HomeMy WebLinkAboutSoutheastern Engineering Contractors, Inc.
SECTION 00300
BID FORM
Bid of S~ u71-/~11 S./~I?'V t-vGrll/(~el?//I/G d,Vk4(1'!c.'RS ,:tP0
Address 1,y(!Y6'1 lOb.) 9r:f71; live- JI/.J#It}r;;,~IJP,()s//~1
Phone (.90.5-) 56-'7- Vd--.;Lk
To furnish all materials, equipment and labor and to perform all work in accordance with
the Contract Documents for construction of: sanitary sewer collection system with
gravity sewer lines, manholes, WASD Lift Station and Force main; Paving, Grading, and
Drainage improvements; Under grounding of certain utilities, such as FPL Power,
CATV, and Telephone will require coordination with others. The installation of a new
water main with seNices is also proposed by the City of North Miami Beach to be
constructed contemporaneously, but not as a part of this contract located in the CITY
OF SUNNY ISLES BEACH.
To: CITY OF SUNNY ISLES BEACH
18070 Collins Avenue, Suite 250 .
Sunny Isles Beach, Florida 33160
The undersigned Bidder has carefully examined the Bidding Documents and the site of
the proposed work and is familiar with the nature and extent of the work and any local
conditions that may in any manner affect the work to be done.
The undersigned Bidder agrees to do all the work and furnish all materials called for by
the Bidding Documents, in the manner prescribed therein and to the standards of quality
and performance established by the Engineer for the unit price amounts stated in the
spaces herein provided, for each of the items or combination of items stipulated. Unit
price line items shall include cost of implementing all applicable safety requirements.
Bidder acknowledges that estimated quantities scheduled are approximated for the sole
purpose of obtaining comparative bids for determination of the lowest responsible and
responsive bidder whose bid best serves the interest of, and represents the best value
to, the Owner pursuant to the criteria set forth in Section 62-8 of the City Code, and that
actual quantities required may increase or decrease. Bidder further agrees that
payments will be made on the basis of actual quantities placed and accepted in the
construction. Bidder acknowledges that price is only a factor in determining the lowest
responsible and responsive bidder.
RECEIVED
~~~:~,~:~ ~';:;;
Office ollne C Clerk ~
05/08
00300- ]
05-4893
Atlantic Isles Roadway and Utility Improvements
Bid Estimated
Item Description Quantity Unit Unit Price Estimated Total
I. General
1 Mobilization and Demobilization (< 5 %) LS $ 9~ &00.00 $ 90, tlaJ. 00
2 MOT, per FOOT including temporary striping and ,
signage, barricades, barriers, arrow panels, etc. as ,:)~. tJcJ{J. (/0
required. LS $ $ :.10,OO~ .&;
,
Subtotal-General $ II U, tJ du. tJ{)
II. Civil
A Demolition / Site Preparation
3 Asphalt pavement demolition/hauling and disposal LS $ / /, (J (}f) ( () () $ il (jOt), tJO
4 Driveway demolition/Hauling and disposal LS $ 3~. {JIlt}. tJO $ 3:2, OtJt1; d()
5 Drainage structures to be removed or abandoned
in place and filled with flowable fill LS $ &, oao, (JtJ $ b. O{%). tJ{}
6 Relocate or adjust existing street signs LS $ I. 5lJ tJ , 01) $ / !JlJtJ..(}t)
7 Remove power /light poles LS $ ~/)O/), (Jf) $ "j IJO/J. t':t:J
8 Relocate existing mailboxes LS $ . . f,:) S~ tl() $ :Ji8'~:M
B Earthwork
9 Green areas in R/W, including fine grade swales
and sod (between back of curb & R/W) LS $ ')-3 ,otJ/J. (.t:J $ 53, c.W. clQ
10 Roadway earthwork LS $ , '? /) ()()(). (J() $ 3tJ,/Ja:;. {k)
, ,
C Paving
11 Asphalt type, FC 12.7, 2.0 inches 8,400 SY $ It,. d~- $/ ?/7. 3(10,00
.
1 2 8" limerock base 10,000 SY $ / ::.>-. /)/) $ /.:;;-0, {JOd, ()cJ
13 12" Stabilize sub-base material 11,000 SY $ 5.IJO $ &5~ atl tJO
14 Select fill 3,350 CY $ d1. 00 $ 71,r05tJ,tJeJ
15 Driveway restoration (per detail on sheet C19) 2,150 SY $ ~::J. tJD $ /33 3M, tV)
16 Type F curb and gutter 3,170 LF $ ~j,nO $ ~ 0, 5 7 (),IO
17 Valley gutter 2,175 LF $ ~/.DC $ L/.5~ b 7s'o(J
18 Transition curb 500 LF $ cJ-./. 00 $ If), ~-OO. /JO
19 Concrete flume 5 EA $ 70t),/JO $ ..3 ,.!>OtJ, t) 0
!/)CJ . (10 , t./. ~ (), C)()
20 Flare end curb 4 EA $ $
21 Pavement seam joint at bridge location 1 LS $ ;)."OO/J.O() $ ,.2. IJOtJ.. 00
D Drainage Structures and Piles
22 Curb drop inlets 22 EA $ .:1, t.OO /)0 $ 5'7,.:;)01), dO
23 Manhole Cover & Frame 2 EA $ -7ot). 00 $ I (too d>O
24 Catch basin Type E 3 EA $ :3 300(1)0 $ q 9tJthoo
25 Catch basin Type 0 8 EA $ ;)' . q 00. I)!J $ d '3 ;JOt);(.XJ
26 Catch basin Type C 14 EA $ ,") , 1& g. ()IJ $ cJ~ 77,;) tJO
27 Control structures 1 LS $ / t../ 001J. /'Jt'J $ I (j. / L 00, Do
28 Pollution retardant baffles 26 EA $ , 3b[). ()f) $ 7 fV'tJ,o/)
29 Furnish & Install 1 5" RCP drainage pipe complete
(including but not limited to excavation, bedding,
backfill, compaction & restoration as per plans L,tl 00 $ q 9, ,Jg 0.. tJD
and specifications) 770 LF $
05/08-Addendum NO.5
00300-2
05-4893
Atlantic Isles Roadway and Utility Improvements
Bid Estimated
Item Description Quantity Unit Unit Price Estimated Total
30 Furnish & Install 18" RCP drainage pipe complete
(including but not limited to excavation, bedding,
backfill, compaction & restoration as per plans S70tJ 101 j -J- S', ~ ()
and specifications) 325 LF $ $
31 Furnish & Install 24" RCP drainage pipe complete
(including but not limited to excavation, bedding,
backfill, compaction & restoration as per plans
and specifications) 1,650 LF $ I~ I. i-'C) $ /00/ bj-a,OO
32 Furnish & Install 30" RCP drainage pipe complete
(including but not limited to excavation, bedding,
backfill, compaction & restoration as per plans '71c.{)O 57/,7;2IJ.tJO
and specifications) 720 LF $ $
33 Ultralite Tideflex Check Valve 1 EA $ ?,l/OC). lJO $ g doo. 00
34 Vortech-Model 5000 1 LS $ L/ b ,OlJO, (}() $ ili ,OCU. 00
E Sanitary Sewer System and Force Main per
WASD Standards/Spec
35 F&I 8" PVC sanitary sewer complete (including
but not limited to excavation, bedding, backfill,
compaction & restoration as per plans and 7d.OO
specifications) 2,340 LF $ $ It: 3, too ,t){)
36 F&I 8" DIP sanitary sewer complete (including but
not limited to excavation, bedding, backfill,
compaction & restoration as per plans and Y (), (){) r, bt>o () ()
specifications) 120 LF $ $
37 F&I 10" PVC sanitary sewer complete {including
but not limited to excavation, bedding, backfill,
compaction & restoration as per plans and 70. ()O / %, rtJo. (Jc)
specifications) 270 LF $ $
38 F&I 12" PVC sanitary sewer complete (including
but not limited to excavation, bedding, backfill,
compaction & restoration as per plans and
specifications) 45 LF $ 7;1./)0 $ 31:2C/t.>,t)u
39 Sanitary drop manholes 48" dia. 1 EA $ ..5: /00 .00 $ .s-; 101) , () 0
40 Core drill existing manhole #24 1 EA $ ,.:;, u! t1d 00 $ <-:.21 ()(}O. 00
41 Sanitary manholes 48" dia. 22 EA $ N.J?tJ&, i.^)? $ b I , boo, DO
42 F&I 6" DIP force main complete (including but not
limited to excavation, bedding, backfill.
compaction & restoration as per plans and l./t:, .00 S.;J,7()O.()O
specifications) 1,150 LF $ $
43 F&I 8" DIP force main complete {including but not
limited to excavation, bedding, backfill,
compaction & restoration as per plans and !:>~ I:. ()O . 00
specifications) 50 LF $ I';) .O() $
44 Miscellaneous sanitary PVC fittings 1 LS $ c). ~(). /)0 $ ~ . t.totJ. DO
45 Miscellaneous DIP valves and fittings 1 LS $ ,/1 OtJ.OO $ LI: f:, OtJ, /) j)
,
46 F&I 6" sanitary services laterals complete
(including but not limited to excavation, bedding,
backfill, compaction & restoration as per plans
and specifications) 62 EA $ /, S-atJ, 00 $ Cj 3, DOb. tJd
47 F&I 6" Force main bridge crossing as per detail on ().~ I O.iJ7), tJ{)
addendum (Bridge No. A) 63 LF $ 3!;~,OO $
48 F&I 6" Force main bridge crossing as per detail on 35o.tJO 17, I{ iJO. DO
addendum (Bridge No. B) 51 LF $ $
05/08-Addendum No. 5 00300-3 05-4893
Atlantic Isles Roadway and Utility Improvements
Bid
Item
Description
Estimated
Quantity Unit
Unit Price
Estimated Total
F Lift Station
49 Complete as per plans to include but not limited
to labor, equipment, materials, electric, $ ;l /:; J,{){J~. () 0
mechanical, earthwork, etc LS $ ;J ~ ;;. , 0 ()() . va
G Pavement Marking, Striping and Signage
50 18" yellow solid line 76 LF $ 0:;. 7!:J- $ ..).~ 7. () ()
51 18" white solid line 290 LF $ D. ?~~ $ 797,.9)
52 24" stop bar 18 LF $ ,3..t~S- $ bJ-' ItJ
53 6" double yellow 122 LF $ /.00 $ / q ~-. CJ()
54 8" white 10'-30' skip 0.50 GM $ t./, 2XJ~. tJ() $ r:.< I 1513.00
55 8" white solid line 351 LF $ I, ().f- $ 3bJ .S~
56 RPM amber/amber 85 EA $ c./.i{{) $ ,37f/,Ou
57 RPM blue/blue 6 EA $ 4,(/0 $ Ol~. C/O
58 R5-1 (Do Not Enter) 3 EA $ d)!:J~, 00 $ /'..!/7J, {J ()
59 R6-1 L (One Way) 1 EA $ ~5ZJ. 0" $ .~:::>(). OCJ
60 R6-1 R (One Way) 3 EA $ a. !;7), t () $ "7~(), 00
61 R3-1 (No Right Turn) 1 EA $ a~. tJtJ $ ~SlJ "CJO
62 R1-2 (Yield) 1 EA $ ;). 57J. OcJ $ ;;l ~~ ,00
$ " CJ7J, :JJ'3,,:SJ -
Subtotal-Civil
III. Electrical - Street Lighting
63 Furnish and install decorative light pole cost 33 EA $ 1, ,;)00. Or) $ ~ 3:7, b 0tJ. &.J
64 Furnish and install decorative light fixture cost 33 EA $ I ,.;J;lS, OD $ Llf). C/&J.CO
65 Wiring of light fixtures 33 EA $ ',::J{){). {Jc') $ <../ ~ . 7/JtJ. ~
66 Copper wiring (As per Plans) 16,000 LF $ l../. ~r $ b 8 "w. 00
.
67 Furnish and install 2" schedule 40 PVC conduit to
include trenching (6" x 12" deep), backfill and </~,tJO(), 00
restoration 4,000 LF $ j,;).{)O $
68 Handholes 33 EA $ L/ OCJ .1)CJ $ '3 dOO, Dc)
.
69 Copper clad ground rods (5/8" dia x 10'L) 33 EA $ f.1J.~. 01} $ j l./- 8 ~-. DO
,
70 Panel & Meter Enclosure, including connection to 9 ;-:J (.,"'>0. [) [) $ 9; d. 00, DO
service point LS $
Subtotal-Electrical $ LftdJ 8/0,w
.
IV. North Miami Beach Water Main Installation
71 Mobilization, General Conditions (Only for items in
IV Installation of Water Main System) LS $ 1. bOo, 00 $ 1, Oct). 0 c)
72 Abandonment / Removal of Existing Water .:J. 5lJO. O()
System 1 LS $ .J, !,.{){). () C) $
73 Install 8" PVC Pipe C-900 2,560 LF $ ~ 1. IJO $ 9,/, '7.JD. Or)
74 Install 6" PVC Pipe C-900 420 LF $ 3.). DO $ 13, t;f./{).~O
75 Install 4" Polyethylene Casing Pipe 85 LF $ .;;1.1, 0 () $ Cl d.. Cj:J- ()O
I I
76 Install 2" Polyethylene Casing Pipe 770 LF $ I/' 00 $ 2, l/ 7(),DCJ
77 55 straps 10 EA $ '-IO~, 00 $ (j,OCO.OO
78 Install Fire Hydrants 6 EA $ -3; .:; t'O. {l (.) $ / '1; cJOO. 00
05/08-Addendum No. 5 00300-4 05-4893
Atlantic Isles Roadway and Utility Improvements
Bid
Item
Description
79 Install 6" Transitional Sleeve
80 Install 8" Gate Valves
81 Install 6" Gate Valves
82 Install 8" x 8" Tee
83 Install 8" x 900 Bend
84 Install 8" x 450 Bend
85 Install 8" x 22.50 Bend
86 Install 8" x 11.250 Bend
87 Install 8" x 6" Tee
88 Install 8" x 6" Reducer
89 Install 6" x 450 Bend
90 Install 6" x 22.50 Bend
91 Install 6" x 6"Tee
92 Install 6" Cap
93 Install 6" x 2" Tapped Cap
94 Install Corporation Stop Tap to 8" DIP w/Tapping
Saddle
95 Install 2" RSGV
96 Install Service Connection 1" w/PVC Casing
97 Install Service Connection 1" Double w/PVC
Casing
98 Install Service Connection 2" w/PVC Casing
99 Install Service Connection 2" Double w/PVC
Casing
Subtotal - North Miami Beach Water Main
Installation
V. Miscellaneous
100 Contingency
VI. FPL Undergrounding
101 Allowance Account
Estimated
Quantity Unit Unit Price Estimated Total
1 EA $ d{)~' 00 $ d-.6b .CO
6 EA $ I, ,~C>O.IJO $ Z c...J.Ct'} tJO
10 EA $ [jOtJ IJ() $ g. DClC> ,DO
2 EA $ .38 .~)-, () () $ 7 ;;0.00
4 EA $ ~&'~. ()() $ 3.~S,.J,tJO
14 EA $ -3 /.~ . ~O $ t./ 3b~. IJO
2 EA $ .-3/:) .00 $ b~ lj, tJ()
3 EA $ .~ I.;) . OCJ $ Q3b. ()D
9 EA $ 371.cJo $ ~..{. "393,(x)
3 EA $ ;),,(/3, 00 $ 7~ 9, ()()
1 EA $ c2 4). c)Q $ (;).. S:S-. CD
1 EA $ ~S-:s-, /)0 $ C) .5~--' Q::)
2 EA $ 3~tf. 00 $ ~ fl8.'Db
1 EA $ IOU. 00 $ /00. oc)
2 EA $ /Ot.J.OC) $ ~cJ. [i)
2 EA $ Lib!. 00 $ I, / ~~, Ou
2 EA $ . ~bf). 00 $ 7<:XJ. ~")
34 EA $ II/Ot.>. C)c) $ -3~ <lOt). 00
1 EA $ 113t)tJ.OO $ 1,3tJ{). Dc.)
6 EA $ ,:J,/Ot).t)t.J $ /~, t, ct:J. 00
10 EA $ <..:2,. dtV. oC $ r-:Jd, tJW. 00
$ .2 ~-c; 797. {)o
,
LS
$250,000.00
$250,000.00
LS
$500,000.00
$500.000.00
TOTAL BASE BID (Item I Thru VI) 1$ 3 ,>-ri.LJ?O~'J-
-rllf'ee JIll) 1!lJ..} hllt? lIuA./I1~~rj -;;~1t.1I1j.ue. IhdClS/JP!:J !'1?Alf'& t1t1/M R~ ~AJtJ nIP-lt.;;tli!
. / Written / e P;(./1:5.
(Contractor) (Date)
So u/II('-'/f(o("/?N &CI/VI'~/~/,uC {);,;1~I'f-C'Ic),et:;."Mc... 7/7/08
05/08-Addendum NO.5
00300-5
05-4893
BID SECURITY
Accompanying this Bid is a certified or cashier's check or a bid bond in the amount of $ 5% of
the bid made payable to the Owner which may be forfeited as liquidated damages if, in the
event this proposal is accepted, the undersigned fails to execute the Agreement and furnish and
pay for the required performance and payment bonds for the Owner within 10 days after
acceptance of the Bid; otherwise said certified or cashier's check or bid bond will be returned to
the undersigned.
The undersigned Bidder agrees to commence work within 10 days after the date of written
Notice to Proceed, and further agrees to substantially complete the work within 160 consecutive
calendar days after the date of written Notice to Proceed, subject to such extensions of time
allowed by the Conditions of the Contract.
The undersigned Bidder also agrees to complete the entire work within 170 days after the
Contract time commences to run.
The undersigned Bidder agrees that this Bid shall be good and may not be withdrawn for a
period of 60 days after the scheduled closing time for receiving bids.
The undersigned further agrees to forfeit to the Owner, as liquidated damages for each calendar
day elapsing between the date established as the date of final completion and the actual date of
final completion of the contract work, the amount of $2,000.00 per calendar day.
The Owner agrees, as a bonus for each calendar day of early completion before the date
established as the date of final completion and the actual date of final completion of the contract
work, the amount of $2,000.00 per calendar day. The bonus is limited to a maximum of
$60,000.00.
05/08
00300-6
05-4893
ADDENDA
Bidder acknowledges the receipt of Addendum No. IS
1. "/, 2~rfI.l9. 3H~ 4~~5 t/2(:;{-JY /?FI #- /
Dated this 77 day of~~ (/ 2#..tI;!?
~ (year)
*
~u7/1~4') i~/c/L Cf;.'61'IlJt:>f'l2l'.LC (JA/7;2AGji:'S I ~ C-
/ d o~7111.J LV Ii J/fh Jl "'c
I-J I' />. It; /J" ~} /L/J-!? Ill>
Contractor:
Address:
SEAL
*
FI" /210~)
3~C'/~
Attachments:
Subcontractor List
Bid Security
Trench Safety Act documentation
END OF DOCUMENT
05/08
00300-7
05-4893
DOCUMENT.00401
BID BOND
BIDDE~ame and A~
. . .LHJ%.l.l:BN crnI:AACJIRS, nc.
1LD54 twl ~ Ave .
HIAlEAH G\RJ:lN), FL TIll8
SURETY (Name and Address of Princioa/ Place of Business):
'" fWIDrnD F1RE lN3l.RAN:E CD. '
HARTWP.n H A7 A
J.ltiRll.rnri cr ('h 115
/
OWNER (Name and Address):
CITY OF SUNNY ISt;.ES BEACH
18070 Collins Avenue
Sunny Isles Beach. Fiorida 33160
BOND NUMBER: n/a
DATE: (Not later than Bid Due Date): 6/23/03
PENAL SUM: E1VE IfRCENT CF AKINI' OF BID
~
IN WITNESS WHEREOF, Surety and Bidder. intending tb be legally bound hereby, subject to the terms
. printed On the reverse side hereof, do each cause this Bid Bond to be duly executed on its behalf by its
authorized officer, agent, or representative. .
srnm=o
SURETY
By:
Note:
(1)" .
(2)
Above addresses are to be used for giving required nolice.
Any SingUlar reference to Bid4er. Surety, Owner or other party shall be
considered plural where applicable.
05/08 Final Version
J
00401-1 j
!
,
05-4893
1. Bidder and Surety, jointly and severally, bind
themselves, their heirs. executors, administrators,
wocessors and a~signs to pay to Owner upon default of
Bidder any difference between the total amount of Bidder's
bid and the total am'ount of the bid of the next lowest,
responsible and responsive bidder as determined by ~er
for the WorK required by the Contract DoctJments, provided
ttlla t: /
1.1. If there is no such next lowest: responsible and
responsive bJOcler, and Owner does not
abswdon the Project, then Bidder and Surety
shall pay to Owner the penal sum set forth on
_ ""the face of this Bond, and .
1.2. In no event shall Bidder's and Surety's obligation
hereunder exceed the penal 8lJm !let forth on
the face of this Bond.
2. Default of Bickler shall OOClJr upon the failure of Bidder
to deliver within the time required by the Bidding Documents
(or any extension thereof agreed to in writing by Owner) the
executed Agreement required by the Bidding Docunents
and any performance and payment bonds required by lhe
Bidding Documents and Contract Documents.
5. Surety waives notice of and any and all defenses
based on Qr arising out of any time extension to issue notice
of award apreed to in writing by Owner and Bidder, provided
that' the t~1 time for issuing notice of award including
exl.ensiOflSi shall not .in the aggregate exceed 120 days from
Bid Due Ditte without Surety's written consent:
i
6. No $uit or action shall be commenc&d under lhis Bond
prior to 3D calendar days after the notice of default, as
required in Paragraph 4 above, is received by Bidder and
Surety an~ in no case later ttaan one year after Bil Due
Date. .
7. AnY: suit Dr ,..-t."" under this Bond shall be
commenced omy In II. ~UUI' of competent jurisdiction located
in the state In which the project Is Iocaled.
8. Not!ces required hereunder snail be in writing and
sent to Bidder end Surety at their respective addresses
shown on.ithe face of this Bond. Such notices may be sent
by personal deiveIY, commercial courier or by United States
Registered or Certified Mail, return receipt requested,
postage pre-paid. and. shall be deemed to be effective upon
receifll by the ~rty concerned.
3.
This obligation shaW be null and void if:
3.1. Owner accepts Biddens bid and Bldder delivers
within the lime reQUired by the Bidding
Documents (or Bny extension thereof agreed to
in wriling by Owner) the executed Agreement
required by the Bidding Documents and any
performance and payment bonds requited by
the Bidding Documents and Contract
Documents, or
3.2. All bids are rejected by Owner, or
3.3.. ONner falls to issue a notice of award to Bidder
within the time specified m the Bidding
Documents (or any extension thereof agreed to
in writing by Bidder and, if applicable, consented
to by Surety when required by paragraph 5
henlof).
4. Payment under this Bond Witl be due and payabLe
upon defaun by Bidder and within 30 calendar days after
T'eOI!!lip.t by Bidder and within 30 calendar days a1ter receipt
by Bidder and Surety of written ROtice of default from 0Wne r,
which notice wiD be giVen wlh reasonable promptness,
identifying thls Bond and the Project and including &
statement of the amount due.
9. Su~ty shall cause to bEl attache<! to this Bond a
cur:rent and effective Power of Attorney evidencing the
authority of tl'Ie officer, agent or representative who el<ecuted
this Bond, on behalf of Surety to execute, seal and deliver
such Bond and bind the Surety thereby.
1 O. Th~ Bond Is Intended to conform to all applicable
. statutOI)' i'equirements. Any llpplicable requirement of any
appllcab~ statute that has been omitted from this Bond shall
be deemEid to be included herein as if set forth at length. If
any pro~ion of this Bood Conflicts with any applicable
provision pI this Bond conflicts wtth any appficable provision
of any apPlicable staMe, then the provir.ion of said statute
shall govern and the remainder of this Bond that is not In
conflict th~rewIh shall continue in full force and effect
11. The tenn "bid" as used herein includes a bid, offer or
proposal ~ applicable.
~~.
05/0'8 Final Version
i
,
I.
~
t
00401.2
05-4893
'POWER OF ATTORNEY
Direct Inquiries/Claims to:
THE HARTFORD
BOND, T-4
P.O. BOX 2103,690 ASYLUM AVENUE
HARTFORD, CONNECTICUT 06115
call: 888-266-3488 or fax: 860-757 -5835
Agency Code: 21-221533
KNOW ALL PERSONS BY THESE PRESENTS THAT:
[K::J Hartford Fire Insurance Company, a corporation duly organized under the laws of the State of Connecticut
[K::J Hartford Casualty Insurance Company, a corporation duly organized under the laws of the State ofIndiana
CK:J Hartford Accident and Indemnity Company, a corporation duly organized under the laws of the State of Connecticut
c=J Hartford Underwriters Insurance Company, a corporation duly organized under the laws of the State of Connecticut
c=J Twin City Fire Insurance Company, a corporation duly organized under the laws of the State of Indiana
c=J Hartford Insurance Company of Illinois, a corporation duly organized under the laws of the State of Illinois
c=J Hartford Insurance Company of the Midwest, a corporation duly organized under the laws of the State ofIndiana
c=J Hartford Insurance Company of the Southeast, a corporation duly organized under the laws of the State of Florida
having their home office in Hartford, Connecticut, (hereinafter collectively referred to as the "Companies") do hereby make, constitute and appoint,
up to the amount of unlimited:
Emesto Freyre, Fausto Alvarez, Ramon A. Rodriguez, Victor M. Pantin, Carl H. Moll, Carlos Lacasa,
William E. Beckham, Marc D. Jacobson, Michael L. Keeby, Mayra Rodriguez
of
Miami, FL
their true and lawful Attorney(s)-in-Fact, each in their separate capacity if more than one is named above, to sign its name as surety(ies) only as
-delineated -above-by-[8'I;-and-to-execute ,- seal- and- acknowledge any- and -all- bonds,- undertakings,- contracts_ and_ather_written _instruments _in, the_
nature thereof, on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and
executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law.
In Witness Whereof, and as authorized by a Resolution of the Board of Directors of the Companies on July 21, 2003 the Companies
have caused these presents to be signed by its Assistant Vice President and its corporate seals to be hereto affixed, duly attested by its Assistant
Secretary. Further, pursuant to Resolution of the Board of Directors of the Companies, the Companies hereby unambiguously affirm that they are
and will be bound by any mechanically applied signatures applied to this Power of Attorney.
1f2...",,,..~
6<1 ('4_~..
~; ,~ ~
;:-. - --
". O. r--~
l~~.! 91 ~/ i/
--""''';'- '~t~~.~..~~$
,,-...
f~O 0\. ~
'\ 1(("-,"',(".\,,\
\\.j '>
,,~ ~~~~.-
Paul A. Bergenholtz, Assistant Secretary
David T. Akers, Assistant Vice President
STATE OF CONNECTICUT}
55.
COUNTY OF HARTFORD
On this 4th day of August, 2004, before me personally came David T. Akers, to me known, who being by me duly sworn, did depose and
say: that he resides in the County of Hampden, Commonwealth of Massachusetts; that he is the Assistant Vice President of the Companies, the
corporations described in and which executed the above instrument; that he knows the seals of the said corporations; that the seals affixed to the
said instrument are such corporate seals; that they were so affixed by authority of the Boards of Directors of said corporations and that he signed
his name thereto by like authority.
Hartford
/)
^ ~)r- (/ /..-/
.AC.JC..4{1 C /.~.....
Scott E. Pascka
Notary Public
CERTIFICATE My Commission Expires October 31.2007
I, the undersigned, Assistant Vice President of the Companies, DO HEREBY CERTIFY that the above and foregoing is a true and correct
copy of the Power of Attorney executed by said Companies, which is still in full force effective as of June 23, 2008.
Signed and sealed at the City of Hartford.
&'i''<7:0..~
(#Bt:;....\
f; ,~ ~\
.:j:t . ~r
\~\t91~lE!
;. .....,:.~~...._.....~ ~~$
''''''''~~~;*
.~...~
: J' ......, -/flirl
~ II "eo'".t41fj''' ~ \ if \~Trc [,t~
:!~r' . 61;1 fa * ~
,,\ lQ1~iil \~ 19,9 '".'1
.................N "~ ~
. '."'~;)' .'tt~~
(i(j(U~t
Gary W. Stumper, Assistant Vice President
POA 2004
I
II
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
I
SWORN STATEMENT PURSUANT TO SECTION 287.133(3)(a),
FLORIDA STATUTES, ON PUBLIC ENTITY CRIMES
1.
~I,-L~ /~~
ntity]
by
for
whose business address is
12054 N.W. 98th Avenue. Hialeah ~~~
and (if applicable) its Federal Employer Identification Number (FEIN) is ~ ~Z.~~,
2.
(If the entity has no FEIN, include the Social Security Number of the individual signing this sworn
statement: .)
I understand that a "public entity crime" as defined in Paragraph 287.133(1 )(g), Florida Stafutes,
means a violation of any state or federal law by a person with respect to and directly related to
the transaction of business with any public entity or with an agency or political subdivision of any
other state or of the United States, including, but not limited to, any bid or contract for goods or
services to be provided to any public entity or an agency or political subdivision of any other
state or of the United States and involving antitrust, fraud, theft, bribery, collusion, racketeering,
conspiracy, or material misrepresentation.
3.
I understand that "convicted" or "conviction" as defined in Paragraph 287.133(1 )(b), Florida
Statues, means a finding of guilt or a conviction of a public entity crime, with or without an
adjudication of guilt, in any federal or state trial court of record relating to charges brought by
indictment or information after July 1, 1989, as a result of a jury verdict, nonjury trial, or entry of a
plea of guilty or nolo contendere.
I understand that an "affiliate" as defined in Paragraph 287.133(1 )(a), Florida Statutes, means:
4.
5.
1. A predecessor or successor of a person convicted of a public entity crime; or
2. An entity under the control of any natural person who is active in the management of the
entity and who has been convicted of a public entity crime. The term "affiliate" includes those
officers, directors, executives, partners, shareholders, employees, members, and agents who
are active in the management of an affiliate. The ownership by one person of shares
constituting a controlling interest in another person, or a pooling of equipment or income among
persons when not for fair market value under an arm's length agreement, shall be a prima facie
case that one person controls another person. A person who knowingly enters into a joint
venture with a person who has been convicted of a public entity crime in Florida during the
preceding 36 months shall be considered an affiliate.
I understand that a "person" as defined in Paragraph 287.133(1)(e), Florida Statutes, means any
natural person or entity organized under the laws of any state or of the United States with the
legal power to enter into a binding contract and which bids or applies to bid on contracts for the
provision of goods or services let by a public entity, or which otherwise transacts or applies to
transact business with a public entity. The term "person" includes those officers, dir~ctor~,
executives, partners, shareholders, employees, members, and agents who are active In
management of an entity.
05/08 Final Version
00402-1
05-4893
II
I
I
I
I
I
I
I
I
I
i
i
i
i
I
!i
Ii
i
I
6. Based on information and belief, the statement which I have marked below is true in relation to
the entity submitting this sworn statement. [Indicate which statement applies]
Neither the entity submitting this sworn statement, nor any of its officers, directors,
executives, partners, shareholders, employees, members, or agents who are active in the
management of the entity, nor any affiliate of the entity has been charged with and convicted of a
public entity crime subsequent to July 1, 1989.
The entity submitting this sworn statement, or one or more of its officers, directors,
executives, partners, shareholders, employees, members, or agents who are active in the
management of the entity, nor any affiliate of the entity has been charged with and convicted of a
public entity crime subsequent to July 1, 1989.
The entity submitting this swo'rn statement, or one or more of its officers, directors,
executives, partners, shareholders, employees, members, or agents who are active in the
management of the entity, nor any affiliate of the entity has been charged with and convicted of a
public entity crime subsequent to July 1, 1989. However, there has been a subsequent
proceeding before a Hearing Officer of the State of Florida, Division of Administrative Hearings
and the Final Order entered by the Hearing Officer of the State of Florida, Division of
Administrative Hearings and the Final Order entered by the Hearing Officer determined that it
was not in the public interest to place the entity submitting this sworn statement on the convicted
vendor list. [attach a copy of the final order]
Sworn to and subscribed before me this
Personally known
~
OR Produced identification
(Type of identification)
05/08 Final Version
00402-2
05-4893
I
!I
DOCUMENT 00403
I
TRENCH SAFETY ACT
(90-96, Laws of Florida)
I
I
i
i
i
Bidder acknowledges that included in the appropriate bid items of the proposal and in the Total
Bid Price are costs for complying with the Florida Trench Safety Act (90-96, Laws of Florida)
effective October 1, 1990. The bidder further identifies the costs of such compliance to be
summarized below:
-
Trench Safety Unit of Unit Unit Extended
Measure Measure (Quantity) Cost Cost
(Description) (LFSF)
A. ~t!~ ?I" J&l't:J /~" ~ ~~ tPRP. -'
B. ..4J'Rx.
C.
D.
Total $ g~ tfl,9&J. 1P
,
i
i
If applicable, the Contractor certifies that all trench excavation done within his control in excess
of five feet in depth shall be in accordance with the Florida Department of Transportation's
Special Provisions Article 125-1 and Subarticle 125-4.1 (TRENCH EXCAVATION SAFETY
SYSTEM AND SHORING, SPECIAL - TRENCH EXCAVATION).
i
Failure to complete the above may result in the bid being declared non-responsive.
I
Contractor agrees that the above safety compliances a~ ~d in his bid package
Signature of Bidding Co
I
I
i
END OF DOCUMENT
i
I
j
05/08 Final Version
00403-1
05-4893
III
III
III
III
III
III
III
III
III
III
III
III
III
III
III
III
III
III
II
DOCUMENT 00420
INFORMATION REQUIRED FROM BIDDERS
GENERAL INFORMATION
The Bidder shall furnish the following information. Failure to comply with this requirement may cause its
rejection. Additional sheets shall be attached as required.
1.
Contractor's Name/Address:
Southeastern engineering eo.~eoaa.lti&
llU:>4 N.W. ~UI ,",VtlIlI.lU, : ~ ~ ~- ~~
3.
Contractor's License:
Primary Classification:
~tP~~7~~U;
&/~/';'- ~ &v~~,
2.
Contractor's Telephone Number:
4.
Number of years as a Cont~tor in construction work of the type involved in this Contract:
~y
5.
~a titles of :;icers of :tractor's firm:
A-"v ~:t#VU-
~~
><e~/~ I
/
6. Name of person who inspected site or proposed work for your firm:
Date of Inspection:
lEd OOIningUII
Y4V.-./t!' Z-,
~t?~
Name:
7. What is the last project of this nature you have completed?
/e" ~ r.:l ;e.~O<:W<L<1Z u.-i r-
8. Have you ever failed to complete work awarded to you; if so, where and why?
/V'd
05/08 Final Version
00420-1
05-4893
I
i
I
Ii
i
II
I
I
9.
Name three individuals or corporations for which you have performed work and to which you refer:
~ y~~ rd ~r/>-<z~.re€-c::/" ~ Jz.,-
10.
List the following information concerning all contracts on hand as of the date of submission of this
proposal. (In case of co-venture, list the information for all co-ventures).
NAME
OF
PROJECT
CITY
TOTAL
CONTRACT
VALUE
CONTRACTED
DATE OF
COMPLETION
%
COMPLETION
TO DATE
/~~~~ /i::) ~~#C!S~ L-/..sr
(Continue list on inset sheet, if necessary)
11.
What equipment do you own that is available for the work?
4//
I
I
I
I
12. What equipment will you purchase for the proposed work?
/1/e;A/ cF
NOTE: Attach additional sheets if required.
I
I
i
If requested by the City, the Bidder shall furnish a notarized financial statement, references and other
information, sufficiently comprehensive to permit an appraisal of his current financial condition.
i
i
i
i
05/08 Final Version
00420-2
05-4893
II
I
Ii
iii
II
Ii
Ii
I
I
I
Ii
.
I'
.
.
.
.
,I-
i
LIST OF SUBCONTRACTORS
The Bidder SHALL list below the name and address of each Subcontractor who will perform work under this
Contract in excess of one-half percent of the total bid price, and shall also list the portion of the work which
will be done by such Subcontractor. After the opening of Proposals, changes or substitutions will be allowed
with written approval of the City of Sunny Isles Beach. Subcontractors must be properly licensed.
1.
2.
-
13u#r.;?;;2/~l.-
3.
4.
5.
6.
7.
8.
9.
10.
NOTE: Attach additional sheets if required.
05/08 Final Version
ubcontractor's Name/Address
~ r-
7PVr# ., $t4P7/ h
/ '
~(;"./~ l- ~#-Wc.e-.z::;;-
~~r#/" ~ .:z;c.
~/C?~; ~ n-,
;' ,
00420-3
05-4893
SECTION 00900
Addendum NO.1
to
Contract documents
CITY OF SUNNY ISLES BEACH
Atlantic Isles Roadway and Utility Improvements
CGA PROJECT NO. 05-4893
CITY BID NO. 08-06-01
To All Bidders:
Bidders for the above-referenced project shall take note of the following changes,
additions, deletions, clarifications, etc. to the Plans and Specifications, which in
accordance with the Contract Documents shall become a part of and have precedence
over anything shown or described otherwise.
IN THE CONTRACT DRAWINGS:
1. In the Plan Sheets please replace all sheets in their entirety.
2. Add North Miami Beach Plan Sheets 1 thru 9 to be part of Alternate NO.1 of the
Bid Schedule.
All other documents, specifications, drawings, terms and conditions remain the same.
\~
Bidders must acknowled~l{f~eipt of Addendum on Page 00300-6.
~~
04/08 Final Version
00900-1
05-4893
_::(:lII;.a~11;l,.iiiI;):_
..~I".l'III:.IRf!
;F.T.a'1i1alllOll. '1IIn;l:r''''I:II:I~.:II~letl~I:II:II:.I~U I:fillllll:..
~UN-II-2008 WED 11:36 AM CALVIN & GIORDANO
~~J~~~~.r""-Tr''']~:~:~~:I~:::.'...]:'_ .. ". '.' i .....:.,:. i~.~::'::.__'i': ..:.:. ....: .. . . .
~:. ~.:~rl~~t:~tj:~l ~.:$~OLc~~e~. ol~C;. ".
.. ... rh Fo'IILaud~r~.I~'~~c:tl. 1$00 F.llei OriYu, $uilf: 600, fort l~udordalu, fh:lTld~ 3331/)
'T Pholl~: 954.~21.77~1 '. Fax: ~S4,.921.6607 '. . ',:. _.. .
.....l"..........(].:... ';;~in\ii;i;ii'!Oii;~;'r5fiovrli3'se-Bi~cl:'s~ij;; ]'40,' We,t J>.1lf"(111~a~h. Florida ]J40~
rhon~: S61.PC4.61ul ' FilK: SC.l.'C.C4.63<iO' .
.._+...---~.........;, ..,..-!-........\...-,.-;.".. ....! .._..:...,.....~.., ... .
I 1 j ! ! '.' .
I I; i
.~...IM.._ .. .~."~...._..._,..."_..~.....,..._..... ... . ..,.~...........
I
I
I I
....r.-.....T....
FAX NO, 0
Facsimile
T.O:
Ed; Domjnguei
Southeastern Engineering
DATE:
June 11, 2008
.. ,...-.....---...".
, ;
, ,...~......-:.....F~ NO: . '(305)557-8568
. I
, 'FRO'1\:F.... . Joanne Maglietta
NO. PAGES
(lnchllllnc Cover):
2
R;E: Atlantic Isles Utility &
Roadway Improvements
Addendum No.2
cc:
File
PROJECT NO.:
05~4893
Hnrd copy follows by:
r, M'I
at
r FodEx
r Courier
W
No hard copy
r Urgent
r
r
P'
Please Reply
For Review
Please Comment
The following Addendum #2 is hereby issued via facsimile, Since this is an Addendum.
it is important to FAX BACK YOUR ACKNOWLEDGEMENT OF RECEIPT, which is
this cover page with one of the "RECEIVED" boxes checked.
Thank you,
RECEIVED? YES, Addendum #2 and cover sheet was received.
D NO, We only received this page.
P;\Praj"I.I2DOII05419J CIly OrS~nny '01.. D..,~. AII'n.le AVO ~ondwny nn4 Oroin.yc fmp"''''m.n,"\CO"C1rondtn..\~P~CSIJl... Ad~1I2-S'u.hchltcm.doo
,-
p, 01
Fr"'~-"T"'~ ;~-~D
R .~ ". -. ,.'.. ./ ';,._:.J ;.-
..... ." .,. ., .
lli Calvin, Giordano & Associates, Inc.
.. j:EXCEPTIONAL SOLUTIONS
.
JUN 1 8 Z008
O Fort Lauderdale Office - 1800 Eller Drive, Suite 600, Fort Lauderdale, Florida 33316
Phone: 9.54.921.7781 . Fax: 954.921.8807
D Palm Beach Office - 560 Village Blvd, Suite 340, West Palm Beach. Florida 33409
Phone: 561.684.6161 . Fax: 561.684.6360
BY:
Letter of Transmittal
TO:
Southeastern Engineering
12054 NW 98th Avenue
Hialeah Gardens, FL 33018
DATE:
June 16,2008
PROJECT NO.
05-4893
ATTN:
Ed Dominguez (305) 557-4226
RE:
Atlantic Isles Utility &
Roadway Improvements
o Under Separate Cover Via
[8J Attached
o Pickup
WE ARE SENDING YOU:
o Courier
[8J FedEx
o USPS
o Shop drawings
o Copy of Letter
o Prints
o Change Order
o Plans 0 Samples
[8J Other Addendum
o Specifications
DATE COPIES NO. DESCRIPTION
1 3 Addendum No.3
THESE ARE TRANSMITTED as checked below:
o For approval 0 Approved as submitted
[8J For your use 0 Approved as noted
o As requested 0 Returned for corrections
o For review and comment
o FOR BIDS DUE_
o Resubmit _ copies for approval
o Submit _ copies for distribution
o Return _ corrected prints.
o Other: INDICA TED BELOW
o PRINTS RETURNED AFTER LOANED TO US
REMARKS: Please Sign and fax bac
addendum.
this confirmation that you received this
YES, Addendum #3 and cover sheet was received.
COPY TO:
File
FROM: Joanne Maglietta
Assistant Contract Administrator
- ~ c..............
Xl!;
/
P:\Projects\2005\054893 City of Sunny Isles Beach - Atlantic Ave Roadway and Drainage Improvemems\Correspondence\SPECSILOT-JM-061608 #3-Southeastem.doc
If enclosures are not as noted, kindly notify us at once.
_::{:lII:II.'I:J:..~t
1JTiW"......IIIJ:.~D'.I.
or..:_1if.t..I']I. "11'11:I:ri\."lII:iI:I!.:iI![CllaU:fJ![CllII'I!I':'i~tII"I:1.
J~N-20-g008 FRI 02:18 PM CALVIN & GIORDANO
::::[...... j" '-1--'".''' i H~ .. . . :
I m1~ ' I , .
.j._... _, 11 Calvin. Giordano: g Associates, Inc.
I ~ ~Ex!Er;Tlo.NA'L S'O~UTIONS
... ~.. . I . .. .\.........'
, r+, ForllLoudcrdale OHlc~ . 1*00 Ella; Drive, Suire 600, FO(II.~ud"ld.lo, Florlua 33316
i L..!.J Ph()~e: 954.921.7761 . FaK: 954.921.8807 :
_: """ '~._.hj~OC~(hOffi~~.:5&O vlii~g~cii~d, S~i;ei1'O: wc,tlSlm Beach, Florida :1340')
L..J Phooe: 561.604.&161 . FpK: 5&1.61l4.lilGO:
" ,
~"'--'~""._""-"''''-i' .- .. ,_n' '1 . .'.'. ...._....f .
FAX NO, 0
Facsimile
-....!..............
TO:
.' .....
Ed'Domlnguez
.. .. .. . .
Southeastern Engineering
(305) 55.7-8568
June 20, 2008
DATE:
FAX'NO:
FROM:
Joanne Maglietta
NO. PAGES
(Including Cover):
2
RE:
Atlantic Isles Utility &
Roadway Improvements
Addendum No.4
cc:
Filo
PROJECT NO.:
05-4893
Hard copy follows by;
r:-: Mail
r FcldEX
r
Courier
P
No hard copy
r'
, Urgent
r
r
P'
Please Reply
For Review
Please Comment
The following Addendum #4 is hereby issued via facsimile. Since this is an Addendum,
it is important to FAX BACK YOUR ACKNOWLEDGEMENT OF RECEIPT, which is
this cover page with one of the "RECEIVEDll boxes checked.
Thank you,
RECEIVED? ~s, Addendum #4 nnd cover sheet was received.
o NO, We only received this page.
w;=~~~~
t6~ ~
r:\r(~J<ell\:!005\OI419J ell, ofSllnny hi.. O...h - AIllntl, Ave1\o,d...y and OrAlilfta.lmprov<m'nl.\C;'JfI'.lpon~.ne.ISPDeSll'u.' A,Idli-ol.5oUlh...lam,doc
P. 01/02
'~l-~.-':.t:--:-r---.lr---T-" ':
~r=~_. i "! .--..+--..~ '., + ...".,t ..j '\
..J.,. ~Calyin, ~iordanoi & Assodates; Inc:
__ L..m ~~~J_~J~~.l~~~~w. SOL U. T I '0 N S
.J.-,. ,~....;;;~2~~~~r:~~~:_~__lt~~.;~~~9.~t8~8~t~~~f'F~rt.~t~~:rdale, Florida 33316
I rb Pal~ Beachpffice r 560 Village Blyd, Suit~ 340, vyest Palm Beach, Florida 33409
~ 4J Phone: 561.684.6161 . Fax: 561.684.6360
,_..~~...,' ~_.~~,__~~._~~>_~_._, '>__N~~_-^-~._t_,____.+ 1 t
i 1 i I;
outlieasteffi:~En ill'e'er'
1'~~~~l
Letter of Transmittal
D~Unde{Separate Cover Via
[8J:Attached
D Pickup
WE ARE SENDING YOU:
D Courier
[8J FedEx
D USPS
D'Shop drawings
D Copy of Letter
D Prints
D Change Order
D Plans D Samples
[8J Other Addendum
D Specifications
1
5
Addendum No.5
THESE ARE TRANSMITTED as checked below:
D For approval D Approved as submitted
[8J For your use D Approved as noted
D As requested D Returned for corrections
D For review and comment
D FOR BIDS DUE_
D Resubmit _ copies for approval
D Submit _ copies for distribution
D Return _ corrected prints.
D Other: INDICATED BELOW
D PRINTS RETURNED AFTER LOANED TO US
REMARKS: Please Sign and fax back this confirmation that you received this
addendum.
D YES, Addendum #5 and cover sheet was received.
COPY TO:
File
FROM: Joanne Maglietta
Assistant Contract Administrator
Southeastern engineering eontractor&, IIrW;
If enc/osures are not as noted, kindly notify us at a"; i',11
-' .....,:-
rn .."....1111I:.1111'''':
~';_'iiF.t..I.I.. 'l1]1II:J:'~"'tI::il:ll.::iINct 1II::iI::iI:IINetlllll/lI:I'llllll:J.
JUL-03-2008 THU 01:19 PM CALVIN & GIORDANO
FAX NO. 0
p, 02/02
Response to RFI No.1
Atlantic Isles roadwllY and Utility Improvemepts
CITY OF SUNNY ISLES BEACH BID NO. 08.06-01
CGA PROJECT NO. 05-4893
July 3, 2008
Central Florida Equipment
I. Bid Item No. 21 "Pavement seam joint at bridge" Please contirm that the specification for
this "seam joint" can be obtained at EE FDOT Index 1200 Sheets 1 thru 3.
Response: For concrete to asphalt joints Ilse self-leveling silicone or /tot pOllr
sealant per FDOT Flexible Pavement Manual (latest edition).
American En~ineering
1. My asphalt subcontractor tells me that type Fe 12.7 does not exist and perhaps it should
be Fe 12.5. In any casel an FC or friction course mix is not normally placed 2 inches
thick. Usually a 1" or 1.25" structure asphalt would be used for the first lift and a .75" or
1" FC (fri.ction course) would be used for the second lift. A 2" of type FC (Friction
course) asphalt is probably not going to give the City the structural integrity or longevity
that they expect. Please confirm the asphalt section required for this road work.
Response: 2" FDOT Superpave Type SP12.5 Asphaltic Concrete.
2. If possible, could we have two separate line items to replace bid item #9-0reen Areas in
ROW, including fine grade and sod? The green area earthwork is relatively minor and it
will be problematic to determine a precise CY quantity in the field. This is one item that
can probably best be handled as a slump sum item. Then the sod should be handled as a
separate line item by the SF for the actual quantity of sod installed in place. Sod in place
is easily measured in the field and then the City pays only for sod actually installed and
the contractor doesn't have to carry a large contingency for possible sod requirements.
Response: No
3. The bid documents require that the contractor pay for penriits. Does this include the City
of Sunny Isles Beach fees or will these fees be waived'? If they are to be included, can
you include a City pennit fee schedule in the next addendum?
Response: Need to getfee sc/,edulefrom City's wehsite or Building Department.
4. The RTD uIlit is said to be included in the base bid but there is not specification on what
model or what program to be 'used for the RTU unit. A specification is needed.
Response: RTU is part of the lift station package designated as a lump sum hid.
RFl Reponsos
.. ,',,",eastern Engineering Contr'IIlCt.rn. m
~~'7k~B93
6!:!!~!!!l!f!1
Project Title:
Type of Construction:
Contract Amount:
Type of Contract:
Client:
Client's Rep.
Completion Date:
Project Title:
Type of Construction:
Contract Amount:
Type of Contract:
Client:
Client's Rep:
Completion Date:
Project Title:
Type of Construction:
Contract Amount:
Type of Contract:
Client:
Client's Rep.
Completion Date:
Project Title:
Type of Construction:
Contract Amount:
Type of Contract:
Client:
Client's Rep.
Completion Date:
Project Title:
Type of Construction:
Contract Amount:
Type of Contract;
Client:
Client's Rep.
Completion Date:
PROJECTS UNDER CONSTRUCTION
(fully bonded)
NW 62nd Street Roadway Improvements
Roadway & 54" dia. Force Main
$6,378,000.00
Unit Prices
Miami Dade County, Public Works Dept.
Mr. Antonio Cotarello, P.E., Div. Chief 305-3752116
June 2008
Belen Basin Pump Stations
Storm Sewer Pump Stations & Drainage
$6,391,000.00
Unit prices
Miami Dade County, Public Works Dept.
Mr. Antonio Cotarello, P.E., Div. Chief 305-3752116
Aug. 2008
Flagami I Fairlawn Pump Stations & Drainage Improvements
Storm Sewer Pump Stations, Roadway and Drainage
$6,714,352.00
Unit Prices
City of Miami
Mr. Ed Herald, Project Manager, 305-4161290
July 2008
Basin 21 Drainage Improvements & Pump Station
Storm Sewer Pump Stations, Paving & Drainage
$2,600,000.00
Unit Prices
Miami Dade County, Public Works Dept.
Mr. Antonio Cotarello, P.E., Div. Chief, 305-3752116
Aug. 2008
Hanford Blvd. Streetscape, Phases I, II, III, IV
Roadway ( streetscape)
$8,100,000.00 (all phases)
Unit Prices
City of North Miami Beach
Mr. Hiep Huynh, P.E., City Engineer, 305-9482925
May 2008 (last phase)
12054 NW. 98th Avenue, Hialeah Gardens, FL 33018 · Phone: (305) 557-4226 · Fax: (305) 557-8568
Projects Under Construction continue:
Project Title:
Type of Construction:
Contract Amount:
Type of Contract:
Client:
Client's Rep.
Completion Date:
Projet Title:
Type of Construction:
Contract Amount:
Type of Contract:
Client:
Client's Rep.
Completion Date:
Project Title:
Type of Construction:
Contract Amount:
Type of Contract:
Client:
Client's Rep.
Completion Date;
Canal 13 Control Structure
72"dia. Culverts
$1,037,046.00
Lump Sum
South Broward Drainage District
Mr. Leo Schwartzberg, P.E., Director, 954-6803337
July 2008
Central Island Drainage & Street Improvements
Roadway
$3,635,852.00
Unit Prices
City of Sunny Isles Beach
Shaun Sharon Gelvez, Assist. City Engineer, 305-7921773
June 2009
Buena Vista Phase II Paving & Drainag
Roadway
$1,775,789.00
Job Order Contract
City of Miami
Mr. ala A. Aluko, Director, Capital Improvements, 305-4161280
June 2008
12054 NW. 98th Avenue, Hialeah Gardens, FL 33018 · Phone: (305) 557-4226 · Fax: (305) 557-8568
Project Title:
Contract Amount;
Client:
Client's Rep.
Completion Date:
Project Title:
Contract Amount
Client:
Client's Rep.
Project Title:
Contract Amount:
Client:
Client's Rep.
Completion Date:
Project Title:
Contract Amount:
Client:
Client's Rep.
Completion Date:
Project Title:
Contract Amount:
Client:
Client's Rep.
Project Title:
Contract Amount:
Client:
Client's Rep.
Completion Date:
Project Title:
Contract Amont:
Client:
PROJECTS COMPLETED (LAST 5 YEARS)
(fully bonded)
Buena Vista Phase I, Paving & Drainage
$1,010,111.00
City of Miami
Mr. OlaA. Aluko, Director, Capital Improvements,305-4161280
Dec. 2007
NE 4th Street Streetscape
$1,007,000.00
City of Miami
Mr. Ola A. Aluko, Director, Capital Improvements, 305-4161280
Arch Creek Pump Stations & Drainage Improvements
$4,869,000.00
Miami Dade County, Public Works Dept.
Mr. Pedro Marzan, P .E., Project Manager, 305-2819062
Dec. 2005
Corona del Mar Roadway Improvements
$1,319,830.00
City of North Miami Beach
Mr. Hiep Huynh, P.E., City Engineer, 305-9482925
Feb. 2005
NW 79th Ave Roadway Improvements
$749,244.00
City of Hialeah Gardens
Mr. Jose Lopez, Public Works Director, 305-8233737
Ponce de Leon Blvd. Median Improvements
$1,800.374.00
City of Coral Gables, Public Works Dept.
Mr. Alberto Delgado, P.E., Director, 305-4605001
June 2006
20 inch Transmission Main at Strand Ave Bridge
$342,000.00
City of North Miami Beach
12054 NW. 98th Avenue, Hialeah Gardens, FL 33018 · Phone: (305) 557-4226 . Fax: (305) 557-8568
Client's Rep.
Completion Date:
Project Title:
Contract Amount:
Client:
Client's Rep.
Completion Date:
Project Title:
Contract Amount:
Client:
Client's Rep:
Completion Date:
Project Title:
Contract Amount:
Client:
Client's Rep.
Completion Date:
Project Title:
Contract Amount:
Client:
Client's Rep:
Completion Date:
Project Title:
Contract Amount:
Client:
Client's Rep.
Completion Date:
Project Title:
Contract Amount:
Client:
Client's Rep.
Completion Date;
Project Title:
Contract Amount:
Client:
Client's Rep.
Completion Date:
Mr. Hiep Huynh, P.E., City Engineer, 305-9482925
May 2005
Paving & Drainage County Wide (FEMA)
$8,000,000.00
DERM, Miami Dade County
Mr. Eduardo Vega, P.E., Assist. Director, 786-5528571
Jan. 2005
S-718, 8" Water Main Installation
$643,000.00
Miami Dade Water & Sewer
Mr. Nelson Cespedes, Project Manager,305-6070799
March 2006
54" dia. Force Main, Microtunnel Installation at NW 62nd Street
$1,995,925.00
Miami Dade Water & Sewer
Mr. Nelson Cespedes, Project Manager, 305-6070799
Feb. 2008
24",36",42", 48'dia. Water Mains Installation, S-746A & S746B
$2,657,000.00
Miami Dade Water & Sewer
Mr. Humberto Codispoti, P.E., Assist. Director, 305-7900235
March 2005
S-700A Repairs & Installation Of Pump Stations (Term Contract)
$6,300,000.00
Miami Dade Water & Sewer
Alma Santiago, P.E., Manager, Contracts Section, 786-5528550
Aug. 2003
S-718-4, Installation of Force Mains & Water Mains
$11,000,000.00
Miami Dade Water & Sewer
Alma Santiago, P.E., Manager, Contracts Section, 786-5528550
Aug. 2003
NW II Oth Street Improvements
$2,840,000.00
Miami Dade County Public Works Dept.
Mr. Antonio Cotarello, P.E. Div. Chief, 305-3752116
Aug. 2004
12054 NW. 98th Avenue, Hialeah Gardens, FL 33018 · Phone: (305) 557-4226 · Fax: (305) 557-8568
. .
Project Title:
Contract Amount:
Client:
Client's Rep.
Completion Date:
Project Title:
Contract Amount:
Client:
Client's Rep.
Completion Date:
Project Title:
Contract Amount:
Client:
Client's Rep.
Completion Date:
NE 6th Ave Improvements
$3,458,000.00
City of Pompano Beach
Mr. Randall Fowler, P.E., City Engineer, 954-7864144
Aug. 2004
Northside Utilities & Drainage
$1,735,727.00
Miami Dade County Aviation Dept.
Mr Steve Rush, Project Manager, 305-8760754
Dec. 2003
Country Club Drive Improvements
$1,670,000.00
City of A ventura
Mr. Tony Tomei, 305-4668923
Jan. 2004
12054 N.W. 98th Avenue, Hialeah Gardens, FL 33018 · Phone: (305) 557-4226 · Fax: (305) 557-8568