continue to maintain all licenses and approvals required to conduct its business and that it will at all times conduct its business activities in a reputable manner. Proof of such licenses and approvals shall be submitted to the City prior to commencement of work under this Agreement. 15. MODIFICATIONS OF WORK. The City reserves the right to make changes in the work, including alterations, reductions or additions thereto. Upon receipt of the City's notification of a contemplated change, the Contractor shall (1) if requested by the City, provide an estimate for the increase or decrease in cost due to the contemplated change, (2) notify the City of any estimated change in completion date, and (3) advise the City in writing if the contemplated change shall affect the Contractor's ability to meet the completion dates or schedules of this Agreement. 16. COORDINATION OF SERVICES. The City's representative/liaison during the performance of this Agreement shall be Jorge Vera, Assistant City Manager whose phone number is 305/792-1912. Contractor shall not respond to requests for services under this Agreement unless the request is received directly from Jorge Vera, Assistant City Manager, or his designated personnel. Any requests received from other City departments/divisions shall be referred to Jorge Vera first for approval or if Jorge Vera is unavailable, then to the Acting City Manager, Rick Conner for approval prior to the commencement of any work. Services performed without authorization by Jorge Vera, Assistant City Manager, or the Acting City Manager, Rick Conner, shall be considered unauthorized and shall not be compensated/paid by the City. 17. ARBITRATION. It is the intention of the parties that whenever possible, if a dispute or controversy arises hereunder then such dispute or controversy shall be settled by arbitration in accordance with the procedures, rules and regulations of the American Arbitration Association. The decision rendered by the Arbitrator shall be final and binding upon the parties and judgment upon the award rendered by the arbitrator may be entered in any court having jurisdiction. Arbitration shall be held in Miami-Dade 21