Reso 2010-1605 - Laserfiche WebLink

Home Browse Search

PROVISION 4 ADMINISTRATION OF THE CONTRACT 4.1 Rights of the City 4.1.1 The City's Representative will administer the Construction Contract. The AlE will assist the City's Representative with the administration of the Contract as indicated in these Contract Documents. 4.1.2 If, in the judgment of the City's Representative, it becomes necessary to accelerate the work, the Contractor, when directed by the City's Representative in writing, shall cease work at any point and transfer its workers to such point or points and execute such portions of the work as may be required to enable others to hasten and properly engage and carry out the work, all as directed by the City's Representative. The additional cost of accelerating the work, if any, will be borne by the City, unless the Contractor's work progress is behind schedule as shown on the most recent progress schedule. 4.1.3 The City's Representative, may, by written notice, require a Contractor to remove from involvement with the Work, any of Contractor's personnel or the personnel of its Subcontractors of any tier whom the City's Representative may deem abusive, incompetent, careless, or a hindrance to proper and timely execution of the Work. The Contractor shall comply with such notice promptly, but without detriment to the Work or its progress. 4.1.4 The City's Representative will schedule Work status meetings that shall be attended by representatives of the Contractor and appropriate Subcontractors of any tier. Material suppliers shall attend status meetings if required by the City's Representative. 4.2 Review of the Work 4.2.1 The NE and the City's Representative shall, at all times, have access to the Work; and the Contractor shall provide proper and safe facilities for such access. 4.2.2 The City's Representative shall have authority to reject Work that does not strictly comply with the requirements of the Contract Documents. Whenever the City's Representative considers it necessary or advisable for implementation of the intent of the Contract Documents, City's Representative shall have the authority to require additional inspection or testing of the Work, whether or not such Work is fabricated, installed or completed. 4.2.3 The fact that the AlE or the City's Representative observed, or failed to observe, faulty Work, or Work done which is not in accordance with the Contract Documents, regardless of whether or not the City has released final payment, shall not relieve the Contractor from responsibility for all damages and additional costs of the City as a result of defective or faulty Work. 20