Goodyear - Laserfiche WebLink

Home Browse Search

`11r or SmA P` flood, events which are not the fault of or are beyond the control of the Contractor, the City, after setting up a new delivery of performance schedule, may allow the Contractor to continue work, or treat the termination as a termination for convenience. c. Opportunity to Cure (General Provision) The City in its sole discretion may, in the case of a termination for breach or default, allow the Contractor 30 days in which to cure the defect. In such case, the notice of termination will state the time period in which cure is permitted and other appropriate conditions If Contractor fails to remedy to City's satisfaction the breach or default of any of the terms, covenants, or conditions of this Contract within [ten (10) days] after receipt by Contractor of written notice from City setting forth the nature of said breach or default, City shall have the right to terminate the Contract without any further obligation to Contractor. Any such termination for default shall not in any way operate to preclude City from also pursuing all available remedies against Contractor and its sureties for said breach or default. d. Waiver of Remedies for any Breach In the event that City elects to waive its remedies for any breach by Contractor of any covenant, term or condition of this Contract, such waiver by City shall not limit City's remedies for any succeeding breach of that or of any other term, covenant, or condition of this Contract. e. Termination for Convenience The City, by written notice, may terminate this contract, in whole or in part, when it is in the Government's interest. If this contract is terminated, the Recipient shall be liable only for payment under the payment provisions of this contract for services rendered before the effective date of termination. f. Termination for Default If the Contractor fails to deliver supplies or to perform the services within the time specified in this contract or any extension or if the Contractor fails to comply with any other provisions of this contract, the City may terminate this contract for default. The City shall terminate by delivering to the Contractor a Notice of Termination specifying the nature of the default. The Contractor will only be paid the contract price for supplies delivered and accepted, or services performed in accordance with the manner or performance set forth in this contract. If, after termination for failure to fulfill contract obligations, it is determined that the Contractor was not in default, the rights and obligations of the parties shall be the same as if the termination had been issued for the convenience of the Recipient. The Contractor's right to proceed shall not be terminated nor the Contractor charged with damages under this clause if- 1. The delay in completing the work arises from unforeseeable causes beyond the control and without the fault or negligence of the Contractor. Examples of such causes include: acts of God, acts of the Recipient, acts of another Contractor in the performance of a contract with the Recipient, epidemics, quarantine restrictions, strikes, freight embargoes; and 2. The contractor, within [10] days from the beginning of any delay, notifies the City in writing of the causes of delay. If in the judgment of the City, the delay is excusable, the time for completing the work shall be extended. The judgment of the City shall be final and conclusive on the parties, but subject to appeal under the Disputes clauses. City of Sunny Isles Beach I Request for Proposal No. 12 -05 -02