|
<br />SECTION 15
<br />
<br />FORM OF PAYMENT BOND
<br />
<br />KNOW ALL MEN BY THESE PRESENTS:
<br />
<br />the requirements of Florida Statute 255.05, we,
<br />, as Principal, hereinafter called Contractor, and,
<br />as Surety, are bound to the City of Sunny Isles
<br />Beach, Florida, as Obligee, hereinafter ailed City, in the amount of [\vUu \\tWld(('o-t~~~(}f'L\ .1..Dollars
<br />($ ..J()() I 000. OC) ) for the payment whereof Contractor and Surety bind themselves, their
<br />heirs, executors, administrators, successors and assigns, jointly and severally.
<br />
<br />
<br />WHEREAS, Contractor has by written agreement entered into a Contract, Bid/Contract No. [type in
<br />Bid No. O~,O ~-OL -L-awarded the Z~~ day of--.:rlf\R ,20~ ,
<br />with Janitorial Maintenance Services in accordance with contract documents prepared by the City of
<br />Sunny Isles Beach, which Contract is by reference made a part hereof, and is hereafter referred to as the
<br />Contract;
<br />
<br />THE CONDITION OF THIS BOND is that if the Contractor:
<br />
<br />15.1. Indemnifies and pays City all losses, damages (specifically including, but not limited to, damages
<br />for delay and other consequential damages caused by or arising out of the acts, omissions or negligence
<br />of Contractor), expenses, costs and attorney's fees including attorney's fees incurred in appellate
<br />proceedings, that City sustains because of default by Contractor under the Contract; and
<br />
<br />15.2. Promptly makes payments to all claimants as defined by Florida Statute 255. 05( 1) supplying
<br />Contractor with all labor, materials and supplies used directly or indirectly by Contractor in the
<br />prosecution of the Work provided for in the Contract, then this obligation shall be void; otherwise, it shall
<br />remain in full force and effect subject, however, to the following conditions:
<br />
<br />15.2.1. A claimant, except a laborer, who is not in privity with the Contractor and who has not
<br />received payment for their labor, materials, or supplies shall, within forty-five (45) days
<br />after beginning to furnish labor, materials, or supplies for the prosecution of the Work,
<br />furnish to the Contractor a notice that they intend to look to the Bond for protection.
<br />
<br />15.2.2. A claimant who is not in privity with the Contractor and who has not received payment
<br />for their labor, materials, or supplies shall, within ninety (90) days after performance of the
<br />labor, or after complete delivery of the materials or supplies, deliver to the
<br />Contractor and to the Surety, written notice of the performance of the labor or delivery of
<br />the materials or supplies and of the non-payment.
<br />
<br />15.2.3. No action for the labor, materials, or supplies may be instituted against Contractor or
<br />the Surety unless the notices stated under the preceding paragraphs 16.2.1 and 16.2.2
<br />have been given.
<br />
<br />15.2.4. Any action under this Bond must be instituted in accordance with the Notice and Time
<br />Limitations provisions prescribed in Section 255.05(2), Florida Statutes.
<br />
<br />The Surety hereby waives notice of and agrees that any changes in or under the Contract Documents
<br />
|