Specifications - Laserfiche WebLink

Home Browse Search

convey, sublet, or otherwise dispose of this contract, or of any or all of its right, title, or interest therein, or its power to execute such contract to any person, firm, or corporation without prior written consent of the City. Any unauthorized assignment shall constitute a default by the successful respondent. 10.7. Default. Failure or refusal of a respondent to negotiates a contract upon qualifying by the City Commission, or untimely withdrawal of response before such qualifying is made and approved, may result claim for damages by the City and may be grounds for removing the respondent from the City's qualifier list. 11. Taxes. The respondent is responsible for paying any and all taxes associated with the agreement. 12. Termination of Agreement. If the respondent fails to perform the conditions of the agreement as specified and as interpreted by the Manager, the Manager shall provide written notice of such violation. 12.1 The City reserves the right to terminate the agreement, without cause, with a 30- day calendar written notice unless otherwise provided in the contract. 12.2 Termination and cancellation of any agreement will not relieve the respondent for work, which was to be completed prior to the termination or cancellation of the agreement. 12.3 If the agreement is terminated for cause, respondent will be removed from the City's qualifier list. 12.4 The City Commission shall have the right to terminate the agreement in the event the respondent files any petition or proceeding for bankruptcy relief or is adjudicated to be bankrupt or insolvent or fails to pay just debts as they ordinarily become due. 12.5 This agreement may not be terminated by the respondent unless otherwise provided in the contract. 13. Insurance Requirements. 13.1 General. The respondent, including service - related respondents, shall purchase and maintain for the entire life of the Project, including any and all approved time extensions, until three (3) years after final acceptance by the City of any completed project (which is in receipt of an issued Certificate of Occupancy,) such insurance as will protect the respondent from claims under professional liability, Workers' Compensation, disability benefit laws or other similar employee benefit laws; from claims for damages because of bodily injury, occupational sickness or disease, or death of respondent employees; from claims insured by usual or unusual injury liability coverage; from claims or injury to or destruction of tangible property and from claims insured by usual Commercial General Liability coverage. The successful respondent shall provide copies of a Certificate of Renewal of insurance for each year of the contract and for three (3) Page 7 of 7 Architectural Services Design & Specifications 71171013:38 PM