Reso 2011-1758 - Laserfiche WebLink

Home Browse Search

City of Sunny Isles Beach 18070 Collins Avenue, Sunny Isles Beach, Florida 33160 (305) 947-0606 phone (305) 949-3113 Fax 21. AUTHORITY TO PRACTICE. Contractor hereby represents and warrants that it has and will continue to maintain all licenses and approvals required to conduct its business and that it will at all times conduct its business activities in a reputable manner. Proof of such licenses and approvals shall be submitted to the City prior to commencement of work under this Agreement. 22. MODIFICATIONS OF WORK. The City reserves the right to make changes in the work, including alterations, reductions or additions thereto. Upon receipt of the City's notification of a contemplated change, the Contractor shall (1) if requested by the City, provide an estimate for the increase or decrease in cost due to the contemplated change, (2) notify the City of any estimated change in completion date, and (3) advise the City in writing if the contemplated change shall affect the Contractor's ability to meet the completion dates or schedules of this Agreement. 23. COORDINATION OF SERVICES. The City's representative/liaison during the performance of this Agreement shall be Gio Batista, Public Works Director/City Engineer whose phone number is (305) 792-1909. Contractor shall not respond to requests for services under this Agreement unless the request is received directly from Gio Batista. Any requests received from other City departments/divisions shall be referred to Gio Batista first for approval or if Gio Batista is unavailable, then to the City Manager, Alan J. Cohen for approval prior to the commencement of any work. Services performed without authorization by Gio Batista, Public Works Director/City Engineer or the City Manager, Alan J. Cohen, shall be considered unauthorized and shall not be compensated/paid by the City. 24. MEDIATION AND ARBITRATION OF DISPUTES The merits of any dispute arising under, out of, in connection with, or in relation to this agreement, or the making or validity thereof, or its interpretation, or any breach thereof, shall be determined and settled by Arbitration before an Arbitrator in the State of Florida, pursuant to the Commercial Arbitration Rules then obtaining of the American Arbitration Association. If the parties hereto are unable to agree upon the selection of an arbitrator, such arbitration shall be held before the American Arbitration Association. Any award rendered shall be final and conclusive upon the parties hereto and a judgment thereon may be entered in the highest court of the State of Florida having jurisdiction. Before submitting a dispute to Arbitration, the parties shall first attempt to resolve the dispute amicably. In the event that the parties hereto are unable to resolve the dispute amicably, either party may give notice for a Mediation session before a Mediator appointed by mutual agreement (hereinafter the "Mediator"). If the parties are unable to agree upon the selection of a mediator, such mediation shall be held before the American Arbitration Association. The Mediator shall make a recommendation to the parties in the form of a written mediated C 1 0 11-067 THE SG GROUP, LLC. AGREEMENT Page 9 of 13 S/6