|
Completion Dates shall not be deemed to.be.extended and Contractor will be expected to achieve
<br />Completion of the Project on or prior to the Scheduled Substantial and Final Completion Dates,
<br />ARTICLE 28. CONSTRUCTION OF WORK
<br />28.1 Contractor shall, in a good and workmanlike manner and in accordance with this
<br />Agreement, prosecute and perform the Work described in and reflected on the Plans and
<br />Specifications. Contractor understands and acknowledges that the City is entering into this
<br />Agreement in reliance upon Contractor's special skill and abilities in performing the Work
<br />hereunder. Contractor shall supervise and direct the Work to be performed in connection with the
<br />Project using Contractor's best efforts, skill, judgment, abilities and attention, and Contractor
<br />shall be solely responsible for all fabrication, shipment, delivery and installation means, methods,
<br />techniques, sequences and procedures, and for coordinating and implementing all portions of the
<br />Work to be performed under this Agreement. Contractor shall provide and pay for all labor,
<br />materials, equipment, tools, machinery, transportation, storage and other facilities and services.
<br />necessary for the proper execution and completion of the Work, whether temporary or permanent
<br />and whether or not incorporated or to be incorporated in the Project.
<br />28.2 Contractor shall at all times enforce strict discipline and good order among Contractor's
<br />employees and shall not employ on the Project any unfit person or anyone not skilled in the task
<br />assigned them. Contractor will clean up and haul away all debris resulting from the performance
<br />of the Work hereunder and will at all times keep and leave the Project in as clean and orderly
<br />condition as the circumstances will permit. All materials, equipment, furnishings and fixtures
<br />incorporated in the Work will be new unless otherwise specified, and all Work to be performed
<br />hereunder will be of a good quality, free from faults and defects, and in conformance with the
<br />provisions of this Agreement, the Plans and Specifications and any other written instrument or
<br />document approved by the City and Contractor in writing and relating to the performance and
<br />prosecution of the Work in connection with the Project.
<br />ARTICLE 29. ADEQUATE SAFETY PRECAUTIONS
<br />29.1 Contractor shall be responsible for initiating, maintaining and supervising all safety
<br />precautions and programs in connection with the performance of its obligations pursuant to this
<br />Agreement. Contractor shall take reasonable precautions for the safety of, and shall provide
<br />reasonable protection to prevent damage, injury or loss to, (a) employees at the Project and other
<br />persons who may be affected thereby, (b) the Work and all materials and equipment to be
<br />incorporated therein, whether in storage on or off the Project site, and (c) all other property at the
<br />Project site or adjacent thereto, such as trees, shrubs, walkways, pavement, driveways, streets and
<br />utilities not designated for removal, relocation or replacement during the course of construction.
<br />Contractor shall erect and maintain, as may be dictated by the conditions surrounding the
<br />performance of the Work, reasonable safeguards for the safety and protection of all persons and
<br />property, including, without limitation, posting danger signs and warnings against potential
<br />hazards, promulgating safety regulations, and installing and maintaining safety and silt fencing
<br />around the perimeter of the Project site, if necessary. If and to the extent any hazardous materials
<br />or equipment or other unusual methods become necessary for the execution of the Work,
<br />Contractor shall exercise utmost care and carry on such activities under the supervision of properly
<br />qualified personnel.
<br />030.6179 - AMERICAN RAMP COMPANY 22
<br />
|