Loading...
HomeMy WebLinkAboutSiltek #1181' DRIVE ACTIVE PARK RECEM 10, 20055 SECTION 00300 JUN 0 9 2005 0 0 -.0 A�M BID FORM CITY OF SUNNY ISLES BEACH OFFICE OF THE CITY CLERK Bid of: For all Site /Civil Work other than Unit Price Work, a Lump Sum of: .v/rs� -E 7h�o/r� rrfc ($ A4,611XL/ PIOXOMPWS AY D 41P/7-5 figures For all Unit Price Site /Civil Work, a Total Su Exhibit A ) of- ($ 7 �6 ,4014q7Y— °r SITS figures For all Lump Sum Architectural Work, a Total Sum (E bit B) of: Tt v4NY`1-5044 / Thb as srxrY -7 eVZ44oies or ($.5 027, /63• A10 e,- , 7-5 (use words) figures Ten fJr�i�o,�Pe,� � (10% Contingency pS 10%f lab � AVJW oe h&i 7Y—odE 8944M.0 A-AI,o ($ ,ok/ ,�-�rds) figures TOTAL BASE BID (Lump sum Unit rites, ad contingency items) .� -Y/l�l -lrJ /LL /f�/ 6►N� �.510 �F7F—i'Y %JyiDV��t�LD — f,/ri�/dt� 7�E pG�l,MGS ($ 6j5';41--5 (use words) figur Contractor Address Contact Person: to furnish all materials, equipment and labor and to perform all work in accordance with the Contract Documents for construction of: 181ST DRIVE ACTIVE PARK, 18115 NORTH BAY ROAD; located in CITY OF SUNNY ISLES BEACH, FLORIDA 33160. To: CITY OF SUNNY ISLES BEACH 18070 Collins Avenue Sunny Isles Beach, Florida 33160 The undersigned Bidder has carefully examined the Bidding Documents and the site of the proposed work and is familiar with the nature and extent of the work and any local conditions that may in any manner affect the work to be done. BID FORM 00300 -1 161 a' DRIVE ACTIVE PARK APRIL 10, 2005 The undersigned Bidder agrees to do all the work and furnish all materials called for by the Bidding Documents, in the manner prescribed therein and to the standards of quality and performance established by the Engineer for the unit price amounts stated in the spaces herein provided, for each of the items or combination of items stipulated. Unit price line items shall include cost of implementing all applicable safety requirements. Bidder acknowledges that estimated quantities scheduled are approximated for the sole purpose of obtaining comparative bids for determination of the lowest responsible bidder and actual quantities required may increase or decrease. Bidder further agrees that payments will be made on the basis of actual quantities placed and accepted in the construction. BID SECURITY Accompanying this Bid is a certified or cashier's check or a bid bond in the amount of $ 5% (not less than 5% of the bid) made payable to the Owner which may be forfeited as liquidated damages if, in the event this proposal is accepted, the undersigned fails to execute the Agreement and furnish and pay for the required performance and payment bonds for the Owner within 10 days after acceptance of the Bid; otherwise said certified or cashier's check or bid bond will be returned to the undersigned. The undersigned Bidder agrees to commence work within 10 days after the date of written Notice to Proceed, and further agrees to substantially complete the work within the time indicated as follows: 1. Architectural building elements, i.e. Recreation Center and Gymnasium work within 365 consecutive calendar days after the date of written Notice to Proceed, subject to such extensions of time allowed by the Conditions of the Contract. 2. Project site elements, i.e. remaining site work within 432 consecutive calendar days after the date of written Notice to Proceed, subject to such extensions of time allowed by the Conditions of the Contract. The undersigned Bidder also agrees to complete final work within 463 calendar days after the date of written Notice to Proceed. The undersigned Bidder agrees that this Bid shall be good and may not be withdrawn for a period of 90 days after the scheduled closing time for receiving bids. The undersigned agrees to forfeit to the Owner, as liquidated damages for each calendar day elapsing between each date established above as the date of substantial completion and the actual date of such substantial completion of the contract work, the amount of $1500.00 per calendar day. BID FORM 00300 -2 181$' DRIVE ACTIVE PARK APRIL 10, 2005 The undersigned further agrees to forfeit to the Owner, as liquidated damages for each calendar day elapsing between the date established above as the date of final completion and the actual date of final completion of the contract work, the amount of $1,000.00 per calendar day. ADDENDA Bidder acknowledges the receipt of Addendum No.'s 1. o/, 2. 4 *r, 3. Z Ri"; 4. -:� 3. Dated this _t_ day of JU E ZcA . (month) (year) Contractor: v/G ��c) P /-*� - Address: _7:K SEAL z-r 7- 6b;!-7 Attachments: 00310 - Bid Form — Exhibit A 00320 - Bid Form — Exhibit B 00401 - Bid Bond 00402 - Form PUR 7068 (Rev. 06/11/92) 00403 - Trench Safety Act Document 00420 - Information Required from Bidders END OF DOCUMENT BID FORM 00300 -3 1818i DRIVE ACTIVE PARK THIS PAGE LEFT INTENTIONALLY BLANK. APRIL 10, 2005 BID FORM 00300 -4 181sT DRIVE ACTIVE PARK 181ST DRIVE ACTIVE PARK EXHIBIT "A" UNIT PRICE SITE /CIVIL BID SCHEDULE Project Bid # 05 -04 -01 ADD. JUNE 6, 2005 Item Quantity Unit Unit Price Cost SITE 6' HT. PICKET FENCE 350 L. F. $ 70,5 6' HT. CURVE WALL PICKET FENCE 70 L. F. $ S,00 PICKET FENCE COLUMN 2 EA. $ �c- vp 9.5' WIDE DBL. CURVE PICKET GATE 3 EA. $ �J /(�, 4�' 5.5' WIDE DOUBLE PICKET GATE 2 EA. $ iZ ti' .L7 SITE FURNISHINGS SUB-TOTAL TRASH RECEPTACLES (SITE) 8 EA. $ 6 FT. BENCH W /BACK 13 EA. $ 6 FT. BENCH W/O BACK 3 EA. $ 4 FT. PICNIC TABLE 5 EA. $ BICYCLE RACK 1 EA. $ WALL MOUNTED FLAG POLE (LVW20) 2 EA. $ 16 SURFACE MOUNT FLAG POLE (EC -30) 1 EA. $ HAYLARD COVER (HC -6) 3 EA. $ CLEAT BOX (CBC -412) 3 EA. $ WATER FOUNTAIN (M43 -2) 2 EA. $ 48" DIAMETER BRONZE SEAL INSET 1 EA. $ SITE LIGHTING SUB -TOTAL PEDESTRIAN LIGHTING W /RECEPTACLES 17 EA. $ LANDSCAPE UP LIGHTING 32 EA. $ LANDSCAPE SPOT LIGHTING 9 EA. $ SUB-TOTAL SOD ST. AUGUSTINE 'FLORATAM' $ $ $ !2� $ $ 3�s, , $ f,;7 s 5 7, $ $ Z5, n, 11450 S.F. $ 0, -e $ Z - 00 SUB -TOTAL $ CON -r. ,dam / r� � �, xtfr 76' S BID FORM - EXHIBIT A 00310 -1 181" DRIVE ACTIVE PARK ADD. JUNE 6, 2005 181ST DRIVE ACTIVE PARK EXHIBIT "A" - UNIT PRICE SITE /CIVIL BID SCHEDULE Proiect Bid # 05 -04 -01 TREE REMOVAL /RELOCATION REMOVAL 48" STRANGLER FIG 36" STRANGLER FIG 24" STRANGLER FIG ARECA PALMS REMOVAL 4" STRANGLER FIG 12" SABAL PALM RELOCATION (OFF -SITE) 26" SABAL PALM 8" DATE PALM 8" ROYAL PALM Item Quantity Unit Unit Price Cost 2 EA. $ /SQL `c' $ c,a 1 EA. $ . ✓:, $ 3 EA. $ i2f�i '� $ 9 EA. $ r $ Q �� 1��� 1 EA. $ , -�' $ 1 EA. $ /fJ ©. " ` $ 1 EA. $ $ 1 EA. To $ r 4 EA. $ bGi� `'`' $ 14 SUB -TOTAL $ 2 " LANDSCAPE Unit price shall include but is not limited to the following: plant material, installation, staking and guying, mulch, fertilizers, and planting soil. TREES & PALMS 8' GW. COCONUT PALM 15 EA. $ °`' $ 12' GW. COCONUT PALM 3 EA. $ Z 3 011 $ 12' HT. GREEN BUTTONWOOD UHT. 14 EA. $ Zz�S r� $ LIGUSTRUM 13 EA. $ Z& �e $ 15' GW. DATE PALM' MEDJOOL' 14 EA. $ L?l��" $ 12' HT. ALEXANDER PALM (SINGLE) MATCHED 3 EA. $ Z193- CIO $ 12' HT. ALEXANDER PALM (DOUBLE) 5 EA. $ $ 'r 12', 16', 22' ALEXANDER PALM (TRIPLE) 5' -6' PYGMY DATE PALM 12 EA. $ Iv $ /� < 8' HT. SCREW PINE 3 EA. $ 1 EA. I,, $ . 16' HT. SOUTHERN LIVE OAK 8' GW. ROYAL PALM UHT. DESERT CASSIA 4 EA. $ ;y7� $ 70 14' -16' CABBAGE PALM 6' O.A.H. FLORIDA THATCH 9 EA. $ PALM 4 EA. $ $ t BID FORM - EXHIBIT A 00310 -2 181ST DRIVE ACTIVE PARK APRIL 10, 2005 Item Quantity Unit Unit Price Cost SHRUBS & GROUNDCOVERS (SIZES PER PLAN) CONT. Unit price shall include but is not limited to the following; plant material, Installation, staking and guying, mulch, fertilizers, and planting soil. BOUGAINVILLEA 15 EA. $ `�� $ A 2�D. TREE CRINUM 69 EA. $ bZ, °t' $ 4.Z °7�, _`g DWARF POWDERPUFF 'NANA' 210 EA. $ $ REDTIP COCOPLUM 166 EA. $ /-j,' $ GREEN ISLAND FICUS 775 EA. $ %�?, "e $ T 725i9g YELLOW IXORA 64 EA. $ /�; �' `' $ ,,2; WAX JASMINE 84 EA. $ � 0 $ EVERGREEN GIANT LIRIOPE 932 EA. $-,i' $ PENTAS 200 EA. $ PHILODENDRON 38 EA. $ f� �46, " XANADU PHILODENDRON 60 EA. $ 77, $ TRINETTE SCHEFFLERA 19 EA. $�iov $ 7— d•'Z�'" DWARF FAKAHATCHEE GRASS 586 EA. $ ,, $,�g� WALKING IRIS 211 EA. $ CARDBOARD PLANT 22 EA. $�(J, $ SUB -TOTAL $ IRRIGATION BACKFLOW PREVENTER 1 EA. $ ;7- von, r.s 2" REMOTE CONTROL VALVE 8 EA. $ $ CONTROLLER 1 EA. $ $ SPRAY HEAD 340 EA. $ i'° $ BUBBLER HEAD 3 EA. $ $ ROTOR HEAD 21 EA. $ Zia -1r' $, QUICK COUPLER 1 EA. $ Z_'�O. ``� $ 3" GATE VALVE 3 EA. $ 04w "" $ 3" MAINLINE 1050 L.F. $ Zo. ' $ :21,E7c`sY��• SUB -TOTAL $$ SUBTOTAL SITE ITEMS $ 3/��0, -/7 el, BID FORM - EXHIBIT A 00310 -3 181sT DRIVE ACTIVE PARK APRIL 10, 2005 rurnvmrnn= SCOREBOARD BASEBALL 1 EA. $ 25' SCOREBOARD POLES 2 EA. $ :i7 " 3 ROW BLEACHER WITH H.C. 1 EA. $ ez m 3 ROW BLEACHER 1 EA. $ SCORE TABLE 1 EA. $ , n' BLEACHER SHADE STRUCTURE 2 EA. $ TRASH RECEPTACLE 2 EA. $ WATER FOUNTAIN 1 EA. $ BASEBALL BASE 3 EA. $ , HOME PLATE 1 EA. $ PITCHERS RUBBER 1 EA. $ lz •'� BASEBALL FENCES & GATES 30' HT. BACKSTOP FENCE 8' HT. CHAINLINK FENCE AT DUGOUT 5' HT. CHAINLINK FENCE AT DUGOUT 15' HT. CHAINLINK FENCE CHAINLINK DOUBLE GATE (15'X15') CHAINLINK GATE AT DUGOUT (3'X8') 20'- 4" O.D. FOUL POLE (YELLOW) HOMERUN LOWER MID RAIL POWDER COATED (YELLOW) DUGOUT DUGOUT ROOF STRUCTURE 6' DUGOUT PLAYERS BENCH r !r $ 2, /�.c� $ $ Z , -7 %; $ s 3722, 2 EA. $ .xA $ Z� SUB - TOTAL/ CNT BID FORM - EXHIBIT A 00310-4 SUB-TOTAL 90 L.F. $ s 100 L.F. $ 60 L.F. $ 610 L.F. $ 2:7/, cam:) 1 EA. $ z77-5 4 EA. $ 2 EA. $ 315 L.F. $ • ; a� SUB-TOTAL r !r $ 2, /�.c� $ $ Z , -7 %; $ s 3722, 2 EA. $ .xA $ Z� SUB - TOTAL/ CNT BID FORM - EXHIBIT A 00310-4 181ST DRIVE ACTIVE PARK APRIL 10, 2005 Item Quantity Unit Unit Price $ 1 4 , Cost FIELD SURFACES 6" TOPSOIL FOR BERMUDA 514 C.Y. $ 4e,75- $ BERMUDA ' TIFWAY' 27720 S.F. $ y $ 12" SAND SUBGRADE FOR TURF /CLAY 1600 TN. $j,�� $ >, ='•' INFIELD CLAY 6" DEPTH 100 TN. $ .k' $ 4 yG&V, INFIELD CLAY ADD MIXTURE 24 TN. $ $ Z S) WARNING TRACK CLAY 3" DEPTH 400 TN. $ U ono $ 1 4 , WARNING TRACK ULTIMATE II MIX. 48 TN. $ $ FINE GRADE SAND /CLAY 41180 S.F. $ $ y SUB-TOTAL $ Xz! r J� FIELD LIGHTING LIGHTING (POLES / CABINET / FIXTURE) 1 LS $ $ LIGHTING (LABOR / CONDUIT) 1 LS $ $ LIGHTING CONTROL LINK 1 EA $ $ LIGHTING 10 WARRANTY 1 EA $ $ SUB -TOTAL $ j '�, Q, SUBTOTAL BASEBALL FIELD ITEMS $ -el, z J� PLAYGROUND AREA PLAYBOOSTER SYSTEM 1 EA. $ W 7ZI, a' $ SEAT WALL CONSTRUCTION W /PRECAST 135 L.F. $ Z23, $ ACCENT POLES WBANNERS 6 EA. $ $ '- WATER VALVE HAND HOLE BOXES 2 EA. $ $ 12" PRECAST CUSTOM COLUMN ACCENTS 12 EA. $ $ SAF DEK SAFETY SURFACE 2000 S.F. $ $ zF, Opp, °y 4" SLAB ON GRADE (SAFETY SURFACE) 2000 S.F. $ Z, ?a $ 24" CONCRETE BANDING 135 L.F. $ $ 3' DIA. ARTISTIC BOLLARDS 6 EA. $ '7 *), r ` $ •�- ,'` SU13 -TOTAL $ SUBTOTAL PLAYGROUND AREA ITEMS BID FORM - EXHIBIT A 00310 -5 181ST DRIVE ACTIVE PARK APRIL 10, 2005 WATER SYSTEM DUCTILE IRON PIPE - 4" WATER MAIN 300 LF $ $ DUCTILE IRON PIPE - 6" WATER MAIN 20 LF $ L��j, �� $ raj DUCTILE IRON PIPE - 8" WATER MAIN 130 LF $ $ , •'i� FIRE HYDRANT ASSEMBLY 1 EA $ `' $, =� DIP 4" x 4" TEE 0.034 Ton $ X06», " $i •'�� DIP 8" x 6" TEE 0.0875 Ton $ ` 49ev, �� $ —� -04-j' DIP 8" x 4" TEE 0.0785 Ton $ $ -40 DIP 8" x 6" REDUCER 0.047 Ton $ $�� DIP 6" x 6" TAPPING SLEEVE AND VALVE 1 EA $ $ >, •�' DIP 4" PLUG 0.007 Ton $ 4,0a, '"`" $ DIP 8" PLUG 0.0225 Ton $ k�i $ DIP 4" 90' BEND 0.112 Ton $ (upe;r, - $ DIP 6" 45' BEND 0.0385 Ton $ ' ` $ DIP - 4" GATE VALVE AND BOX 3 EA $ 10cV, v $ e r, o), DIP - 6" GATE VALVE AND BOX 2 EA $ j0011, $ qCqrp, u3 DOUBLE DETECTOR CHECK VALVE ASSEMBLY - FIRE SERVICE 1 EA $ -V $ REDUCED PRESSURE BACK FLOW PREVENTOR - WATER SERVICE 1 EA $ , -e' $ PRESSURE VACUUM BREAKER - IRRIGATION SERVICE 1 EA $ la Ir $ 1 112" COPPER TUBING 205 LF $ , " $ SAMPLE POINT 2 EA $ au $� r PLUG WITH 2" BLOWOFF 1 EA $ a9 $ REMOVE AND DISPOSE OF EXISTING PIPE 400 LF $7, ° ' $ SUB -TOTAL $ SEWER SYSTEM 4" PVC SERVICE 65 L.F. $ a _ CLEAN -OUT 2 EA. $ P, "I' $ ,, �j , • �� CONNECT TO EXIST. SEWER LINE 2 EA. $ - yJ, ` ' $ SUB -TOTAL $ ;?J ;pp CON . BID FORM - EXHIBIT A 00310 -6 181 ST DRIVE ACTIVE PARK APRIL 10, 2005 Item Quantity Unit Unit Price Cost PAVING PARKING 3/4" ASPHALT (First Lift) 650 S.Y. $ 4.6- $ ; 7, 3/4" ASPHALT (Second Lift) 650 S.Y. $ $ r 8" LIMEROCK BASE 715 S.Y. $ `„ $ p 12" SUBGRADE 765 S.Y. 777T__57 $ G C7 TYPE "D" CURB 1000 L.F. $ 15it3y' $ 1300 S.F. SUB -TOTAL $ SIDEWALKS 12" COMPACTED SUBBASE (SIDEWALK) 921 S Y $ {' $ GREY CONC. (BRM W/TROWEL EDGE) 650 S.Y. $ $ 12" COMPACTED SUBBASE (SIDEWALK) 700 S.Y. $ $ GREY CONC. AT DUGOUT (BRM W/TROWEL EDGE) 75 S.Y. $ $ 12" COMPACTED AT DUGOUT SUBBASE 80 S.Y. $ ?, $�. -yv SPECIALTY SIDEWALKS COLOR CONC. (LT. EARTHTONE.- FIELD - ROCKSALT) 6100 S.F. $ '67, °'k'' COLOR CONC. (LT. EARTHTONE - BAND - SMOOTH) 1400 S.F. $ _�-, cx—' COLOR CONC. (BLUE - BAND - SMOOTH) 430 S.F. $ _5-1 =;' COLOR CONC. (LT. BLUE - BAND - SMOOTH) 325 S.F. $, m,-' COLOR CONC. (LT. BLUE - FIELD - ROCKSALT) 30 S.F. aV COLOR CONC. (LT. EARTHTONE - PAVERBAND - SMOOTH) 345 S.F. Ok, 8 "X8" CLAY BRICK PAVERS 1300 S.F. ADA - CLAY BRICK PAVERS 450 S.F. DRAINAGE SUB -TOTAL 6" PVC PIPE 250 LF $'> 10" PERFORATED UNDERDRAIN PIPE 1400 LF $ }' 18" SOLID HDPE 385 LF 15" SOLID HDPE 355 LF 12" DRAIN BASIN 16 EA $ f �✓'�' 18" DRAIN BASIN 16 EA $ J_5-a�� ` DRAINAGE WELL 1 EA $ DRAINAGE STRUCTURE 12'x 10'x 7' 1 EA $ SUB -TOTAL BID FORM - EXHIBIT A $�7 , 7_,m. -5a $ Z37,. y� CONT. 00314 -7 181sT DRIVE ACTIVE PARK APRIL 10, 2005 MISCELLANEOUS ANEOUS MOBILIZATION MAINTENANCE OF TRAFFIC SUB -TOTAL L.S. $ a-t2, ' $ 567 ,,Ooo., L.S. $ :t $ -9 r, SUB -TOTAL $ �, f.✓'!.r%L�.' SUBTOTAL SITE ITEMS SUBTOTAL BASEBALL FIELD ITEMS SUBTOTAL PLAYGROUND ITEMS SUBTOTAL SITE ENGINEERING ITEMS '(Provide Total on Bid Form) $ $ $ E I /,, 8Z, BID FORM - EXHIBIT A 00310 -8 Item Quantity Unit Unit Price Cost SIGNING & MARKING R7 -1 SIGNS 2 EA $ FTP -26 SIGNS 4 EA $ $ 6" WHITE SOLID LINE 850 L.F. $ $ 6" BLUE SOLID LINE 185 L.F, $ $ MISCELLANEOUS ANEOUS MOBILIZATION MAINTENANCE OF TRAFFIC SUB -TOTAL L.S. $ a-t2, ' $ 567 ,,Ooo., L.S. $ :t $ -9 r, SUB -TOTAL $ �, f.✓'!.r%L�.' SUBTOTAL SITE ITEMS SUBTOTAL BASEBALL FIELD ITEMS SUBTOTAL PLAYGROUND ITEMS SUBTOTAL SITE ENGINEERING ITEMS '(Provide Total on Bid Form) $ $ $ E I /,, 8Z, BID FORM - EXHIBIT A 00310 -8 181 ST DRIVE ACTIVE PARK REV. APRIL 28, 2005 181ST DRIVE ACTIVE PARK EXHIBIT "B" - LUMP SUM ARCHITECTURAL WORK BID SCHEDULE Project Bid #05 -04 -01 Furnish all materials, equipment and labor and to perform all work in accordance with the Contract Documents for construction of the associated items below. UNIT PRICES Auger Cast -In -Place Piling added to or subtracted from Base Bid volume in accordance with Specification Sections 01270 and 02372 and Structural Drawings. GG77 �° 1 Cubic Yard $ zC/�. AOzf/7�'7)- RECREATION CENTER All Recreation Center work 1 L.S. $ Metal Lockers (Section 10505) 1 L.S. $ g, � Gymnasium Equipment (Section 11490) 1 L.S. $ 7' Telescoping Bleachers (Section 12660) 1 L.S. $ ` All remaining Gymnasium work 1 L.S. $T *ARCHITECTURAL WORK TOTAL: $ —, 5 — cZ 7 "(Provide I otal on bid Form) BID FORM - EXHIBIT B 00320-1 05/19/2005 15:23 FAX 3542171728 SILTEK.GROUP.INC. d 003/004 18101 ACTIVE PARK DOCUMENT 00401 BID BOND APRIL 10, 2006 1;i5yislon. IMF M. all-I RID BID DUE DATE, June 9, 2005 PROJECT (Brief Description Including Location): 181st DRIVE ACTIVE PARK [BONA BOND NUMBER: N/A DATE: (Not later than Bid Due Date): June 9, 2005 PENAL SUM: Five Percent of Amount Bid IN WITNESS WHEREOF, Surety and Bidder, intending to be legally bound hereby, subject to the terms printed on the reverse side hereof, do each cause this Bid Bond to be duly executed on its behalf by Its authorized officer, agent, or representative. BIDDER Siltek Group, Inc. Bidder's lNam Corr Signature and Title SURETY Hartford Fire pal) Insurance Company ��II---Suret ame and Corporate Seal r witness Itle enr tx Y. in -Fact Note: (1) Above addresses are to be used for giving required notice. (2) Any singular reference to Bidder, Surety. Owner or other party shall be considered plural where applicable, BID BOND 00401 -1 181sT ACTIVE PARK APRIL 10, 2005 SWORN STATEMENT PURSUANT TO SECTION 287.133(3)(a), FLORIDA STATUTES, ON PUBLIC ENTITY CRIMES THIS FORM MUST BE SIGNED AND SWORN TO IN THE PRESENCE OF A NOTARY PUBLIC OR OTHER OFFICIAL AUTHORIZED TO ADMINISTER OATHS. This sworn statement is submitted to g/Ti 0,0r-- 5'0WAJY ,$14r—S B4er-f:41 [ rint nne of the public entity] by .� /1E .s . [ rnt individual's name and title for S /LTiC Co J> [print name of entity submitting sworn statement] whose business address is 43 Ao6 rvooD TOA and (if applicable) its Federal Employer Identification Number (FEIN) is 57Y 3557 8��j (If the entity has no FEIN, include the Social Security Number of the individual signing this sworn statement: ) 2. I understand that a "public entity crime" as defined in Paragraph 287.133(1)(g), Florida Statutes, means a violation of any state or federal law by a person with respect to and directly related to the transaction of business with any public entity or with an agency or political subdivision of any other state or of the United States, including, but not limited to, any bid or contract for goods or services to be provided to any public entity or an agency or political subdivision of any other state or of the United States and involving antitrust, fraud, theft, bribery, collusion, racketeering, conspiracy, or material misrepresentation. 3. I understand that "convicted" or "conviction" as defined in Paragraph 287.133(1)(b), Florida Statues, means a finding of guilt or a conviction of a public entity crime, with or without an adjudication of guilt, in any federal or state trial court of record relating to charges brought by indictment or information after July 1, 1989, as a result of a jury verdict, nonjury trial, or entry of a plea of guilty or nolo contendere. 4. I understand that an "affiliate" as defined in Paragraph 287.133(1)(a), Florida Statutes, means: 1. A predecessor or successor of a person convicted of a public entity crime; or 2. An entity under the control of any natural person who is active in the management of the entity and who has been convicted of a public entity crime. The term "affiliate" includes those officers, directors, executives, partners, shareholders, employees, members, and agents who are active in the management of an affiliate. The ownership by one person of shares constituting a controlling interest in another person, or a pooling of equipment or income among persons when not for fair market value under an arm's length agreement, shall be a prima facie case that one person controls another person. A person who knowingly enters into a joint venture with a person who has been convicted of a public entity crime in Florida during the preceding 36 months shall be considered an affiliate. 5. I understand that a "person" as defined in Paragraph 287.133(1)(e), Florida Statutes, means any natural person or entity organized under the laws of any state or of the United States with the legal power to enter into a binding contract and which bids or applies to bid on contracts for the provision of goods or services let by a public entity, or which otherwise transacts or applies to transact business with a public entity. The term "person" includes those officers, directors, executives, partners, shareholders, employees, members, and agents who are active in management of an entity. Form PUR 7068 (Rev. 06/11/92) 00402 -1 181sT ACTIVE PARK APRIL 10, 2005 6. Based on information and belief, the statement which I have marked below is true in relation to the entity submitting this sworn statement. [Indicate which statement applies] Neither the entity submitting this sworn statement, nor any of its officers, directors, exec tives, partners, shareholders, employees, members, or agents who are active in the management of the entity, nor any affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1, 1989. The entity submitting this sworn statement, or one or more of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity, nor any affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1, 1989. The entity submitting this sworn statement, or one or more of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity, nor any affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1, 1989. However, there has been a subsequent proceeding before a Hearing Officer of the State of Florida, Division of Administrative Hearings and the Final Order entered by the Hearing Officer of the State of Florida, Division of Administrative Hearings and the Final Order entered by the Hearing Officer determined that it was not in the public interest to place the entity submitting this sworn statement on the convicted vendor list. [attach a copy of the final order] I UNDERSTAND THAT THE SUBMISSION OF THIS FORM TO THE CONTRACTING OFFICER FOR THE PUBLIC ENTITY IDENTIFIED IN PARAGRAPH I (ONE) ABOVE IS FOR THAT PUBLIC ENTITY ONLY AND, THAT THIS FORM IS VALID THROUGH DECEMBER 31 OF THE CALENDAR YEAR IN WHICH IT IS FILED. I ALSO UNDERSTAND THAT I AM REQUIRED TO INFORM THE PUBLIC ENTITY PRIOR TO ENTERING INTO A CONTRACT IN EXCESS OF THE THRESHOLD AMOUNT PROVIDED IN SECTIOP CATEGORY TWO OF ANY CHANGE IN THE INFORM Sworn to and subscribed before me this _�_ day of i r,14'cf— , 20v Personally known OR Produced identification Z/ /' (Type of identification) DELTA L. LEE `.z MY COMMISSION i DD 154242 FXME& October 19, 2006 k , 'x bonded T Budget Notary $er` 11C Notary Public - State of�� My commission expires (Printed typed or stamped commissioned name of notary public) Form PUR 7068 (Rev. 06/11/92) 00402 -2 1819T ACTIVE PARK DOCUMENT 00403 TRENCH SAFETY ACT (90 -96, Laws of Florida) APRIL 10, 2005 Bidder acknowledges that included in the appropriate bid items of the proposal and in the Total Bid Price are costs for complying with the Florida Trench Safety Act (90 -96, Laws of Florida) effective October 1, 1990. The bidder further identifies the costs of such compliance to be summarized below: Trench Safety Measure (Description) A. B. C. D. Unit of Measure (LFSF) Unit Unit Extended (Quantity) Cost Cost Total $ /O, 0 c2c If applicable, the Contractor certifies that all trench excavation done within his control in excess of five feet in depth shall be in accordance with the Florida Department of Transportation's Special Provisions Article 125 -1 and Subarticle 125 -4.1 (TRENCH EXCAVATION SAFETY SYSTEM AND SHORING, SPECIAL - TRENCH EXCAVATION). Failure to complete the above may result in the bid being declared non - responsive. Contractor agrees that the above safety complianc bid package. END OF DOCUMENT TRENCH SAFETY ACT 00403 -1 181 sr ACTIVE PARK THIS PAGE INTENTIONALLY LEFT BLANK. APRIL 10, 2005 TRENCH SAFETY ACT 00403 -2 181sT ACTIVE PARK DOCUMENT 00420 INFORMATION REQUIRED FROM BIDDERS GENERAL INFORMATION APRIL 10, 2005 The Bidder shall furnish the following information. Failure to comply with this requirement may cause its rejection. Additional sheets shall be attached as required. 1. Contractor's Name /Address: -.5/1— G 2. Contractor's Telephone Number: 4��) Z/ %'"68Z9 3. Contractor's License: G G G O& D Primary Classification: _f w 4. Number of years as a Cori actor in construction work of the type involved in this Contract: .5 Zy 5. List the names and titles of all officers of Contractor's firm: 91 7 Name of person who inspected site or proposed work for your firm: Name: ✓� 0 Date of Inspection: 157/3 /oS What is the last project of this nature you have completed? G 7Y ©F 8. Have you ever failed to complete work awarded to you; if so, where and why? /1-41D INFO REQUIRED FROM BIDDERS 00420 -1 181ST ACTIVE PARK APRIL 10, 2005 9. Name three individuals or corporations fo which you have performed work and to which you refer: cAa, 9 o LL - 10. List the following information concerning all contracts on hand as of the date of submission of this proposal. (In case of co- venture, list the information for all co- ventures). NAME TOTAL CONTRACTED % OF CONTRACT DATE OF COMPLETION PROJECT CITY VALUE COMPLETION TO DATE (Continue list on inset sheet, if necessary) 11. What equipment do you own that is available for the work? . &hi 12. What equipment will you purchase for the proposed work? l4o)iw E NOTE: Attach additional sheets if required. If requested by the City, the Bidder shall furnish a notarized financial statement, references and other information, sufficiently comprehensive to permit an appraisal of his current financial condition. INFO REQUIRED FROM BIDDERS 00420 -2 05/19/2005 15:23 FAX 9542171723 SILTEK.GROUP.INC. Z 004/004 1810 ACTIVE PARK 1. Bidder and Surety, jointly and severally, bird themselves, their helm. eaecutcra, administrators, suocessors and assigns to pay to Owner upon default of Bidder any di(ferenoe between the total amount of 8lddoes bid and the total amount of the bid of the next lowest. responsibla and responsive bidder as determined by Owner for the Work required by the Contract Documents, provided that. 1.1. If there is no such next lowest, responsible and responsive bidder, and Owner does not abandon the Project, then Bidder and Surety shall pay to Owner the penal sum set forth on the feoa of this Bond, and 1.2. In no event shall Bidders and Suroty'o obligation hereunder exceed the penal sum set forth on the face of this Bond, 2. Default of Bidder shall occur upon the failure of Bidder to deliver within the time required by the Bidding Documents (or any extension thereof agreed to In writing by Owner) the executed Agreement required by the Bidding Documenta and any performance and payment bonds required by the Bidding Documents and Contract Documents. 3. This obligation shall be null anti void If: 3.1. Owner accepts Bidder's bid and Bidder delivers within the time required by the Bidding Doou nenta (or any extension thereof agreed to in writing by Owner) the executed Agreement required by the Bidding Documents and any performance and payment bonds required by the Bidding Documents and Contract Documents, or 3.2. All bids are rejected by Owner, or 3.3. Owner falls to Issue a notice of award to Bidder wlthln the time specified In the Bidding Documents (or any extension thereat agreed to In wilting by Bidder and, If applicable, consented to by Surety when required by paragraph 5 hereof). 4. Payment under this Bond will be due and payable upon defautt by Bidder and within 30 calendar days after receipt by Bidder and within 30 calendar days after receipt by Bidder and Surety of written notice of default from Owner. which notice vAli be given with reasonable promptness, Identlfying this Bond and the Project and Including a statement of the amount due. APRIL. 10, 2OW S. Surety waives notice of and any and all defenses based on or arleing out of any time extension to Issue notice of award agreed to In writing by Owner and Bidder, provided that the total time for Issuing notioe of award Including extensions shall not In the aggregate exceed 120 days from Ski Due Data without Surety's written consent. a. No suit or action shall be commenced under this Bond prior to 30 Calendar days after the nottoe of default required In paragraph 4 above Is received by Bidder and Surety and In no case later than one year after Bid Due Date. 7. Any suit or action under this Bond shall be oommenoed only In a court of oompetent Jurisdiction located In the state in which the Project Is located. 8. Notes required hereunder shall be In writing and sent to Bidder and Surety at their respective addresses shown on the face of this Bond. Such notices may be sent by personal delivery, commercial courier or by United States Registered or Certffled Mail, return receipt requested, postage pre -paid, and shall be deamed to be effective upon receipt by the party concerned. 9. Surety shall cause to be attached to this Bond a current and effective Power of Attorney evidanoing the authority of the officer, agent or representative who executed thle Bond on bahalf of Surety to execute, seal and deliver such Bond and bind the Surety thereby, 10. This Bond Is Intended to conform to all applicable statutory requirements. Any applicable requlremeM of any applicable statute that has been omitted from this Bond shall be deemed to be included herein as if Bet forth at length. If any provielon of this Bail conflicts with any applicable provision of this Bond confllcN with any applI=abte provision of any applicable statute, then the provision of said statute shall govem and the remainder of this Bond thrt is not In conflict therewith shall Continue In full fords and affoot. 11. The term 'bid' as used herein Inoludss a bid, offer or proposal as applicable. BID BOND 00401 -2 Obligee'sHnsured's Name The City of Sunny Isles Beach Sltek Group, Inc. Obligee's /lnsured's Mailing Address 18o7o Collins Avenue Sunny Isles Beach, Florida 3316o 4403 Dogwood Circle Weston, Florida 33331 Bond/Policy Number N/A own IMPORTANT NOTICE TO OBLIGEES /POLICYHOLDERS — TERRORISM RISK INSURANCE ACT OF 2002 You are hereby notified that, under the Terrorism Risk Insurance Act of 2002, effective November 26, 2002, we must make terrorism coverage available in your bond /policy. However, the actual coverage provided by your bond /policy for acts of terrorism, as is true for all coverages, is limited by the terms, conditions, exclusions, limits, other provisions of your bond /policy, any endorsements to the bond /policy and generally applicable rules of law. Any terrorism coverage provided by this bond /policy is partially reinsured by the United States of America under a formula established by Federal Law. Under this formula, the United States will pay 90% of covered terrorism losses exceeding a statutorily - established deductible paid by sureties /insurers until such time as insured losses under the program reach $100 billion. If that occurs, Congress will determine the procedures for, and the source of, any payments for losses in excess of $100 billion. The premium charge that has been established for terrorism coverage under this bond /policy is either shown on this form or elsewhere in the bond /policy. If there is no premium shown for terrorism on this form or elsewhere in the bond /policy, there is no premium for the coverage. Terrorism premium: 1 $0 Form B- 3333 -0 Page 1 of 1 © 2002, The Hartford Direct Inquiries /Claims to: POWER OF ATTORNEY THE HARTFORD BOND, T-4 690 ASYLUM AVENUE HARTFORD, CONNECTICUT 06115 call: 888 - 266 -3488 or fax: 860 - 757 -5835 KNOW ALL PERSONS BY THESE PRESENTS THAT: Agency Code: 21- 229752 Hartford Fire Insurance Company, a corporation duly organized under the laws of the State of Connecticut OHartford Casualty Insurance Company, a corporation duly organized under the laws of the State of Indiana X Hartford Accident and Indemnity Company, a corporation duly organized under the laws of the State of Connecticut Hartford Underwriters Insurance Company, a corporation duly organized under the laws of the State of Connecticut Twin City Fire Insurance Company, a corporation duly organized under the laws of the State of Indiana Hartford Insurance Company of Illinois, a corporation duly organized under the laws of the State of Illinois Hartford Insurance Company of the Midwest, a corporation duly organized under the laws of the State of Indiana Hartford Insurance Company of the Southeast, a corporation duly organized under the laws of the State of Florida having their home office in Hartford, Connecticut, (hereinafter collectively referred to as the "Companies') do hereby make, constitute and appoint, up to the amount of unlimited: Charles J. Nielson, Mary C. Aceves, Warren Alter, Charles D. Nielson of Miami Lakes, FL their true and lawful Attorney(s) -in -Fact, each in their separate capacity if more than one is named above, to sign its name as surety(ies) only as delineated above by ®, and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written instruments in the nature thereof, on behalf of the Companies in their business of guaranteeing the fidelity of persons, guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. In Witness Whereof, and as authorized by a Resolution of the Board of Directors of the Companies on July 21, 2003 the Companies have caused these presents to be signed by its Assistant Vice President and its corporate seals to be hereto affixed, duly attested by its Assistant Secretary. Further, pursuant to Resolution of the Board of Directors of the Companies, the Companies hereby unambiguously affirm that they are and will be bound by any mechanically applied signatures applied to this Power of Attorney. e�7►pMS � :` ca.ne.rro~: � �,9a:" '��eM�Wr�• �.t�.roec� +,n4 $a'��woWw� •«- � S � 1564 :^ � ` °s - � zf �87CA V 1970 1979 S� A e 1. t � €xs. � gib ............ .b4 y 'rr.�..�.�.�.�.•• .;.F 'fie .. ':3 1979 ♦ d,PAT4AV9,�a '� IA 'e �,� � ,�'�' "a,rMrV r�•HBrPIP' o ��J ct . (�-� Paul A. Bergenholtz, Assistant Secretary STATE OF CONNECTICUT SS. Hartford COUNTY OF HARTFORD 0), ,,/ -� David T. Akers, Assistant Vice President On this 23rd day of July, 2003, before me personally came David T. Akers, to me known, who being by me duly sworn, did depose and say: that he resides in the County of Hampden, Commonwealth of Massachusetts; that he is the Assistant Vice President of the Companies, the corporations described in and which executed the above instrument; that he knows the seals of the said corporations; that the seals affixed to the said instrument are such corporate seals; that they were so affixed by authority of the Boards of Directors of said corporations and that he signed his name thereto by like authority. '�44 E. p� � * Scott E. Paseka Notary Public CERTIFICATE My Commission Expires October 31, 2007 I, the undersigned, Assistant Vice President of the Companies, DO HEREBY CERTIFY that the above and foregoing is a true and correct copy of the Power of Attorney executed by said Companies, which is still in full force effective as of June 9, 2005. Signed and sealed at the City of Hartford. -yl~s errx�o : � � 9 � r IND- 11 * Of `979 0 i 1a79 TW4� ri� YA. It • 1 ' . .. Gary W. Stumper, Assistant Vice President POA 2004 0 A 0 R O � � � Cl) J F- U W I-) 0 w a. � � @ k 0 q f f LO U-) E E CL 0 k k ƒ ƒ ƒ ƒ k � ■ v m @ m CL J 7 2 E 0 o n o ¥ o c o Q 0 + k R R R R R 0 $ \ E a # 6 6 6 co ° 00 2 h « & 2 \ / 2 b R R r- c n m O V � � C\[ co 0 � � U / E 0 0 c m m $� Q f 0 / 7 7 f \ / O 0 9 w £ 0 00 U ® £ E % 2 ) g Q �ƒ 2 \ 0 § 0 / @ x E q @ ® E Q ® ® N % 2 \ 0 S m ƒ 0 § 0 U f 0 U \ 2 \ E U ±) 2 0 k cn § E 0 E @ • 6 E 7 E J 181" ACTIVE PARK LIST OF SUBCONTRACTORS APRIL 10, 2005 The Bidder SHALL list below the name and address of each Subcontractor who will perform work under this Contract in excess of one -half percent of the total bid price, and shall also list the portion of the work which will be done by such Subcontractor. After the opening of Proposals, changes or substitutions will be allowed with written approval of the City of Sunny Isles Beach. Subcontractors must be properly licensed. Work to be Performed Subcontractor's Name/Address 2. 3. 3 5. C 7. I.), e91 10. NOTE: Attach additional sheets if required. INFO REQUIRED FROM BIDDERS 00420 -3 SILTEK 181st DRIVE ACTIVE PARK Specialty Company Contact Info. Structural Shell Siltek Group Inc 4403 Dogwood Circle Weston, Florida 33331 PH 954 - 217 -6829 Site: McKay Contracting, Inc. 1234 SW 1st Way Deerfield Beach, FL 33441 PH 954 - 480 -6404 Plumbing: Zager Plumbing 740 S Deerfield Ave., Ste.1 Deerfield Beach, FL 33441 Ph: 954 - 481 -2629 Fire Sprinklers: Caribbean Fire & Associates 3856 SW 30th Avenue Suite 109 Hollywood, Florida 33312 Ph: 954 - 581 -9393 HVAC: Pilar Services 8191 N.W. 91 st Terrace Bay A -3 Medley, Florida 33166 Ph: 305 - 888 -2421 Electrical: Statewide Electrical 13277 S.W. 124 Street, Suite # 9 Miami, Florida 33186 Ph: 786 - 236 -8075 Structural Steel TWS Fabricators 2350 SW 57th Way Hollywood, FL 33023 Ph. 954 - 983 -9749 Windows: Florida Engineered Glass 8942 SW 10th Terrace Miami, FL 33174 Ph. 786 - 402 -0407 Doors: ADH 19113 E Lake Drive Miami Lakes, FL 33015 Ph. 305 - 321 -9529 Roof: Southern Coast 237 NW 1st Street Deerfield Beach, FL 33441 Ph: 954 -426 -3312 Piles: Ebsary Foundation 2154 North River Dr. Miami, FL 33125 Ph: 305-325-0530 Landscaping Tropic Landscaping P.O. Box 901368 Homestead, Florida 33090 -1368 Ph : (305) 245-4144 181ST DRIVE ACTIVE PARK APRIL 10, 2005 SECTION 00020 NOTICE TO BIDDERS NOTICE IS HEREBY GIVEN that the CITY COMMISSION OF THE CITY OF SUNNY ISLES BEACH is seeking sealed bids for the following work as specified. 181't Drive Active Park ML Project No. 114122 City of Sunny Isles Beach Bid No. 05 -04 -01 Sealed bids for the construction of the 181" Drive Active Park, at 18115 North Bay Road, Sunny Isles Beach, Florida, 33160, consisting of a two (2) acre site to be developed as a public recreation facility will be received by the Owner, City of Sunny Isles Beach. Work generally will consist of a baseball field with lighting, perimeter on- street parking, a new recreation center, a new gymnasium, landscape, infrastructure, and miscellaneous site amenities. Bids shall be on a unit price basis; segregated bids will not be accepted. Sealed bids will be received by the Office of the City Clerk until 2:00 P.M., on Tuesday, May 31, 2005 at the City of Sunny Isles Beach Governmental Center located at 18070 Collins Avenue, Sunny Isles Beach, Florida 33160. Bids received after this time will be returned unopened. Bids submitted will be opened publicly and read aloud at this time. Bidders are to register in person at the Office of the City Clerk to receive authorization to obtain the complete set of Bidding Documents. General Bid forms can be obtained from the Office of the City Clerk, City of Sunny Isles Beach, Governmental Center located at 18070 Collins Avenue, Sunny Isles Beach, Florida 33160. Bid security in the amount of five percent (5 %) of the Total Bid must accompany the Bid in accordance with the Instructions to Bidders. A mandatory Pre -Bid Meeting for all potential Bidders is set for 8:00 A.M. on Tuesday May 17, 2005 at the City of Sunny Isles Beach, Governmental Center located at 18070 Collins Avenue, Sunny Isles Beach, Florida 33160. NOTICE TO BIDDERS 00020 -1 181" DRIVE ACTIVE PARK APRIL 10, 2005 The City reserves the right to reject any or all Bids, with or without cause, to waive technical errors and informalities, and to accept the Bid, which best serves the interest of the City. For further information, contact the office of the City Clerk: Jane Hines City Clerk City of Sunny Isles Beach (305) 947 -0606 Publish Date(s): April 29, 2005 END OF DOCUMENT NOTICE TO BIDDERS 00020 -2 181 "DRIVE ACTIVE PARK SECTION 00100 INSTRUCTIONS TO BIDDERS 1. DEFINITION OF TERMS APRIL 10, 2005 1.1 Bidding Documents - these include the Advertisement for Bid, Instructions to Bidders, Bid Form, sample bidding and contract forms, proposed Contract Documents as defined in the General Conditions and any Addenda issued prior to receipt of bids. 1.2 Total Base Bid - the amount stated on the Bid Form for which the Bidder offers to perform all the Work as described in the Bidding Documents. 1.3 Unit Price - the amount stated in the Bid Form as a price per unit of measurement for materials or labor as described in the Bidding Documents. 1.4 Lump Sum Price - the amount stated in the Bid Form as a price per lump sum of measurement for materials or labor as described in the Bidding Documents. 1.5 Addenda - written and graphic documents issued by the Engineer prior to the execution of the Contract to modify or interpret the Bidding Documents. 2. BIDDING DOCUMENTS 2.1 Instructions on how to obtain complete sets of Bidding Documents may be obtained from the Office of the City Clerk as stated in the Advertisement for Bid. 2.2 Complete sets of Bidding Documents shall be used by Bidders in preparation of Bids; neither the Owner nor the Engineer /Architect assumes any responsibility for errors or misinterpretations resulting from the use of incomplete sets. 2.3 Bidding documents consist of this project manual along with the following construction plans titled: a. 181 ' Drive Active Park, 18115 North Bay Road MLA Project No.: 114122 City of Sunny Isles Beach Bid No. 05 -04 -01 3. EXAMINATION OF DOCUMENTS AND SITE 3.1 Bidders shall visit the site of the proposed work and become familiar with the nature and extent of work to be performed and local conditions that may affect the work. 3.2 The Bidding Documents were prepared to present an essentially accurate representation of existing conditions, interpreted from available information on INSTRUCTIONS TO BIDDERS 00100 -1 APRIL 10, 2005 181sT DRIVE ACTIVE PARK the site. The Bidder is not relieved, however, of the responsibility of becoming fully informed as to existing conditions at the site. 3.3 Bidders shall examine existing site improvements, and conditions, utilities, and streets to determine all conditions, which will affect the Work. 4. INTERPRETATION OF BIDDING DOCUMENTS 4.1 All questions requiring clarification or interpretation of the Bidding Documents shall be made in writing and shall reach the office of the Owner at least 5 days prior to the date for receipt of bids. Direct all requests to the attention of the Project Manager at Miller, Legg & Associates, Inc., (954) 436 -7000. 4.2 Any modification or interpretation of the Bidding Documents will be made by Addendum to all who are recorded by the Engineer as having received a complete set of Bidding Documents. 4.3 Interpretations or modifications of Bidding Documents made in any manner other than by Addendum will not be binding. 4.4 A Bidder, prior to submitting his Bid, shall ascertain that he has received all Addenda issued, and shall acknowledge their receipt in the Bid Form. 5. SUBSTITUTIONS 5.1 Bidders represent that their Bid is based upon the materials and equipment described in the Bidding Documents. 5.2 Requests for substitutions will be considered prior to receipt of bids if they reach the Engineer at least 10 days prior to the date for receipt of bids. 5.3 Acceptance by the Engineer /Architect of a proposed substitution will be issued in the form of an Addendum or Substitution Request Form. 6. QUALIFICATION OF BIDDERS 6.1 If requested, the Bidder shall submit to the Owner, prior to award of contract, a properly completed Contractors Qualification Statement, along with any other evidence of his satisfactory experience and ability to perform the proposed Work. 6.2 If requested by the Owner, the Bidder shall submit a certified financial statement, prepared within the past 30 days, indicating current financial resources, liabilities, capital equipment, and past history performance. 6.3 Bidders may be disqualified and their bids rejected for any of the following specific reasons: a. Reason to believe that collusion exists among Bidders. 001 00-2 INSTRUCTIONS TO BIDDERS 181ST DRIVE ACTIVE PARK APRIL 10, 2005 b. Determination of lack of competency as may be revealed by qualification statements, financial statements, experience records, or other question- naires. C. The Bidder's uncompleted work load which in the judgement of the Owner may cause detrimental impact on prompt completion of this project. d. The Bidder is involved in any litigation against the Owner. e. The Bidder has defaulted on any previous contract or is in arrears on any existing contract. f. The submittal of more than one proposal from an individual, firm, partnership, corporation or association under the same or different names. 6.4 It shall be a requirement of this bid that there are no related party transactions between the bidder and any employee, agent or contractor of the City of Sunny Isles Beach. Any bidder who is a related party, as noted herein, will be considered non - responsive and the proposal and bid bond will be immediately returned. A bidder will be considered a related party if the bidder has an ownership interest or is in any way related to an employee, agent, consultant or contractor of the City, is a sub - consultant of an employee, agent, consultant or contractor, and can influence the management or operating policy of the other to an extent that one of the transacting parties might be prevented from fully pursuing its own separate interests. 7. PERFORMANCE OF WORK BY CONTRACTOR: 7.1 The Contractor shall perform on the site and with his own forces, work equivalent to at least forty percent (40 %) of the total amount of work to be performed under this contract. After the contract is awarded, and during the progress of the work, the Owner reserves the right to reduce the percentage of work performed by the contractor's own forces. 8. BID PREPARATION 8.1 Prepare bids on the forms provided by the Engineer with all blanks on the Bid Form filled in by typewriter or written in ink. 8.2 State total base bid amount in both words and figures. In case of a discrepancy between the two, the amount written in words shall govern. 8.3 Bids shall include the legal name and address of the Bidder and indicate whether the Bidder is a sole proprietor, a partnership, a corporation, or other legal entity. a. Individual - provide name and post office address. b. Partnership - provide name and post office address of each member of the partnership. C. Corporation - provide name and post office address of person signing the form and legal evidence of his authority to do so; names and addresses of the corporation president, secretary and treasurer; name of state where chartered; and affixed with the seal of the corporation, attested by the secretary. INSTRUCTIONS TO BIDDERS 00100 -3 181sT DRIVE ACTIVE PARK APRIL 10, 2005 8.4 Bids shall include documentation required by the Florida "Trench Safety Act." The Trench Safety Act form is included within the Bid Form Section for completion in the Bid Contractor include the the Bidders the costt of Owner. The ancenlwit prices presented the applicable trench safety standards. 8.5 All Unit Prices requested on the Bid Forms Exhibits A and Exhibit B shall be bid. 9. BID SUBMITTAL 9.1 Submit one (1) original and five (5) copies, enclosed in a sealed opaque envelope, addressed to the entity receiving the bids as stated in the Advertisement for Bids. The envelope shall be further identified with the Project name, the Bidder's name and address, and the words "BID ENCLOSED" with the following Forms and /or Documents: a. 00300 - Bid Form b. 00310 - Bid Form — Exhibit A C. 00320 - Bid Form — Exhibit B d. 00401 - Bid Bond e. 00402 - Form PUR 7068 (Rev. 06/11/92) f. 00403 - Trench Safety Act Document g. 00420 - Information Required from Bidders 9.2 Deposit Bids at the designated location on or before the time and date for receipt of Bids indicated in the Advertisement for Bids. Bids received after the time and date indicated for receipt of Bids will be returned unopened. 10. BID SECURITY 10.1 Each Bid shall be accompanied by a cashiers check drawn on any State or National Bank in Florida, or an acceptable Bidders Bond, payable unconditionally to the Owner, in an amount of five percent (5 %) of the amount of the total Bid. 10.2 Failure of the successful Bidder to enter into the Contract in accordance with his Bid, or failure to furnish the required bonds will be just cause for an annulment of the award with the amount of the bid security being forfeited to the Owner as liquidated damages, not as a penalty. 10.3 Should a Bid Bond be used, acceptable Surety companies shall be determined from the latest United States Treasury Department's list of companies holding certificates of authority as acceptable Sureties on Federal Bonds. Requirements for Acceptable Surety Companies are outlined in Item 15.4. 10.4 The Owner may retain the bid security of those Bidders to whom an award may be considered until successful execution of the Contract and bonds; or the specified time for holding bids has elapsed; or all Bids have been rejected. 11. MODIFICATION AND WITHDRAWAL OF BID 00100 -4 INSTRUCTIONS TO BIDDERS 181 ST DRIVE ACTIVE PARK 12. 13 14. 15. APRIL 10, 2005 11.1 Prior to the time of bid opening, a Bidder may withdraw his Bid at any time, but may not resubmit it. Bids may not be modified after submittal. 11.2 After the bid opening, no Bid may be withdrawn, canceled or modified for a period of 90 days after the time and date designated for the receipt of bids. OPENING OF BIDS 12.1 Bids submitted will be opened publicly and read aloud at the time and place stated in the Advertisement for Bids. GOVERNING LAWS AND REGULATIONS 13.1 Bidders shall be familiar with all federal, state, and local laws, ordinances, rules, and regulations that may in any way affect the Work. 13.2 Trench Safety Act: The Occupational Safety and Health Administration excavation safety standards, 29 CFR 1926.650 Subpart P trench safety standards will be in effect during the period of construction of the Project. In compliance with current State of Florida statutes, the Bidder shall provide documentation required by the Florida Trench Safety statute to the Owner, in conjunction with the Bid Form. LIQUIDATED DAMAGES 14.1 The Owner may incur financial loss if the Work is not substantially complete by the date set forth in the Agreement. The Contractor (and his Surety) shall be liable for liquidated damages in accordance with the Supplementary Conditions and the Agreement. PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND 15.1 With the execution and delivery of the Contract, the Bidder shall furnish the following Surety bonds of the forms contained herein: a. Performance Bond guaranteeing full and faithful execution of the Work in an amount equal to 100 percent of the Contract Sum, and including guaranteed repair and maintenance of all defects due to faulty materials and workmanship that appear within one year after completion of contract. b. Labor and Material Payment Bond guaranteeing full and proper protection of all claimants supplying labor and materials in the Work in an amount equal to 100 percent of the Contract Sum. 15.2 Bonds shall be executed by Surety authorized to do business in the State of Florida and listed on the latest U.S. Treasury Department list of companies holding certificates of authority as acceptable sureties on Federal Bonds. INSTRUCTIONS TO BIDDERS 00100 -5 APRIL 10, 2005 181ST DRIVE ACTIVE PARK 15.3 Bonds executed by an Attorney -in -Fact on behalf of the Surety, shall have affixed thereto a certified and current copy of Power of Attorney, indicating the monetary limit of such power. 15.4 Qualifications: As to companies being rated acceptable: A Bid Bond and Performance and Payment Bond must be executed by a Surety Company of recognized standing, authorized to do business in the State of Florida and having been in business with a record of successful continuous operation for at least (5) years. In addition to the above — minimum qualifications, the Surety Company must meet the following additional qualifications. a. The City will accept a surety bond from a company with a rating of B ++ or better for bonds up to $1 million, provided, however, that if any Surety Company appears on the watch list that is published quarterly by Intercom of the Office of the Florida Insurance Commissioner, the City shall review and either accept or reject the Surety Company based on the financial information available to the City. A Surety Company that is rejected by the City may be substituted by the bidder or proposer with a surety company acceptable to the City, only if the bid amount does not increase. b. The Surety Company shall have at least the following minimum ratings: Amount of Bond Policyholder's Rating Financial Size Category 100,000 to 1,000,000 B ++ Class V or higher 1,000,001 to 2,000,000 A- Class VI or higher 2,000,001 to 5,000,000 A Class VII or higher C. All Surety Companies are subject to review and approval by the Owner and may be rejected without cause. All bonds signed by an Agency must be accompanied by a certificate of authority to act. 15.5 The Surety Company shall submit verification from the Department of Insurance Office of the Treasurer stating the surety company's license and certificate of authorization to do business in the State of Florida. 16. SUBCONTRACTOR LIST 16.1 In conjunction with the BudaForm, Bidder i proposed for the principal portions of subcontractors and major suppliers the Work. Submit list on form provided by the Engineer. 16.2 Prior to award of Contract, the Owner will notify the Bidder in writing if they have an objection to any person or entity listed. Upon such reasonable objection, the Bidder shall propose an acceptable substitute person or entity in accordance with Article 6.06 of the General Conditions. 00100 -6 INSTRUCTIONS TO BIDDERS 181" DRIVE ACTIVE PARK APRIL 10, 2005 17. BID PROTEST 17.1 In the event of a timely protest, the City Manager or his/her designee shall stay the award of the contract unless, after consulting with the City Attorney and the affected director, he /she determines that the award of the contract without delay is necessary to protect substantial interests of the city. 17.2 The city shall require a deposit from a protester to compensate the City for the expenses of administering the protest. If the protest is decided in the protester's favor, the entire deposit shall be returned to the protester. If the protest is not decided in the protester's favor, the deposit shall be forfeited to the city. The deposit shall be in the form of a cashier's check and shall be in the amount of 1 % of the amount of the pending award, with a minimum deposit of $500 and a maximum deposit of $10,000. 18. CONTRACT AWARD AND EXECUTION 18.1 Until final award of Contract, the Owner reserves the right to reject any and all Bids, with or without cause; to waive any informality or irregularity; or to accept the Bid which is in the best interest of the Owner. 18.2 It is the intent of the Owner to award a Contract to the lowest responsible Total Base Bidder whose Bid is in conformance with the Bidding Documents and does not exceed the funds available. 18.3 Upon acceptance of a Bid and award of the Contract, the successful Bidder shall deliver the executed Contract, along with required bonds and any other items re- quested, to the Owner within 10 days. Failure to do so will be deemed as a breach of agreement by the Bidder and result in forfeiture of bid security as described in the Instructions to Bidders. 18.4 The Owner reserves the right to hold all proposals and bid guarantees for a period not to exceed 90 days after the date of bid opening stated in the Advertisement for Bids. 18.5 The award of the contract, if it is awarded, will be to the lowest responsible total base bidder whose qualifications indicate the award will be to the best interest of the Owner and whose proposal shall comply with the requirements of the Contract Documents. Time is of the essence for this project and the time limits set in the proposal, if set by the bidder, will be accorded weight by the Owner in the determination of the best proposal. In no case will the award be made until all necessary investigations have been made into the responsibility of the low bidder and the Owner is satisfied that the bidder is qualified to do the Work and have the necessary organization, capital and equipment to carry out the provisions of the contract to the satisfaction of the Owner within the time specified. 18.6 If the Contractor feels that a problem exists either prior to, or during the bid opening, he shall contact the City (within 24 hours of the bid opening) and follow the City's' current policy for bid protests. INSTRUCTIONS TO BIDDERS 00100 -7 APRIL 10, 2005 181ST DRIVE ACTIVE PARK as a total contract any combination 18.7 The Owner reserves theltems that would be in the best interest of the Owner. the Unit Price Bid Schedule 19. CASH ALLOWANCES 19.1 The Bidder is advised that a space is provided in the Bid Form, Document 00300, for this purpose only. The Contractor shall not proceed on any additional work to be covered by allowances until authorized in writing by the Engineer. Such work shall be approved by the Owner, shall be within the scope of work defined by this Contract and shall not exceed the amount indicated in the Bid Form. Any amount remaining in the Cash Allowance will be retained by the Owner. END OF DOCUMENT 00100 -8 INSTRUCTIONS TO BIDDERS 181't DRIVE ACTIVE PARK :.. SECTION 00300 BID FORM For all Site /Civil Work other than Unit Price Work, a Lump Sum of: APRIL 10, 2005 (use words) ($ ) figures For all Unit Price Site /Civil Work, a Total Sum (Exhibit A) of: (use words) ($ ) figures For all Lump Sum Architectural Work, a Total Sum (Exhibit B) of: (use words) Ten Percent (10 %) Contingency Items (poi of total above items) (use words) figures ($ ) figures TOTAL BASE BID (Lump sum, Unit prices, and contingency items) (use words) Contractor Address Contact Person: Phone: ($ ) figures to furnish all materials, equipment and labor and to perform all work in accordance with the Contract Documents for construction of: 181 ST DRIVE ACTIVE PARK, 18115 NORTH BAY ROAD; located in CITY OF SUNNY ISLES BEACH, FLORIDA 33160. To: CITY OF SUNNY ISLES BEACH 18070 Collins Avenue Sunny Isles Beach, Florida 33160 The undersigned Bidder has carefully examined the Bidding Documents and the site of the proposed work and is familiar with the nature and extent of the work and any local conditions that may in any manner affect the work to be done. BID FORM 00300 -1 181'0 DRIVE ACTIVE PARK APRIL 10, 2005 The undersigned Bidder agrees to do all the work and furnish all materials called for by the Bidding Documents, in the manner prescribed therein and to the standards of quality and performance established by the Engineer for the unit price amounts stated in the spaces herein provided, for each of the items or combination of items stipulated. Unit price line items shall include cost of implementing all applicable safety requirements. Bidder acknowledges that estimated quantities scheduled are approximated for the sole purpose of obtaining comparative bids for determination of the lowest responsible bidder and actual quantities required may increase or decrease. Bidder further agrees that payments will be made on the basis of actual quantities placed and accepted in the construction. BID SECURITY Accompanying this Bid is a certified or cashier's check or a bid bond in the amount of 1 50% (not less than 5% of the bid) made payable to the Owner which may be forfeited as liquidated damages if, in the event this proposal is accepted, the undersigned fails to execute the Agreement and furnish and pay for the required performance and payment bonds for the Owner within 10 days after acceptance of the Bid; otherwise said certified or cashier's check or bid bond will be returned to the undersigned. The undersigned Bidder agrees to commence work within 10 days after the date of written Notice to Proceed, and further agrees to substantially complete the work within the time indicated as follows: 1. Architectural building elements, i.e. Recreation Center and Gymnasium work within 365 consecutive calendar days after the date of written Notice to Proceed, subject to such extensions of time allowed by the Conditions of the Contract. 2. Project site elements, i.e. remaining site work within 432 consecutive calendar days after the date of written Notice to Proceed, subject to such extensions of time allowed by the Conditions of the Contract. The undersigned Bidder also agrees to complete final work within 463 calendar days after the date of written Notice to Proceed. The undersigned Bidder agrees that this Bid shall be good and may not be withdrawn for a period of 90 days after the scheduled closing time for receiving bids. The undersigned agrees to forfeit to the Owner, as liquidated damages for each calendar day elapsing between each date established above as the date of substantial completion and the actual date of such substantial completion of the contract work, the amount of $1500.00 per calendar day. 00300 -2 BID FORM 181'" DRIVE ACTIVE PARK APRIL 10, 2005 The undersigned further agrees to forfeit to the Owner, as liquidated damages for each calendar day elapsing between the date established above as the date of final completion and the actual date of final completion of the contract work, the amount of $1,000.00 per calendar day. ADDENDA Bidder acknowledges the receipt of Addendum No.'s 1. ,2. ,3. ,4. ,5. Dated this day of (month) (year) Contractor: Address: SEAL Attachments: 00310 - Bid Form — Exhibit A 00320 - Bid Form — Exhibit B 00401 - Bid Bond 00402 - Form PUR 7068 (Rev. 06/11/92) 00403 - Trench Safety Act Document 00420 - Information Required from Bidders END OF DOCUMENT BID FORM 00300 -3 181'' DRIVE ACTIVE PARK THIS PAGE LEFT INTENTIONALLY BLANK. BID FORM APRIL 10, 2005 00300 -4 181" DRIVE ACTIVE PARK APRIL 10, 2005 PICKET FENCF / CATES 6' HT. PICKET FENCE 6' HT. CURVE WALL PICKET FENCE PICKET FENCE COLUMN 9.5' WIDE DBL. CURVE PICKET GATE 5.5' WIDE DOUBLE PICKET GATE SITE FURNISHINGS TRASH RECEPTACLES (SITE) 6 FT. BENCH W /BACK 6 FT. BENCH W/O BACK 4 FT. PICNIC TABLE BICYCLE RACK WALL MOUNTED FLAG POLE (LVW20) SURFACE MOUNT FLAG POLE (EC -30) HAYLARD COVER (HC -6) CLEAT BOX (CBC -412) WATER FOUNTAIN (M43 -2) 48" DIAMETER BRONZE SEAL INSET SITE LIGHTING PEDESTRIAN LIGHTING W /RECEPTACLES LANDSCAPE UP LIGHTING LANDSCAPE SPOT LIGHTING SOD ST. AUG USTINE 'FLORATAM' BID FORM - EXHIBIT A 350 L.F. $ $ 70 L.F. $ $ 2 EA. $ $ 3 EA. $ $ 2 EA. $ $ SUB -TOTAL $ 8 EA. $ $ 13 EA. $ $ 3 EA. $ $ 5 EA. $ $ 1 EA. $ $ 2 EA. $ $ 1 EA. $ $ 3 EA. $ $ 3 EA. $ $ 2 EA. $ $ 1 EA. $ $ SUB -TOTAL $ 17 EA. $ $ 32 EA. $ $ 4 EA. $ $ SUB -TOTAL $ 11450 S.F. $ $ SUB -TOTAL $ CONT. 00310 -1 181ST DRIVE ACTIVE PARK APRIL 10, 2005 DRIVE ACTIVE PARK. RICA a17'FCIVIL. BID SCHEOUI.E g N� � 4 . y e TREE REMOVAL�RELOCATION REMOVAL 48" STRANGLER FIG 36" STRANGLER FIG 24" STRANGLER FIG ARECA PALMS REMOVAL 4" STRANGLER FIG 12" SABAL PALM RELOCATION (OFF -SITE) 26" SABAL PALM 8" DATE PALM 8" ROYAL PALM Item Quantity Unit Unit Price Cost 2 EA. $ $ 1 EA. $ $ 3 EA. $ $ g EA. $ $ 1 EA. $ $ 1 EA. $ $ EA. 1 EA. $ $ 1 EA. $ $ 4 EA. $ $ EA. SUB -TOTAL $ LANDSCAPE Unit price shall include but is not limited to the following: plant material, installation, staking and guying, mulch, fertilizers, and planting soil. TREES & PALMS EA. $ $ 8' GW. COCONUT PALM 3 3 EA. $ $ 12' GW. COCONUT PALM 14 EA. $ $ 12' HT. GREEN BUTTONWOOD 13 EA. $ $ 6' HT. LIGUSTRUM 14 EA. $ $ 15' GW. DATE PALM ' MEDJOOL' 3 3 EA. $ $ 12' HT. ALEXANDER PALM (SINGLE) MATCHED $ 12' HT. ALEXANDER PALM (DOUBLE) 5 EA. $ $ $ 12', 16', 22' ALEXANDER PALM (TRIPLE) 12 EA. $ $ 5' -6' PYGMY DATE PALM 3 1 EA. EA. $ $ 8' HT. SCREW PINE 15 EA. $ $ 16' HT. SOUTHERN LIVE OAK 4 4 EA. $ $ 8' GW. ROYAL PALM 3 EA. $ $ 6' HT. DESERT CASSIA EA. $ $ 14' -16' CABBAGE PALM 4 4 EA. $ $ 6' O.A.H. FLORIDA THATCH PALM 00310 -2 BID FORM - EXHIBIT A 181ST DRIVE ACTIVE PARK APRIL 10, 2005 181ST DRIVE ACTIVE PARK EXHIBIT "A" - UNIT PRICE SITE/CIVIL BID SCHEDULE Proiect Bid # 05 -0401 Item SHRUBS & GROUNDCOVERS (SIZES PER PLAN) Quantity Unit Unit Price Cost CONT. Unit price shall include but is not limited to the following: plant material, installation, staking and guying, mulch, fertilizers, planting soil. and BOUGAINVILLEA 15 EA. $ $ TREE CRINUM 69 EA. $ $ DWARF POWDER PUFF'NANA' 210 EA. $ BUBBLER HEAD REDTIP COCOPLUM EA. $ $ $ GREEN ISLAND FICUS 166 166 EA. EA. $ $ YELLOW IXORA EA. $ $ WAX JASMINE 64 EA. $ $ EVERGREEN GIANT LIRIOPE 84 84 EA. $ $ PENTAS L.F. EA. $ $ PHILODENDRON 200 0 EA. $ $ XANADU PHILODENDRON EA. $ $ TRINETTE SCHEFFLERA 60 EA. $ $ DWARF FAKAHATCHEE GRASS 19 19 EA. $ $ WALKING IRIS EA. $ $ CARDBOARD PLANT 211 EA. $ $ 22 EA. $ $ IRRIGATION SUB -TOTAL $ BACKFLOW PREVENTER 2" REMOTE CONTROL VALVE 1 EA. $ $ CONTROLLER 8 EA. $ $ SPRAY HEAD 1 EA. $ $ BUBBLER HEAD 340 EA. $ $ ROTOR HEAD 3 EA. $ $ QUICK COUPLER 21 EA. $ $ 3" GATE VALVE 1 EA. $ $ 3" MAINLINE 3 EA. $ $ 1050 L.F. $ $ SUB -TOTAL $ SUBTOTAL SITE ITEMS $ BID FORM - EXHIBIT A 00310 -3 181sT DRIVE ACTIVE PARK APRIL 10, 2005 181ST DRIVE ACTIVE PARK EXHIBIT "A" -UNIT PRICE SITE/CIVIL BID SCHEDULE Project Bid # 05 -04 -01 FURNISHINGS SCOREBOARD BASEBALL 1 2 EA. EA. $ $ $ $ 2 SCOREBOARD POLES 5' 1 EA. $ $ 3 ROW BLEACHER WITH H.C. 1 EA. $ $ 3 ROW BLEACHER 1 EA. $ $ SCORE TABLE 2 EA. $ $ BLEACHER SHADE STRUCTURE 2 EA. $ $ TRASH RECEPTACLE 1 EA. $ $ WATER FOUNTAIN 3 EA. $ $ BASEBALL BASE 1 EA. $ $ HOME PLATE 1 EA. $ $ PITCHERS RUBBER SUB -TOTAL $ BASEBALL FENCES & GATES 30' HT. BACKSTOP FENCE 90 L.F. $ $ $ $ 8' HT. CHAINLINK FENCE AT DUGOUT 100 L.F. $ 5' HT. CHAINLINK FENCE AT DUGOUT 60 L.F. $ $ 15' HT. CHAINLINK FENCE 610 L.F. EA. $ $ $ CHAINLINK DOUBLE GATE (15'X15') 1 $ $ CHAINLINK GATE AT DUGOUT (3'X8') 4 EA. $ $ 20'- 4" O.D. FOUL POLE (YELLOW) 2 EA. $ $ HOMERUN LOWER MID RAIL POWDER COATED (YELLOW) 315 L.F. SUB -TOTAL $ DUGOUT DUGOUT ROOF STRUCTURE 2 EA. EA. $ $ $ $ 6' DUGOUT PLAYERS BENCH 8 SUB -TOTAL CONT. 00310 -4 BID FORM - EXHIBIT A 181sT DRIVE ACTIVE PARK 181ST DRIVE ACTIVE PARK EXHIBIT "A" - UNIT PRICE SITE/CIVIL BID SCHEDULE Proied Bid # 05 -04.01 APRIL 10, 2005 FIELD SURFACES Item Quantity Unit Unit Price Cost 6" TOPSOIL FOR BERMUDA 514 C.Y. $ $ BERMUDA' TIFWAY' 772 0 2772 S.F. $ $ 12" SAND SUBGRADE FOR TURF /CLAY L.F. TN. $ WATER VALVE HAND HOLE BOXES INFIELD CLAY 6" DEPTH EA. $ $ $ INFIELD CLAY ADD MIXTURE 10 0 0 TN. $ $ WARNING TRACK CLAY 3" DEPTH EA. TN. $ $ WARNING TRACK ULTIMATE II MIX. 400 TN. $ $ FINE GRADE SAND /CLAY 48 TN. $ $ 135 41180 S.F. $ $ FIELD LIGHTING EA. $ SUB -TOTAL $ LIGHTING (POLES / CABINET / FIXTURE) SUB -TOTAL $ SUBTOTAL LIGHTING (LABOR / CONDUIT) 1 LS $ $ LIGHTING CONTROL LINK 1 LS $ $ LIGHTING 10 WARRANTY 1 EA $ $ 1 EA $ $ SUB -TOTAL $ SUBTOTAL BASEBALL FIEI D ITEMS $ PLAYGROUND AREA h r, lo- <<,.Ia,:. PLAYBOOSTER SYSTEM SEAT WALL CONSTRUCTION W /PRECAST 1 EA. $ $ ACCENT POLES W /BANNERS 135 L.F. $ $ WATER VALVE HAND HOLE BOXES 6 EA. $ $ 12" PRECAST CUSTOM COLUMN ACCENTS 2 EA. $ $ SAF DEK SAFETY SURFACE 12 EA. $ $ 4" SLAB ON GRADE (SAFETY SURFACE) 2000 S.F. $ $ 24" CONCRETE BANDING 2000 S.F. $ $ 3' DIA. ARTISTIC BOLLARDS 135 L.F. $ $ 6 EA. $ $ SUB -TOTAL $ SUBTOTAL PLAYCROIlND AREA ITEMS $ BID FORM - EXHIBIT A 00310 -5 181ST DRIVE ACTIVE PARK APRIL 10, 2005 WATER SYSTEM DUCTILE IRON PIPE - 4" WATER MAIN 300 LF $ $ $ DUCTILE IRON PIPE - 6" WATER MAIN 20 LF $ $ $ DUCTILE IRON PIPE - 8" WATER MAIN 1 LF $ FIRE HYDRANT ASSEMBLY 1 1 EA Ton $ $ $ DIP 4" x 4" TEE 0.034 Ton $ $ DIP 8" x 6" TEE 0.0875 Ton $ $ DIP 8" x 4" TEE 0.0785 Ton $ $ DIP 8" x 6" REDUCER 0. 047 EA $ $ DIP 6" x 6" TAPPING SLEEVE AND VALVE 1 $ DIP 4" PLUG 0.007 Ton Ton $ $ $ DIP 8" PLUG 0.0225 $ $ DIP 4" 90° BEND 0.112 Ton Ton $ $ DIP 6" 45° BEND 0.0385 EA $ $ DIP - 4" GATE VALVE AND BOX 3 $ DIP - 6" GATE VALVE AND BOX 2 EA EA $ $ $ DOUBLE DETECTOR CHECK VALVE ASSEMBLY - FIRE SERVICE 1 REDUCED PRESSURE BACK FLOW PREVENTOR - WATER SERVICE 1 EA $ $ PRESSURE VACUUM BREAKER - IRRIGATION SERVICE 1 EA $ $ $ 1 1/2" COPPER TUBING 205 LF EA $ $ $ SAMPLE POINT 2 1 EA $ $ PLUG WITH 2" BLOWOFF 400 LF $ $ REMOVE AND DISPOSE OF EXISTING PIPE SUB -TOTAL $ SEWER SYSTEM L.F. $ $ 4" PVC SERVICE 2 2 EA. $ $ CLEAN -OUT 2 EA. $ $ CONNECT TO EXIST. SEWER LINE SUB -TOTAL $ CONT. 00310 -6 BID FORM - EXHIBIT A 181" DRIVE ACTIVE PARK 181 ST DRIVE ACTIVE PARK EXHIBIT "A" - UNIT PRICE SITE/CIVIL BID SCHEDULE APRIL 10, 2005 PAVING Item Quantity Unit Unit Price Cost PARKING 3/4" ASPHALT (First Lift) 3/4" ASPHALT (Second Lift) 8" LIMEROCK BASE 12" SUBGRADE TYPE "D" CURB SIDEWALKS 12" COMPACTED SUBBASE (SIDEWALK) GREY CONC. (BRM W/TROWEL EDGE) 12" COMPACTED SUBBASE (SIDEWALK) GREY CONC. AT DUGOUT (BRM W/TROWEL EDGE) 12" COMPACTED AT DUGOUT SUBBASE SPECIALTY Slnl=WAi Ks, COLOR CONC. (LT. EARTHTONE.- FIELD - ROCKSALT) COLOR CONC. (LT. EARTHTONE - BAND - SMOOTH) COLOR CONC. (BLUE - BAND - SMOOTH) COLOR CONC. (LT. BLUE - BAND - SMOOTH) COLOR CONC. (LT. BLUE - FIELD - ROCKSALT) COLOR CONC. (LT. EARTHTONE - PAVERBAND - SMOOTH) 8 "X8" CLAY BRICK PAVERS ADA - CLAY BRICK PAVERS DRAINAGE 6" PVC PIPE 10" PERFORATED UNDERDRAIN PIPE 18" SOLID HDPE 15" SOLID HDPE 12" DRAIN BASIN 18" DRAIN BASIN DRAINAGE WELL DRAINAGE STRUCTURE 12'x 10'x 7' BID FORM - EXHIBIT A 650 S.Y. $ $ 650 S.Y. $ $ 715 S.Y. $ $ 765 S.Y. $ $ 1000 L.F. $ $ SUB -TOTAL $ 921 S.Y. $ $ 650 S.Y. $ $ 700 S.Y. $ $ 75 S.Y. $ $ 80 S.Y. $ $ 6100 S.F. $ $ 1400 S.F. $ $ 430 S.F. $ $ 325 S.F. $ $ 30 S.F. $ $ 345 S.F. $ $ 1300 S.F. $ $ 450 S.F. $ $ SUB -TOTAL $ 250 LF $ $ 1400 LF $ $ 385 LF $ $ 355 LF $ $ 16 EA $ $ 16 EA $ $ 1 EA $ $ 1 EA $ $ SUB -TOTAL $ CONT. 00310 -7 181sT DRIVE ACTIVE PARK 181ST DRIVE ACTIVE PARK _ EXHIBIT "A" - UNIT PRICE SITEICIVIL BID SCHEDULE Project aid # 05-04 -01 APRIL 10, 2005 Item Quantity Unit Unit Price Cost SIGNING & MARKING 2 EA $ R7 -1 SIGNS 4 EA $ $ FTP -26 SIGNS 850 L.F. $ $ 6" WHITE SOLID LINE 185 185 L.F. $ $ 6" BLUE SOLID LINE SUB -TOTAL $ MMU i ANEOUS_ 1 L.S. $ $ MOBILIZATION 1 L.S. $ $ MAINTENANCE OF TRAFFIC SUB -TOTAL $ SUBTOTAL SITE ENGINEERING ITEMS $ SUBTOTAL SITE ITEMS $ SUBTOTAL BASEBALL FIELD ITEMS $ SUBTOTAL PLAYGROUND ITEMS $ SUBTOTAL SITE ENGINEERING ITEMS $ UNIT I '(Provide Total on Bid Form) 00510 -8 BID FORM - EXHIBIT A 181ST DRIVE ACTIVE PARK APRIL 10, 2005 Furnish all materials, equipment and labor and to perform all work in accordance with the Contract Documents for construction of the associated items below. RECREATION CENTER All Recreation Center work GYMNASIUM Metal Lockers (Section 10505) Gymnasium Equipment (Section 11490) Telescoping Bleachers (Section 12660) All remianing Gymnasium work BID FORM - EXHIBIT B 1 L.S. $ 1 L.S. $ 1 L.S. $ 1 L.S. $ 1 L.S. $ '(Provide Total on Bid Form) 00320-1 181sT DRIVE ACTIVE PARK THIS PAGE LEFT INTENTIONALLY BLANK. APRIL 10, 2005 181"' ACTIVE PARK DOCUMENT 00401 BID BOND BIDDER Name and Address): SURETY (Name and Address of Princioal Place of Business): OWNER (Name and Address): BID CITY OF SUNNY ISLES BEACH 18070 Collins Avenue Su--"'-'-- Beach Florida 33160 BID DUE DATE: PROJECT (Brief Description including Location): BOND BOND NUMBER: DATE: (Not later than Bid Due Date): PENAL SUM: APRIL 10, 2005 IN WITNESS WHEREOF, Surety and Bidder, intending to be legally bound hereby, subject to the terms printed on the reverse side hereof, do each cause this Bid Bond to be duly executed on its behalf by its authorized officer, agent, or representative. BIDDER Bidder's Name and Corporate Seal (Seal) By: Signature and Title Attest: Signature and Title SURETY Surety's Name and Corporate Seal By: Attest: Signature and Title (Attach Power of Attorney) Signature and Title Seal) Note: (1) Above addresses are to be used for giving required notice. (2) Any singular reference to Bidder, Surety, Owner or other party shall be considered plural where applicable. BID BOND 00401 -1 181s' ACTIVE PARK 1. Bidder and Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to pay to Owner upon default of Bidder any difference between the total amount of Bidder's bid and the total amount of the bid of the next lowest, responsible and responsive bidder as determined by Owner for the Work required by the Contract Documents, provided that: 1.1. If there is no such next lowest, responsible and responsive bidder, and Owner does not abandon the Project, then Bidder and Surety shall pay to Owner the penal sum set forth on the face of this Bond, and 1.2. In no event shall Bidder's and Surety's obligation hereunder exceed the penal sum set forth on the face of this Bond. 2. Default of Bidder shall occur upon the failure of Bidder to deliver within the time required by the Bidding Documents (or any extension thereof agreed to in writing by Owner) the executed Agreement required by the Bidding Documents and any performance and payment bonds required by the Bidding Documents and Contract Documents. 3. This obligation shall be null and void if: 3.1. Owner accepts Bidder's bid and Bidder delivers within the time required by the Bidding Documents (or any extension thereof agreed to in writing by Owner) the executed Agreement required by the Bidding Documents and any performance and payment bonds required by the Bidding Documents and Contract Documents, or 3.2. All bids are rejected by Owner, or 3.3. Owner fails to issue a notice of award to Bidder within the time specified in the Bidding Documents (or any extension thereof agreed to in writing by Bidder and, if applicable, consented to by Surety when required by paragraph 5 hereof). 4. Payment under this Bond will be due and payable upon default by Bidder and within 30 calendar days after receipt by Bidder and within 30 calendar days after receipt by Bidder and Surety of written notice of default from Owner, which notice will be given with reasonable promptness, identifying this Bond and the Project and including a statement of the amount due. BID BOND APRIL 10, 2005 5. Surety waives notice of and any and all defenses based on or arising out of any time extension to issue notice of award agreed to in writing by Owner and Bidder, provided that the total time for issuing notice of award including extensions shall not in the aggregate exceed 120 days from Bid Due Date without Surety's written consent. 6. No suit or action shall be commenced under this Bond prior to 30 calendar days after the notice of default required in paragraph 4 above is received by Bidder and Surety and in no case later than one year after Bid Due Date. 7. Any suit or action under this Bond shall be commenced only in a court of competent jurisdiction located in the state in which the Project is located. 8. Notices required hereunder shall be in writing and sent to Bidder and Surety at their respective addresses shown on the face of this Bond. Such notices may be sent by personal delivery, commercial courier or by United States Registered or Certified Mail, return receipt requested, postage pre -paid, and shall be deemed to be effective upon receipt by the parry concerned. 9. Surety shall cause to be attached to this Bond a current and effective Power of Attorney evidencing the authority of the officer, agent or representative who executed this Bond on behalf of Surety to execute, seal and deliver such Bond and bind the Surety thereby. 10. This Bond is intended to conform to all applicable statutory requirements. Any applicable requirement of any applicable statute that has been omitted from this Bond shall be deemed to be included herein as if set forth at length. If any provision of this Bond conflicts with any applicable provision of this Bond conflicts with any applicable provision of any applicable statute, then the provision of said statute shall govern and the remainder of this Bond that is not in conflict therewith shall continue in full force and effect. 11. The term "bid" as used herein includes a bid, offer or proposal as applicable. 00401 -2 181sT ACTIVE PARK APRIL 10, 2005 SWORN STATEMENT PURSUANT TO SECTION 287.133(3)(a), FLORIDA STATUTES, ON PUBLIC ENTITY CRIMES THIS FORM MUST BE SIGNED AND SWORN TO IN THE PRESENCE OF A NOTARY PUBLIC OR OTHER OFFICIAL AUTHORIZED TO ADMINISTER OATHS. This sworn statement is submitted to by [print name of the public entity] for [print individual's name and title] LF1111L11a111e ut entity sunmtttmg sworn statement] whose business address is and (if applicable) its Federal Employer Identification Number (FEIN) is (If the entity has no FEIN, include the Social Security Number of the individual signing this sworn statement: 2. I understand that a "public entity crime" as defined in Paragraph 287.133(1)(g), Florida Statutes, means a violation of any state or federal law by a person with respect to and directly related to the transaction of business with any public entity or with an agency or political subdivision of any other state or of the United States, including, but not limited to, any bid or contract for goods or services to be provided to any public entity or an agency or political subdivision of any other state or of the United States and involving antitrust, fraud, theft, bribery, collusion, racketeering, conspiracy, or material misrepresentation. 3. I understand that "convicted" or "conviction" as defined in Paragraph 287.133(1)(b), Florida Statues, means a finding of guilt or a conviction of a public entity crime, with or without an adjudication of guilt, in any federal or state trial court of record relating to charges brought by indictment or information after July 1, 1989, as a result of a jury verdict, nonjury trial, or entry of a plea of guilty or nolo contendere. 4. I understand that an "affiliate" as defined in Paragraph 287.133(1)(a), Florida Statutes, means: 1. A predecessor or successor of a person convicted of a public entity crime; or 2. An entity under the control of any natural person who is active in the management of the entity and who has been convicted of a public entity crime. The term "affiliate" includes those officers, directors, executives, partners, shareholders, employees, members, and agents who are active in the management of an affiliate. The ownership by one person of shares constituting a controlling interest in another person, or a pooling of equipment or income among persons when not for fair market value under an arm's length agreement, shall be a prima facie case that one person controls another person. A person who knowingly enters into a joint venture with a person who has been convicted of a public entity crime in Florida during the preceding 36 months shall be considered an affiliate. I understand that a "person" as defined in Paragraph 287.133(1)(e), Florida Statutes, means any natural person or entity organized under the laws of any state or of the United States with the legal power to enter into a binding contract and which bids or applies to bid on contracts for the provision of goods or services let by a public entity, or which otherwise transacts or applies to transact business with a public entity. The term "person" includes those officers, directors, executives, partners, shareholders, employees, members, and agents who are active in management of an entity. Form PUR 7068 (Rev. 06/11/92) 00402 -1 181s" ACTIVE PARK APRIL 10, 2005 6. Based on information and belief, the statement which I have marked below is true in relation to the entity submitting this sworn statement. [Indicate which statement applies] Neither the entity submitting this sworn statement, nor any of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity, nor any affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1, 1989. The entity submitting this sworn statement, or one or more of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity, nor any affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1, 1989. The entity submitting this sworn statement, or one or more of its officers, directors, executives, partners, shareholders, employees, members, or agents who are active in the management of the entity, nor any affiliate of the entity has been charged with and convicted of a public entity crime subsequent to July 1, 1989. However, there has been a subsequent proceeding before a Hearing Officer of the State of Florida, Division of Administrative Hearings and the Final Order entered by the Hearing Officer of the State of Florida, Division of Administrative Hearings and the Final Order entered by the Hearing Officer determined that it was not in the public interest to place the entity submitting this sworn statement on the convicted vendor list. [attach a copy of the final order] I UNDERSTAND THAT THE SUBMISSION OF THIS FORM TO THE CONTRACTING OFFICER FOR THE PUBLIC ENTITY IDENTIFIED IN PARAGRAPH 1 (ONE) ABOVE IS FOR THAT PUBLIC ENTITY ONLY AND, THAT THIS FORM IS VALID THROUGH DECEMBER 31 OF THE CALENDAR YEAR IN WHICH IT IS FILED. I ALSO UNDERSTAND THAT I AM REQUIRED TO INFORM THE PUBLIC ENTITY PRIOR TO ENTERING INTO A CONTRACT IN EXCESS OF THE CATEGORY TWO OF ANY CHANGE N THE INFORMATION CONTAINED N THIS FORM. FOR Sworn to and subscribed before me this day of Personally known OR Produced identification (Type of identification) Form PUR 7068 (Rev. 06/11/92) [signature] 20 Notary Public - State of My commission expires (Printed typed or stamped commissioned name of notary public) 00402 -2 18187 ACTIVE PARK DOCUMENT 00403 TRENCH SAFETY ACT (90 -96, Laws of Florida) APRIL 10, 2005 Bidder acknowledges that included in the appropriate bid items of the proposal and in the Total Bid Price are costs for complying with the Florida Trench Safety Act (90 -96, Laws of Florida) effective October 1, 1990. The bidder further identifies the costs of such compliance to be summarized below: Trench Safety Unit of Unit Unit Extended Measure Measure (Quantity) Cost Cost (Description) (L--SF) A. B. C. D. Total $ If applicable, the Contractor certifies that all trench excavation done within his control in excess of five feet in depth shall be in accordance with the Florida Department of Transportation's Special Provisions Article 125 -1 and Subarticle 125 -4.1 (TRENCH EXCAVATION SAFETY SYSTEM AND SHORING, SPECIAL - TRENCH EXCAVATION). Failure to complete the above may result in the bid being declared non - responsive. Contractor agrees that the above safety compliances and costs are included in his bid package. Signature of Bidding Contractor END OF DOCUMENT TRENCH SAFETY ACT 00403 -1 181sT ACTIVE PARK THIS PAGE INTENTIONALLY LEFT BLANK. TRENCH SAFETY ACT APRIL 10, 2005 00403 -2 181 ST ACTIVE PARK APRIL 10, 2005 DOCUMENT 00420 INFORMATION REQUIRED FROM BIDDERS GENERAL INFORMATION The Bidder shall furnish the following information. Failure to comply with this requirement may cause its rejection. Additional sheets shall be attached as required. 1. Contractor's Name /Address: 2. 3. Contractor's Telephone Number: Contractor's License: Frimary Giassirication: 4. Number of years as a Contractor in construction work of the type involved in this Contract: 5. List the names and titles of all officers of Contractor's firm: A 7. Name of person who inspected site or proposed work for your firm: Name: Date of Inspection: What is the last project of this nature you have completed? 8. Have you ever failed to complete work awarded to you; if so, where and why? INFO REQUIRED FROM BIDDERS 00420 -1 181ST ACTIVE PARK APRIL 10, 2005 g. Name three individuals or corporations for which you have performed work and to which you refer: 10. List the following information concerning all contracts on hand as of the date of submission of this proposal. (In case of co- venture, list the information for all co- ventures). NAME TOTAL CONTRACTED % OF CONTRACT DATE OF COMPLETION PROJECT CITY VALUE COMPLETION TO DATE (Continue list on inset sheet, if necessary) 11. What equipment do you own that is available for the work? 12. What equipment will you purchase for the proposed work? NOTE: Attach additional sheets if required. If requested by the City, the Bidder shall furnish a notarized financial statement, references and other information, sufficiently comprehensive to permit an appraisal of his current financial condition. INFO REQUIRED FROM BIDDERS 00420 -2 181sT ACTIVE PARK LIST OF SUBCONTRACTORS APRIL 10, 2005 The Bidder SHALL list below the name and address of each Subcontractor who will perform work under this Contract in excess of one -half percent of the total bid price, and shall also list the portion of the work which will be done by such Subcontractor. After the opening of Proposals, changes or substitutions will be allowed with written approval of the City of Sunny Isles Beach. Subcontractors must be properly licensed. Work to be Performed 2. 3. 4. 5. 1.11 7. 113 10 10. NOTE: Attach additional sheets if required. Subcontractor's Name /Address INFO REQUIRED FROM BIDDERS 00420 -3 181sT ACTIVE PARK THIS PAGE LEFT INTENTIONALLY BLANK. INFO REQUIRED FROM BIDDERS APRIL 10, 2005 00420 -4 181sT ACTIVE PARK EJCDC STANDARD FORM OF AGREEMENT BETWEEN OWNER AND CONTRACTOR ON THE BASIS OF A STIPULATED PRICE THIS AGREEMENT is dated as of the day of CITY OF SUNNY ISLES BEACH (hereinafter called OWNER) and (hereinafter called CONTRACTOR). APRILI0, 2005 in the year 20_ by and between OWNER and CONTRACTOR, in consideration of the mutual covenants hereinafter set forth, agree as follows: Article 1. WORK. CONTRACTOR shall complete all Work as specified or indicated in the Contract Documents. The Work is generally described as follows: Sealed bids for the construction of the 181" Drive Active Park, at 18115 North Bay Road, Sunny Isles Beach, Florida, 33160, consisting of a two (2) acres site to be developed as a public recreation area will be received by the Owner, City of Sunny Isles Beach. Work generally will consist of a baseball field with lighting, perimeter on- street parking, a new recreation center, a new gymnasium, landscape, infrastructure, and miscellaneous site amenities. Article 2. ENGINEER. The Project has been designed by: Miller, Legg & Associates, Inc. d/b /a Miller Legg 1800 N. Douglas Road, Suite 200 Pembroke Pines, Florida 33024 who is hereinafter called ENGINEER and who is to act as OWNER'S representative, assume all duties and responsibilities and have the rights and authority assigned to ENGINEER in the Contract Documents in connection with completion of the Work in accordance with the Contract Documents. Article 3. CONTRACT TIMES. 3.1. The Architectural Building work will be substantially completed within 365 calendar days after the date when the Contract Times commence to run and the Project Site work will be completed within 432 calendar days after the date when the Contract Times commence to run as provided in paragraph 2.3 of the General Conditions, and completed and ready for final payment in accordance with paragraph 14.07 of the General Conditions within 463 calendar days after the date when the Contract Times commence to run. 3.2. LIQU IDATED DAMAGES. OWNER and CONTRACTOR recognize that time is of the essence of this Agreement and that OWNER will suffer financial loss if the Work is not completed within the times specified in paragraph 3.1 above, plus any extensions thereof allowed in accordance with Article 12 of the General Conditions. They also recognize the delays, expense and difficulties involved in proving the actual loss suffered by OWNER if the Work is not completed on time. Accordingly, instead of requiring any such proof, OWNER and CONTRACTOR agree that as liquidated damages for delay (but not as a penalty) CONTRACTOR shall pay OWNER One Thousand Five Hundred and 00/100 dollars ($1500.00) for each day that expires after the time specified in paragraph 3.1 for each Substantial Completion date until the Work is substantially complete. If CONTRACTOR shall neglect, refuse or fail to complete the project by the project completion date within the time specified in paragraph 3.1 for completion and readiness for final payment or any proper extension thereof granted by OWNER, CONTRACTOR shall pay OWNER One Thousand and 00/100 dollars ($1000.00) for each day that expires after the time specified in paragraph 3.1 for completion and readiness for final payment. EJCDC STANDARD FORM OF AGREEMENT 00500 -1 181sT ACTIVE PARK Article 4. CONTRACT PRICE. APRILIO, 2005 OWNER shall pay CONTRACTOR for completion of the Work in accordance with the Contract Documents an amount in current funds equal to the sum of the amounts determined pursuant to paragraphs 4.1 and 4.2 below: 4.1. For all Site /Civil work other than Unit Price Work, a Lump Sum of: (use words) figures All specific cash allowances are included in the above price and have been computed in accordance with paragraph 11.02 of the General Conditions; plus 4.2. for all Unit Price Work, an amount equal to the sum of the established unit price for each separately identified item of Unit Price Work times the estimated quantity of that item as indicated in this paragraph 42 UNIT PRICE WORK For all Unit Price Work, (Refer to Exhibit "A" Unit Price Site /Civil Work Schedule) a Total Sum of: ($ ) (use words) figures For all Unit Price Work (Refer to Exhibit "B" Lump Sum Architectural Work Schedule) a Total Sum of: (use words) figures Ten Percent (10 %) Contingency Items (10% of total above items) ($ ) (use words) figures TOTAL BASE BID (Lump sum, Unit prices, and contingency items) (use words) figures As provided in paragraph 11.03 of the General Conditions estimated quantities are not guaranteed, and determinations of actual quantities and classification are to be made by ENGINEER as provided in paragraph 9.08 of the General Conditions. Unit prices have been computed as provided in paragraph 11.03.6 of the General Conditions. EJCDC STANDARD FORM OF AGREEMENT 00500 -2 181ST ACTIVE PARK Article 5. PAYMENT PROCEDURES. APRILI0, 2005 CONTRACTOR shall submit Applications for Payment in accordance with Article 14 of the General Conditions. Applications for Payment will be processed by ENGINEER as provided in the General Conditions. 5.1. Progress Payments; Retainage. OWNER shall make progress payments on account of the contract Price on the basis of CONTRACTOR's Applications for Payment as recommended by ENGINEER, on or about the last day of each month during construction as provided in paragraphs 5.1.1. and 5.1.2. below. All such payments will be measured by the schedule of values established in paragraph 2.07 of the General Conditions (and in the case of Unit Price Work based on the number of units completed) or, in the event there is no schedule of values, as provided in the General Requirements. 5.1.1. Prior to Substantial Completion, progress payments will be made in an amount equal to the percentage indicated below, but, in each case, less the aggregate of payments previously made and less such amounts as ENGINEER shall determine, or OWNER may withhold, in accordance with paragraph 14.02 of the General Conditions. 90 % of Work completed (with the balance being retainage). If Work has been 50% completed as determined by ENGINEER, and if the character and progress of the Work have been satisfactory to OWNER and ENGINEER, OWNER, on recommendation of ENGINEER, may determine that as long as the character and progress of the Work remain satisfactory to them, there will be no additional retainage on account of Work completed, in which case the remaining progress payments prior to Substantial Completion will be in an amount equal to 100% of the Work completed. 90 % (with the balance being retainage) of materials and equipment not incorporated in the Work (but delivered, suitably stored and accompanied by documentation satisfactory to OWNER as provided in paragraph 14.02 of the General Conditions and within Section 9 -6.5 partial payments as provided in FDOT Standard Specifications for Road and Bridge Construction. 5.1.2. When circumstances beyond the CONTRACTORS control arise (as determined by the OWNER) the OWNER may allow the total payment to the CONTRACTOR to increase to 98% of the contract price (with the balance being retainage), less such amounts as ENGINEER shall determine, only after receipt of the final as- builts and upon substantial completion of the project and in accordance with Paragraph 14.02 of the General Conditions. 5.2. Final Payment. Upon final completion and acceptance of the Work in accordance with paragraph 14.07 of the General Conditions, OWNER shall pay the remainder of the Contract Price as recommended by ENGINEER as provided in said paragraph 14.07. Article 6. INTEREST. (Not Applicable) Article 7. CONTRACTOR'S REPRESENTATIONS. In order to induce OWNER to enter into this Agreement CONTRACTOR makes the following representations: 7.1. CONTRACTOR has examined and carefully studied the Contract Documents (including the Addenda listed in paragraph 8) and the other related data identified in the Bidding Documents including "technical data." 7.2. CONTRACTOR has visited the site and become familiar with and is satisfied as to the general, local and site conditions that may affect cost, progress, performance or furnishing of the Work. EJCDC STANDARD FORM OF AGREEMENT 00500 -3 181sT ACTIVE PARK APRILI0, 2005 7.3. CONTRACTOR is familiar with and is satisfied as to all federal, state and local Laws and Regulations that may affect cost, progress, performance and furnishing of the Work. 7.4. CONTRACTOR has carefully studied all reports of explorations and tests of subsurface conditions at or contiguous to the site and all drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the site (except Underground Facilities) which have been identified in the Supplementary Conditions as provided in paragraph 4.2.1. of the General Conditions. CONTRACTOR accepts the determination set forth in paragraph SC -4.2 of the Supplementary Conditions of the extend of the "technical data" contained in such reports and drawings upon which CONTRACTOR is entitled to rely as provided in paragraph 4.2 of the General Conditions. CONTRACTOR acknowledges that such reports and drawings are not Contract Documents and may not be complete for CONTRACTOR's purposes. CONTRACTOR acknowledges that OWNER and ENGINEER do not assume responsibility for the accuracy or completeness of information and data shown or indicated in the Contract Documents with respect to Underground Facilities at or contiguous to the site. CONTRACTOR has obtained and carefully studied (or assumes responsibility for having done so) all such additional supplementary examinations, investigations, explorations, tests, studies and data concerning conditions (surface, subsurface and Underground Facilities) at or contiguous to the site or otherwise which may affect cost, progress, performance or furnishing of the Work or which relate to any aspect of the means, methods, techniques, sequences and procedures of construction to be employed by CONTRACTOR and safety precautions and programs incident thereto. CONTRACTOR does not consider that any additional examinations, investigations, explorations, tests, studies or data are necessary for the performance and furnishing of the Work at the contract Price, within the Contract Times and in accordance with the other terms and conditions of the Contract Documents. 7.5. CONTRACTOR is aware of the general nature of work to be performed by OWNER and others at the site that relates to the Work as indicated in the Contract Documents. 7.6. CONTRACTOR has correlated the information known to CONTRACTOR, information and observations obtained from visits to the site, reports and drawings identified in the Contract Documents and all additional examinations, investigations, explorations, tests, studies and data with the Contract Documents. 7.7. CONTRACTOR has given ENGINEER written notice of all conflicts, errors, ambiguities or discrepancies that CONTRACTOR has discovered in the Contract Documents and the written resolution thereof by ENGINEER is acceptable to CONTRACTOR, and the Contract Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performance and furnishing of the Work. Article 8. CONTRACT DOCUMENTS. The Contract Documents which comprise the entire agreement between OWNER and CONTRACTOR concerning the Work consist of the following: 8.1. This Agreement (pages 1 to 9 inclusive). 8.2. Exhibits to this Agreement (page) inclusive). 8.3. Performance, Payment, and other Bonds, identified as exhibits 00600 and 00601 and consisting of 4 pages. 8.4. Notice to Proceed. 8.5. General Conditions (pages 00700 -1 to 00700 -42. inclusive). 8.6. Supplementary Conditions (pages 00800 -1 to 00800 -7, inclusive). 8.7. Specifications bearing the title 1819t Drive Active Park Project Manual Vol. 1 & 2 and consisting of 16 divisions. EJCDC STANDARD FORM OF AGREEMENT 00500 -4 181 " ACTIVE PARK APRILI0, 2005 8.8. Drawings consisting of a cover sheet and sheets numbered as specified in the Drawing Index INX -1. 8.9. Addenda , inclusive. 8.10. CONTRACTOR's Bid (pages inclusive). 8.11. Documentation submitted by CONTRACTOR prior to Notice of Award (pages N/A to inclusive). 8.12. The following which may be delivered or issued after the Effective Date of the Agreement and are not attached hereto: All Written Amendments and other documents amending, modifying or supplementing the Contract Documents pursuant to paragraph 3.04 of the General Conditions. The documents listed in paragraphs 8.2 et seq. above are attached to this Agreement (except as expressly noted otherwise above). There are no Contract Documents other than those listed above in this Article 13. The Contract Documents may only be amended, modified or supplemented as provided in paragraph 3.04 of the General Conditions. Article 9. MISCELLANEOUS. 9.1. Terms used in this Agreement which are defined in Article 1 of the General Conditions will have the meanings indicated in the General Conditions. 9.2. No assignment by a party hereto of any rights under or interests in the Contract Documents will be binding on another party thereto without the written consent of the party sought to be bound; and, specifically but without limitation, moneys that may become due and moneys that are due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents. 9.3. OWNER and CONTRACTOR each binds itself, its partners, successors, assigns and legal representatives to the other party hereto, its partners, successors, assigns and legal representatives in respect to all covenants, agreements and obligations contained in the Contract Documents. 9.4. Any provisions or part of the Contract Documents held to be void or unenforceable under any Law or Regulation shall be deemed stricken, and all remaining provisions shall continue to be valid and binding upon OWNER and CONTRACTOR, who agree that the Contract Documents shall be reformed to replace such stricken provisions or part thereof with a valid and enforceable provision that comes as close as possible to expressing the intention of the stricken provision. 9.5. OTHER PROVISIONS. 9.5.1. DRAWINGS 181ST DRIVE ACTIVE PARK, 18115 NORTH BAY ROAD BID NO. 05 -04 -01 (ML Project No. 114122) EJCDC STANDARD FORM OF AGREEMENT 00500 -5 181 ST ACTIVE PARK DESCRIPTION SHEET NO. NOTE: REFER TO INDEX OF DRAWINGS INX -1 APRILI0, 2005 9.5.2. The CONTRACTOR agrees to indemnify and save harmless the CITY OF SUNNY ISLES BEACH, AND MILLER LEGG and their agents and employees, from or on account of any injuries or damages received or sustained by any person or person during or on account of any operations connected with the construction of these roadway improvements; or by or in consequence of any negligence in connection with the same; or by use of any improper materials or by or on account of any act or omission of the said Contractor, subcontractor, agents, servants, or employees; and 9.5.3. The CONTRACTOR agrees to maintain in force at all times during the life of the construction, public liability insurance, by separate certificate, in an amount not less than $1,000,000 for injuries, including willful death, to any one person and subject to those same limits for each person, in an amount not less that $1,000,000 for damages as a result of each occurrence and property damage insurance and in an amount not less than $1,000,000 for damages on any one occurrence. Such policy shall specifically protect the CITY OF SUNNY ISLES BEACH, AND MILLER LEGG their agents and employees, by making them an additional insured, and shall not be modified or canceled without thirty (30) days written notice to the CITY OF SUNNY ISLES BEACH. 9.5.4 Should the final completion and acceptance of the work herein embraced together with any modification or additions be delayed beyond the time herein set because of lace of performance by the Contract, it is understood and agreed that aside from any other liquidated damage per day for such delay from such time until the work is completed and accepted as herein provided, all costs of engineering and inspection on behalf of the Owner will be charged to the contractor and deducted from any estimate or payment otherwise due and payable to him from time to time. The costs of engineering and inspection which may be charged to the Contractor by the Owner under this article shall be equal to the Engineer's charges to the Owner. IN WITNESS WHEREOF, OWNER and CONTRACTOR have signed this Agreement in Five (5) parts. One counterpart each has been delivered to OWNER, CONTRACTOR and ENGINEER. All portions of the Contract Documents have been signed, initialed or identified by OWNER and CONTRACTOR or identified by ENGINEER on their behalf. This Agreement will be effective on , 20_ (which is the Effective Date of the Agreement). ATTEST: [CORPORATE SEAL] Address for giving notices By [CORPORATE SEAL] License No. Agent for service of process EJCDC STANDARD FORM OF AGREEMENT 00500 -6 181"ACTIVE PARK APRILI0, 2005 (If CONTRACTOR is a corporation, attached evidence of authority to sign). SIGNATURE PAGE FOR CONTRACTS /AGREEMENTS CITY EXECUTIONS IN WITNESS WHEREOF, the parties hereto have made and executed this (Agreement or Contract) on the respective dates under each signature: City of Sunny Isles Beach through its City Commission, signing by and through its Mayor, authorized to execute same by Commission action on the day of ; and CONTRACTOR authorized to execute same. ATTEST: Jane Hines, City Clerk Approved as to form and legality by By: Office of the City Attorney 0 Lynn M. Dannheisser, City Attorney day of ,20 -- CITY OF SUNNY ISLES BEACH, through its City Commission Norman S. Edelcup, Mayor day of ,20 -- Christopher J. Russo, City Manager day of (CITY SEAL) 20 -- EJCDC STANDARD FORM OF AGREEMENT 00500 -7 181sT ACTIVE PARK CERTIFICATE AS TO CORPORATE PRINCIPAL M that Dade County Florida for is behalf of the Corporation. Signed and sealed this (SEAL) STATE OF FLORIDA COUNTY OF DADE APRIL10, 2005 certify that I am the of and who signed the Bid with City of Sunny Isles, , City Bid No. f of said Corporation with full authority to sign said Bid on day of � 20 -- Signature Typed w/Title SWORN TO AND SUBSCRIBED before me this _ day of 120-- My Commission Expires: Notary Public EJCDC STANDARD FORM OF AGREEMENT 00500 -8 181ST ACTIVE PARK APRIL 10, 2005 Construction Payment Bond Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. CONTRACTOR (Name and Address): SURETY (Name and Principal Place of Business): OWNER (Name and Address): CITY OF SUNNY ISLES BEACH 18070 Collins Avenue Sunny Isles Beach, Florida 33160 CONSTRUCTION CONTRACT Date: Amount: $ Description (Name and Location): PROJECT NAME City of Sunny Isles Beach BOND Date (Not earlier than Construction Contract Date): Amount: $ Modifications to this Bond Form: CONTRACTOR AS PRINCIPAL SURETY Company (Corp. Seal) Company Signature: Signature: Name and Title: Name and Title: CONTRACTOR AS PRINCIPAL SURETY Company (Corp. Seal) Company Signature: Name and Title: EJCDC No. 1910 -28B (1984 Edition) Signature: Name and Title: Prepared through the joint efforts of the Surety Association of America, Engineers' Joint Contract Documents Committee, The Associated General Contractors of America, Institute of Architects, American Subcontractors Association, and the Associated Specialty Contractors. (Corp. Seal) (Corp. Seal) 00600 -1 181sT ACTIVE PARK I . The Contractor and the Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. 2. With respect to the Owner, this obligation shall be null and void if the Contractor: 2.1. Promptly makes payment, directly or indirectly, for all sums due Claimants, and 2.2. Defends, indemnifies and holds harmless the Owner from all claims, demands, liens or suits by any person or entity who furnished labor, materials or equipment for use in the performance of the Construction Contract, provided the Owner has promptly notified the Contractor and the Surety (at the address described in Paragraph 12) of any claims, demands, liens or suits and tendered defense of such claims, demands, liens or suits to the Contractor and the Surety, and provided there is no Owner Default. 3. With respect to Claimants, this obligation shall be null and void if the Contractor promptly makes payment, directly or indirectly, for all sums due. 4. The Surety shall have no obligation to Claimants under this Bond until: 4.1. Claimants who are employed by or have a direct contract with the Contractor have given notice to the Surety (at the address described in Paragraph 12) and sent a copy, or notice thereof, to the Owner, stating that a claim is being made under this Bond and, with substantial accuracy, the amount of the claim. 4.2. Claimants who do not have a direct contract with the Contractor: 1. Have furnished written notice to the Contractor and sent a copy, or notice thereof, to the Owner, within 90 days after having last performed labor or last finished materials or equipment included in the claim stating, with substantial accuracy, the amount of the claim and the name of the party to whom the materials were furnished or supplied or for whom the labor was done or performed: and 2. Have either received a rejection in whole or in part from the Contractor, or not received within 30 days of furnishing the above notice any communication from the Contractor by which the Contractor has indicated the claim will be paid directly or indirectly: and 3. Not having been paid within the above 30 days, have sent a written notice to the Surety (at the address described in paragraph 12) and sent a copy, or notice thereof, to the Owner, stating that a claim is being made under this Bond and enclosing a copy of the previous written notice famished to the Contractor. 5. If a notice required by Paragraph 4 is given by the Owner to the Contractor or to the Surety, that is sufficient compliance. 6. When the Claimant has satisfied the conditions of Paragraph 4, the Surety shall promptly and at the Surety's expense take the following actions: 6.1. Send an answer to the Claimant, with a copy to the Owner, within 45 days after receipt of the claim, stating the amounts that are undisputed and the basis for challenging any amounts that are disputed. 6.2. Pay or arrange for payment of any undisputed amounts. 7. The Surety's total obligation shall not exceed the amount of this Bond, and the amount of this Bond shall be credited for any payments made in good faith by the Surety. 8. Amounts owned by the Owner to the Contractor under the Construction Contract shall be used for the performance of the Construction Contract and to satisfy claims, if any, under any Construction Performance Bond. By the APRIL 10, 2005 Contractor furnishing and the Owner accepting this Bond, they agree that all funds earned by the Contractor in the performance of the Construction Contract are dedicated to satisfy obligations of the Contractor and the Surety under this Bond, subject to the Owner's priority to use the funds for the completion of the work. 9. The Surety shall not be liable to the Owner, Claimants or others for obligations of the Contractor that are unrelated to the Construction Contract. The Owner shall not be liable for payment of any costs or expenses of any Claimant under this Bond, and shall have under this Bond no obligations to make payments to, give notices on behalf of, or otherwise have obligations to Claimants under this Bond. 10. The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to relate subcontracts, purchase orders and other obligations. 11. No suit or action shall be commenced by a Claimant under this Bond other than in a court of competent jurisdiction in the location in which the work or part of the work is located or after the expiration of one year from the date (1) on which the Claimant gave the notice required by Subparagraph 4.1 or Clause 4.2 (iii), or (2) on which the last labor or service was performed by anyone or the last materials or equipment were furnished by anyone under the construction Contract, whichever of (1) or (2) fast occurs. If the provisions of this Paragraph are void or prohibited by law, the minimum period of limitation available to sureties as a defense in the jurisdiction of the suit shall be acceptable. 12. Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the signature page. Actual receipt of notice by Surety, the Owner or the Contractor, however accomplished, shall be sufficient compliance as of the date received at the address shown on the signature page. 13. When this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. The intent is, that this Bond shall be construed as a statutory bond and not as a common law bond. 14. Upon request by any person or entity appearing to be a potential beneficiary of this Bond, the Contractor shall promptly furnish a copy of this Bond or shall permit a copy to be made. 15. DEFINITIONS 15.1. Claimant: An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, materials or equipment for use in the performance of the Contract. The intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment" that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were furnished. 15.2. Construction Contract: The agreement between the Owner and the Contractor identified on the signature page, including all Contract Documents and changes thereto. 15.3. Owner Default: Failure of the Owner, which has neither been remedied nor waived, to pay the Contractor as required by the Construction Contract or to perform and complete or comply with the other terms thereof. (FOR INFORMATION ONLY —Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or other party): 00600 -2 EJCDC No. 1910 -28B (1984 Edition) Prepared through the joint efforts of the Surety Association of America, Engineers' Joint Contract Documents Committee, The Associated General Contractors of America, American Institute of Architects, American Subcontractors Association, and the Associated Specialty Contractors. 181" ACTIVE PARK DRIVE APRIL 10, 2005 Construction Performance Bond Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. CONTRACTOR (Name and Address): SURETY (Name and Principal Place of Business): OWNER (Name and Address): CITY OF SUNNY ISLES BEACH 18070 Collins Avenue Sunny Isles Beach, Florida 33160 CONSTRUCTION CONTRACT Date: Amount: $ Description (Name and Location): PROJECT NAME City of Sunny Isles Beach BOND Date (Not earlier than Construction Contract Date): Amount: $ Modifications to this Bond Form: CONTRACTOR AS PRINCIPAL SURETY Company (Corp. Seal) Company (Corp. Seal) Signature: Signature: Name and Title: Name and Title: CONTRACTOR AS PRINCIPAL SURETY Company (Corp. Seal) Company (Corp. Seal) Signature: Signature: Name and Title: Name and Title: EJCDC No. 1910 -28A (1984 Edition) 00601_1 Prepared through the joint efforts of the Surety Association of America, Engineers' Joint Contract Documents Committee, The Associated General Contractors of America, American Institute of Architects, American Subcontractors Association, and the Associated Specialty Contractors. 181sT ACTIVE PARK DRIVE 1. The Contractor and the Surety, jointly and severally, bind themselves, their heirs, executors, administrators, successors and assigns to the Owner for the performance of the Construction Contract, which is incorporated herein by reference. 2. If the Contractor performs the Construction Contract, the Surety and the Contractor shall have no obligation under this Bond, except to participate in conferences as provided in Subparagraph 3.1. 3. If there is no Owner Default, the Surety's obligation under this Bond shall arise after: 3.1. The Owner has notified the Contractor and the Surety at its address described in Paragraph 10 below, that the Owner is considering declaring a Contractor Default and has requested and attempted to arrange a conference with the Contractor and the Surety to be held not later than fifteen days after receipt of such notice to discuss methods of performing the Construction Contract. If the Owner, the Contractor and the Surety agree, the Contractor shall be allowed a reasonable time to perform the Construction Contract, but such an agreement shall not waive the Owner's right, if any, subsequently to declare a Contractor Default: and 3.2, The Owner has declared a Contractor Default and formally terminated the Contractor's right to complete the contract. Such Contractor Default shall not be declared earlier than twenty days after the Contractor and the Surety have received notice as provided in Subparagraph 3.1: and 3.3. The Owner has agreed to pay the Balance of the Contract Price to the Surety in accordance with the terms of the Construction Contract or to a contractor selected to perform the Construction Contract in accordance with the terms of the contract with the Owner. 4. When the Owner has satisfied the conditions of Paragraph 3, the Surety shall promptly and at the Surety's expense take one of the following actions: 4.1. Arrange for the Contractor, with consent of the Owner, to perform and complete the Construction Contract: or 4.2. Undertake to perform and complete the Construction Contract itself, through its agents or through independent contractors: or 4.3. Obtain bids or negotiated proposals from qualified contractors acceptable to the Owner for a contract for performance and completion of the Construction Contract, arrange for a contract to be prepared for execution by the Owner and the contractor selected with the Owner's concurrence, to be secured with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the Construction Contract, and pay to the Owner the amount of damages as described in Paragraph 6 in excess of the Balance of the Contract Price incurred by the Owner resulting from the Contractor's default: or 4.4. Waive its right to perform and complete, arrange for completion, or obtain a new contractor and with reasonable promptness under the circumstances: 1. After investigation, determine the amount for which it may be liable to the Owner and, as soon as practicable after the amount is determined, tender payment therefor to the Owner: or 2. Deny liability in whole or in part and notify the Owner citing reasons therefor. 5. If the Surety does not proceed as provided in Paragraph 4 with reasonable promptness, the Surety shall be deemed to be in default on this Bond fifteen days after receipt of an additional written notice from the Owner to the Surety demanding that the Surety perform its obligations under this Bond, and the Owner shall be entitled to enforce any remedy available to the Owner. If the Surety proceeds as provided in Subparagraph 4.4, and the Owner refuses the payment tendered or the Surety has denied liability, in whole or in part, without APRIL 10, 2005 further notice the Owner shall be entitled to enforce any remedy available to the Owner. 6. After the Owner has terminated the Contractor's right to complete the Construction Contract, and if the Surety elects to act under Subparagraph 4.1, 4.2, or 4.3 above, then the responsibilities of the Surety to the Owner shall not be greater than those of the Contractor under the Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the Owner under the Construction Contract. To the limit of the amount of this Bond, but subject to commitment by the Owner of the Balance of the Contract Price to mitigation of costs and damages on the Construction Contract, the Surety is obligated without duplication for: 6.1. The responsibilities of the Contractor for correction of defective work and completion of the Construction Contract: 6.2. Additional legal, design professional and delay costs resulting from the Contractor's Default, and resulting from the actions or failure to act of the Surety under Paragraph 4: and 6.3. Liquidated damages, or if no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance or non - performance of the Contractor. 7. The Surety shall not be liable to the Owner or others for obligations of the Contractor that are unrelated to the Construction Contract, and the Balance of the Contract Price shall not be reduced or set off on account of any such unrelated obligations. No right of action shall accrue on this Bond to any person or entity other than the Owner or its heirs, executors, administrators, or successors. 8. The Surety hereby waives notice of any change, including changes of time, to the Construction Contract or to related subcontracts, purchase orders and other obligations. 9. Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the location in which the work or part of the work is located and shall be instituted within two years after Contractor Default or within two years after the Contractor ceased working or within two years after the Surety refuses or fails to perform its obligations under this Bond, whichever occurs fast. If the provisions of limitation available to sureties as a defense in the jurisdiction of the suit shall be applicable. 10. Notice to the Surety, the Owner or the Contractor shall be mailed or delivered to the address shown on the signature page. 11. When this Bond has been famished to comply with a statutory or other legal requirement in the location where the construction was to be performed, any provision in this Bond conflicting with said statutory or legal requirement shall be deemed deleted herefrom and provisions conforming to such statutory or other legal requirement shall be deemed incorporated herein. The intent is that this Bond shall be construed as a statutory bond and not as a common law bond. 12. Definitions. 12.1. Balance of the Contract Price: The total amount payable by the Owner to the Contractor under the Construction Contract after all proper adjustments have been made, including allowance to the Contractor of any amounts received or to be received by the Owner in settlement of insurance or other claims for damages to which the Contractor is entitled, reduced by all valid and proper payments made to or on behalf of the Contractor under the Construction Contract. 12.2. Construction Contract: The agreement between the Owner and the Contractor identified on the signature page, including all Contract Documents and changes thereto. 12.3. Contractor Default: Failure of the Contractor, which has neither been remedied nor waived, to perform or otherwise to comply with the terms of the Construction Contract. 12.4. Owner Default: Failure of the Owner, which has neither been remedied nor waived, to pay the Contractor as required by the Construction Contract or to perform and complete or comply with the other terms thereof. (FOR INFORMATION ONLY —Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or other party): 00601 -2 EJCDC No. 1910 -28A (1984 Edition) Prepared through the joint efforts of the Surety Association of America, Engineers' Joint Contract Documents iati n , n d Committee, The Associated General Contractors of America, American Institute of Architects, American Subcontractors Association, and the Associated Specialty Contractors. 181ST ACTIVE PARK DOCUMENT 00650 ACKNOWLEDGEMENT OF CONFORMANCE WITH O.S.H.A. STANDARDS TO THE CITY OF SUNNY ISLES BEACH APRIL 10, 2005 We acknowledge and agree that as contractors for the construction of the "181 T DRIVE ACTIVE PARK, 18115 NORTH BAY ROAD ", that we have the sole responsibility for compliance with all requirements of the Federal Occupational Safety and Health Act of 1970, and all State and Local Safety and Health regulations, and agree to indemnify and hold harmless the City of Sunny Isles Beach, and Miller, Legg & Associates, Inc. against any and all legal liability or loss the District or the Engineer may incur due to failure to comply with such act. ATTEST CONTRACTOR By: ATTEST Title: DATE END OF DOCUMENT ACKNOWLEDGEMENT OF OSHA STANDARDS 00650 -1 181sT ACTIVE PARK THIS PAGE LEFT INTENTIONALLY BLANK. ACKNOWLEDGEMENT OF OSHA STANDARDS APRIL 10, 2005 00650 -2 This document has important legal consequenceS; consultation with an attorney is encouraged with respect to its use or modification. This document should be adapted to the particular circumstances of the contemplated Project and the Controlling Law. STANDARD GENERAL CONDITIONS OF THE CONSTRUCTION CONTRACT Prepared by ENGDMM JOINT CONTRACT DOCUMENTS COMM ME and 0,11 Issued and Published Jointly By National Society of Professional Engineers AM AMERICAN CONSULTING Pro/esskmi Engineers in P*WPradke AMERICAN SOCIETY OF ENGINEERS COUNCIL CIVIL ENGINEERS PROFESSIONAL ENGINEERS IN PRIVATE PRACTICE a practice division of the NATIONAL SOCIETY OF PROFESSIONAL ENGINEERS AMERICAN CONSULTING ENGINEERS COUNCIL AMERICAN SOCIETY OF CIVIL ENGINEERS Ibis document has been approved and endorsed by Associated General t Contractors of America Construction Specifications Institute 1V*w These GeneW Condtdom have been prepared for use with the Owner- C,ontrctm A (No 1910 -8-A -1 or 1910 - 8-A-2) (1996 Editions). Their provisions a1e interrelated sad a change in one may necessitate a change in the other. P their usage are contained in the EICDC User's Guide (No. 1910 - For uPPlemewarY Conditions, see Guide to the Preparation �' da°1 m the ( 1996 Edition). of �PP3' C�ditions (No. 1910 -17) EJCDC No. 1910 -8 (1996 Edition) Copyright 01996 National Society of Professional Engineer: 1420 King Street, Alexandria, VA 22314 American Consulting Eogmew CotmcH 101515th Street N.W.. WAdd gtM DC 20005 American Society of Civil Engiaoers 345 Fast 47th Street, New York, NY 10017 TABLE OF CONTENTS Pam ARTICLE 1 - DEFINITIONS AND TERMINOLOGY 1.01 Defined Terms ........... 00700-6 1.02 Terminology ...................... ............................... 00700 - 6 ARTICLE 2 - PRELIMINARY MATTERS .. .. 00700-8 2.01 Delivery of Bonds ........... _ .. 00700-9 2.02 Copies of Documents 00700-9 2.03 Commencement of Contract Temes; Notice to Proceed . • • • • . • . ' ........ ' ......... 00700-9 2.04 Starting the Work .......................... 00700-9 2.05 Before Starting Construction 00700-9 2.06 Preconstruction Conference .......... ..... 00700-9 2.07 Initial Acceptance of Schedules . ............................... 00700-10 ARTICLE 3 - CONTRACT DOCUMENTS: INTENT, AMENDING • . • . � ........ ' ........ ' . ' 00700-10 3.01 Intent ......... .REUSE ............. 00700-10 3.02 Reference Standards ........ ...... ..... ... 00700-10 3.03 Reporting and Resolving Discrepancies . ............. .... ...... .... 00700-10 3.04 Amending and Supplementing ..... ..........................00700-11 uPP g Contract Documents 00700-11 3.05 Reuse of Documents ........ • ......................... . ARTICLE 4 - AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; • 00700-11 REFERENCE POINTS 4.01 Availability of Lands .......... .. .. .. .... 00700-11 4.02 Subsurface and Physical Conditions .......... 00700 - 11 4.03 Differing Subsurface or physical Conditions . ............... ' ... ' . ' ... ' 00700-12 4.04 Underground Facilities ......... .. .. .. 00700-12 4.05 Reference Points .......... ..... 00700-13 4.06 Hazardous Environmental Condition at Site .. .. .. 00700-13 ARTICLE 5 - BONDS AND INSURANCE ..... , .. .. ....... 00700-14 5.01 Performance, P ment ....... ... ..... ... .. ... 00706-15 ay ,and Other Bonds .. 5.02 Licensed Sureties and Insurers ................. . 00700-15 5.03 Certificates of bsurance ......... ............................... 00700-15 5.04 CONIIZlCTOR's Liability Ireswance ...... ............................... 00700-15 5.05 OWIVER's liability Insurance . .................... 00700-15 5.06 Property Insu wzce ......... ............................... 00700-16 5.07 Waives of Rights .. ............................... 00700-16 5.08 Receipt and Appli vdm of bts wwr Proceeds' .............................. 00700-17 5.09 Acceptance of Bonds and Lcsuraarux Option to �l� ......................... 00700-18 5.10 Partial Utilization, Aabiowkdgment of property, Insurer ........................ 00700-18 ARTICLE 6 - CONTRACTOR'S RESPONSIBILITIES ....................... 00700-18 6.01 Supervision and SrSperintendenee . ....... ' ........................... 00700 - 18 6.02 Labor, Wonting Hours 00700-18 6.03 Services. Materials, and Equipment . ' .... .........• ...................... ...................... 00700-19 6.04 Progress Schedule 00700-19 6.05 Substitutes and " Or- F, quals . ........................... 00700 - 19 6.06 Concerning Subcontractors. Suppliers, and Others ............................ 00700-19 6.07 Pazm Feu and Royalties .. ........................... 00700- 20 6.06 Permits ...... .......... ............................... 00700 - 21 6.09 Laws and Reguladau ............................... .............00700 - 21 6.10 Tara .. ............................... ....................... 00700 -22 6.11 Use of Sits and OlherAraos .............- ............. ..............00700 - 22 6.12 Record Doeutnarts ........ ..........� .......................... 00700 -22 6.13 Safety and Protection ......... ............................... 00700 -22 6.14 Safety ReprasataAw ........ ............................... ..... 00700- 23 6.15 Hazard C mmmkation programs ....... ............................... 00700 .23 ...................... 00700. 23 00700-3 6.16 Emergencies ................................... 00700 -23 6.17 Shop Drawings and Samples ........... ............................... 00700 -23 6.18 Continuing the Work ............................... * * * * ....... 00700- 24 6.19 CopvMC7,OR's General Warranty and Guarantee .................... * .... 00700- 25 6.20 Indemnification ................... ............................... 00700- 25 WORK ............................... 00700- 26 ARTICLE 7 - OTHER 7.01 .................... Related Work at Site ................ ............................... 00700 -26 7.02 Coordination ................................... 00700- 26 ARTICLE 8 - OWNER'S RESPONSIBILITIES ................................. 00700- 26 8.01 Communications to Contractor ........................... ******** ..... 00700 -26 8.02 Replacement of ENGINEER ...... o ............. ...... 00700 -26 8.03 Furnish Data ............. o ...................... ...... 00700 -26 8.04 Pay Promptly When Due ............................ 0 ............... 00700 -26 8.05 Lands and Easements. Reports and Tests ...................... 00700- 26 00700 -27 8.06 Insurance ...................... ............................... 00700 -27 8.07 Change Orders .................................... -* ..... *** ..... 00700 -27 8.08 Inspections, Tests, and Approvals .............................. 00700 -27 8.09 Limitations on OWNER's Responsibilities ................................. 9.10 Undisclosed Hazardous Environmental Condition ................. *,*** ...... 00700- 27 8.11 Evidence of Financial Arrangements . - o ................ ...... 00700 -27 ARTICLE 9 - ENGINEER'S STATUS DURING CONSTRUCTION ........................... 00700- 27 9.01 OWNER'S Representative ........................................... 00700- 27 00700- 27 9.02 Visits to Site ........................................ **''*** ..... 00700 -27 9.03 Project Representative ................................ ** -* ......... ............. 00700- 28 9.04 Clarifications and Interpretations ....................... 00700 -28 9.05 Authorized Variations in Work ........................ ***''**,* ....... 00700- 28 9.06 Rejecting Defective Work .............................. 0**,*'*** ..... 00700 -28 9.07 Shop Drawings, Change Orders and Payments ..... o ................... ..... 00700 -28 9.08 Determinations for Unit Price Work ...... ............................... Decisions on Requirements of Contract Documents and Acceptability of Work .......... 00700 -28 9.09 9.10 Limitations on ENGVYEER's Authority and Responsibilities ...................... 00700- 28 ARTICLE 10 - CHANGES IN THE WORK; CLAIMS ................................... 00700 -29 00700- 29 10.01 Authorized Changes In the Work ........................ **,**,,*** ..... 00700 -29 10.02 Unauthorized Changes in the Work ...... ............................... 00700-29 10.03 Execution of Change Orders ........... ............................... 00700-29 10.04 Nodficadon to Surely ............... ............................... 00700 -30 10.05 ARTICLE 11- Claims and Disputes ........................... ................ COST OF THE WORK; CASH ALLOWANCES; UNIT PRICE WORK .............. 00700-30 00700 -30 11.01 Cost of the Work ................................................. 00700- 32 11.02 cash Allowances ............................ * ..... **"**'*"* ..... 00700- 32 11.03 ARTICLE 12 - Unit Price Work ................................. CHANGE OF CONTRACT PRICE; CHANGE OF CONTRACT TIMES ...... ............. 00706 -33 00700 -33 12.01 Change of Contract Price ............ ............................... 00700 -33 12.02 Change of Contract 11*0 ............ 0 .............................. CONMCTOR's Control 00700 -33 12.03 Delays Beyond ................................. 00700- 34 12.04 Delays Within CON7RACTOR's Control .................................. 's Control 00700 -34 12.05 Delays Beyond OW7M's and CONM CTOR ........................ 00700 34 12.06 ARTICLE 13 - Delay Damages .................................................. TESTS AND INSPECTIONS; CORRECTION. REMOVAL OR ACCEPTANCE OF 00700-34 DEFECTIVE WORK ................................... * * * , , * • 00700- 34 13.01 Notice of Defects .... ............................................. 00700 -34 13.02 Accts to Work ...................... I ........ * * ... * ............. 00700-34 13.03 Tests and Inspections ............... ............................... 00700 -35 13.04 Uncovering Work .................. ............................... 00700-35 13.05 OWNER May Stop Me Work .......................... ..... 00700 -35 13.06 Correction Or RemOvd Of Defective Work .. ............................... 00700 - 4 13.07 Correction Period 13.08 .. ............................... 00700 -35 Acceptance of Defective Wonlc ......... ............................... 13.09 00700 - 36 OWNER May Correct Defective Work . ARTICLE 14 - ................... 00700 - 36 PAYMENTS TO CONTRACTOR AND COMPLETION 14.01 ............. 00700 - 36 Schedule of Values . ............................... 14.02 00700 - 36 Progress Payments . ... ............................... 14.03 00700- 37 CONTRACTOR Is Warranty of Title ........... 14.04 ..........................00700 - 38 Substantial Completion ... ............................... 14.05 00700 -38 Partial Utilization ................. 14.06 ............................... 00700 -39 Final Inspection ................................................. 14.07 00700 -39 Final Payment ............. 14.08 ............................... 00700 -39 Final Completion Delayed ........................................... 14.09 Waiver of Claims ................................................. ..... 00700 -40 00700 -40 ARTICLE 15 - SUSPENSION OF WORK AND TERMINATION 15.01 ............................ -40 . • OWNER May Suspend Work . 15.02 ..... 00700-40 ............................. OWNER May Terminate for Cause ....... 15.03 ............................... 00700 -40 • • ... • OWNER May Terminate For Convenience 15.04 ................................. .. 00700-41 CONTRACTOR May Stop Work or Terminate ............... 00700-41 ARTICLE 16 - DISPUTE RESOLUTION - •00700-41 16.01 .. ............................... ... Methods and Procedures ........ 00700-41 ARTICLE 17 - MISCELLANEOUS 17.01 ..... ............................... ...... Giving Notice 00700 -42 17.02 ........ ............................... Computation of 77mes .... 00700- 42 17.03 ...... ......................... 00700-42 Cki nulative Remedies 17.04 ............... ............................... 00700- 42 Survival of Obligations ............................. .......... 17.05 00700- 42 Controlling Law .................. ............................... 00700 -42 r 00700-5 GENERAL CONDITIONS ARTICLE I - DEFINITIONS AND TERMINOLOGY 1.01 Defined Terns A. Wherever used in the Contract Documents and printed with initial or all capital letters, the terms listed below will have the meanings indicated which are applicable to both the singular and plural thereof. 1. Addenda -- Written or graphic instruments issued prior to the opening of Bids which clarify, correct, or change the Bidding Requirements or the Contract Documents. 2. Agreement —The written instrument which is evidence of the agreement between OWNER and CONTRACTOR covering the Work. 3. Application for Payment —The form acceptable to ENGINEER which is to be used by CONTRACTOR during the course of the Work in requesting progress or final payments and which is to be accompanied by such supporting documentation as is required by the Contract Documents. 4. Asbestos —Any material that contains more than one percent asbestos and is friable or is releasing asbestos fibers into the air above current action levels established by the United States Occupational Health Administration. S. Bid - ILe offer or proposal of a bidder stbmitted on the presexibed form setting forth the prices for the Work to be performed. 6. Bidding Documents —The Bidding Requirements and the proposed Contract Documents ("including all Addenda issued prior to receipt of Bids). 7. Bidding Requirements —The Advertisement or Invitation to Bid, Institutions to Bidders. Bid security form, if any, and the Bid form with any supplements. S. Bonds — Performance and payment bonds and other instruments of socirity. g. C7tange Order —A document recommended by ENGINEER which is signed by CONTRACTOR and OWNER and xwhorim sn addition, deletion, or revision in the Work or an ejoMeat in the Contract Price or the Contract Times, issued on or after the Effective Date of the Agreement. 10. Claim - -A demand or assertion by OWNER or CONTRACTOR seeking an adjustment of Contract Price or Contract Times, or both, or other relief with respect to the terms of the Contract. A demand for money or services by a third party is not a Claim. 11. Contract —The entire and integrated written agreement between the OWNER and CONTRACTOR concerning the Work. The Contract supersedes prior negotiations, representations, or agreements, whether written or oral. 12. Contract Documents —The Contract Documents establish the rights and obligations of the parties and include the Agreement, Addenda (which pertain to the Contract Documents), CONTRACTOR's Bid (including documentation accompanying the Bid and any post Bid documentation submitted prior to the Notice of Award) when attached as an exhibit to the Agreement, the Notice to Proceed, the Bonds, these General Conditions, the Supplementary Conditions, the Specifications and the Drawings as the same are more specifically identified in the Agreement, together with all Written Amendments, Change Orders, Work Change Directives, Field Orders, and ENGINEER's written interpretations and clarifications issued on or after the Effective Date of the Agreement. Approved Shop Drawings and the reports and drawings of subsurface and physical conditions are not Contract Documents. only printed or hard copies of the items listed in-this paragraph ar+e•Ceotrad Doctments. Files In electronic media format -of text. data, graphics. and the like that may be furnished by OWNER to CONTRACTOR are not Contract Documents. 13. Contract Price —The moneys payable by OWNER to CONTRACTOR for completion of the Work in accordance with the Contract Documents as stated in the Agreement (subject to the provisions of paragraph 11.03 in the case of Unit Price Work). 14. Corarad 77ma —The number of days or the dates stated in the Agreement to: 0 achieve Substantial Completion; and (u) complete the Work so that it is ready for find payment as evidenced by ENGIN M's written ,recommendation of final payment. 00700.6 15. CONRACTOR —The individual or entity with whom OWNER has entered into the Agreement. i 16. Cost of the Work —See paragraph I LO L A for definition. 17. Drawings —That part of the Contract Documents prepared or approved by ENGINEER which graphically Shows the scope. extent, and character of the Work to be performed by CONTRACTOR. Shop Drawings and other CONTRACTOR submittals are not Drawings as so defined. 18. Effective Date of the Agreement - -The date indicated in the Agreement on which it becomes effective, but if no such date is indicated, it means the date on which the Agreement is signed and delivered by the last of the two parties to sign and deliver. 19. ENGINEER --The individual or entity named as such in the Agreement. 20. ENGMEER's Comsultant—An individual or entity having a contract with ENGINEER to furnish services as ENGINEER's independent professional associate or consultant with respect to the Project and who is identified as such in the Supplementary Conditions. 21. Field Order - -A written order issued by ENGI- NEER which requires minor changes in the Work but which does not involve a change in the Contract Price or the Contract Times. 22. General Requirements — Sections of Division 1 of the Specifications. The General Requirements pertain to all sections of the Specifications. 23. Hazardous Environmental Condition —The presence at the Site of Asbestos. PCBs, Petroleum, Hazardous Waste, or Radioactive Material in such quantities or circumstances that may present a substantial danger to persons or property exposed thereto in connection with the Work. 24. Hazardous Waste —The term Hazardous Waste shall have the meaning provided in Section 1004 of the Solid Waste Disposal Act (42 USC Section 6903) as amended from time to time. 25. Laws and Regulations; laws or Regulations —Any and all applicable lawn. toles, regulations, ordinances, codes, and orders of any and all governmental bodies, agencies, authorities, and courts having jurisdiction. 26. L ns-- Charges, security interests, or enwmbn»ces upon Prejoct funds, real property, or personal Property. 00700-7 27. Milestone —A principal event specified in the Contract Documents relating to an intermediate comple- tion date or time prior to Substantial Completion of all the Work. 28. Notice ofAwurd —The written notice by OWNER to the apparent successful bidder stating that upon timely compliance by the apparent successful bidder with the conditions precedent listed therein, OWNER will sign and deliver the Agreement. 29. Notice to Proceed - -A written notice given by OWNER to CONTRACTOR fixing the date on which the Contract Times will commence to run and on which CONTRACTOR shall start to perform the Work tinder the Contract Documents. 30. OWNER —The individual, entity, public body, or authority with whom CONTRACTOR has entered into the Agreement and for whom the Work is to be performed. 31. Partial Utilization —Use by OWNER of a substan- tially completed part of the Work for the purpose for which it is intended (or a related purpose) prior to Substantial Completion of all the Work. 32. PCBs — Polychlorinated biphenyls. 33. Petroleum — Petroleum, including crude oil or any fraction thereof which is liquid at standard conditions of temperature and P (60 degrees Fahrenheit and 14.7 pounds per square inch absolute). such as oil, petroleum, fuel Oil, oil sludge. Oil refuse, gasoline, kerosene, and oil mixed with other non - Hazardous Waste and crude oils. 34. Project- -The total construction of which the Wort to be performed under the Contract Documents may be the whole, or a part as may be indicated elsewhere in the Contract Documents. 35. Project Manual —The bound documentary information prepared for bidding and constructing the Work. A listing of the contents of the Project Manual, which may be bound in one or more volumes, is contained in the table(s) of contents. 36. Radiaac*w Material - ,Source, special nuclear, or byproduct material as defined by the Atomic Energy Act of 1954 (42 USC Section 2011 et seq.) as amended from time to time. r 37. RasUe rt Project Representative —The authorized reps+ SC= ve of ENGINEER who may be assigned to doe Site or any part thereof. 38. Samples— Physical examples of materials, equipment, or workmanship that are representative of some portion of the Work and which establish the standards by which such portion of the Work will be judged. 39. Shop Drawings —All drawings, diagrams, illustra- tions, schedules, and other data or information which are specifically prepared or assembled by or for CON- TRACTOR and submitted by CONTRACTOR to illustrate some portion of the Work. 40. Site - -Lands or areas indicated in the Contract Documents as being furnished by OWNER upon which the Work is to be performed, including rights -0f - -way and easements for access thereto, and such other lands furnished by OWNER which are designated for the use of CONTRACTOR. 41. Specifications —That part of the Contract Documents consisting of written technical descriptions of materials, equipment, systems, standards, and workmanship as applied to the Work and certain administrative details applicable thereto. 42. Subcontractor - -An individual or entity having a direct contract with CONTRACTOR or with any other Subcontractor for the performance of a part of the Work at the Site. 43. Substantial Completion —The time at which the Work (or a specified part thereof) has progressed to the point where, in the opinion of ENGINIUU; , the Work (or a specified part thereof) is sm%ckntly complete, in accordance with the Contract Documents. so that the Wodc (or a specified part thereof) can be ufflzed for the purposes for which it is intended. The terms "st"antially complete" and "substantially compIMC as applied to all or part of the Work refer to Substantial Completion thereof. 44. Supplementary Conditions —That part of the Contract Documents which amends or supplements these General Conditions. 45. Supplier —A manufacturer, fabricator. supper, distributor, materialman. or vendor having a direct contract with CONTRACTOR or with any Subcontractor to furnish materials or equipment to be incorporated in the Work by CONTRACTOR or any Subcontractor. 46. Underground Fadlides —All underground pipelines, conduits. ducts, cables, wines, manholes, vaults, tanks, tunnels, or other such facilities or attachments, and any encasements containing such facilities, inchiding those that convey electricity, gases, steam, liquid petroleum products, telephone or other communications, cable television, water, wastewater, storm water, other liquids or chemicals, or traffic or other control systems. 47. Unit Price Work —Work to be paid for on the basis of unit prices. 48. Work —The entire completed construction or the various separately identifiable parts thereof required to be provided under the Contract Documents. Work includes and is the result of performing or providing all labor, services, and documentation necessary to produce such construction, and furnishing, installing, and incorporating all materials and equipment into such construction, all as required by the Contract Documents. 49. Work Qiange Directive —A written statement to CONTRACTOR issued on or after the Effective Date of the Agreement and signed by OWNER and recommended by ENGINEER ordering an addition, deletion, or revision in the Work, or responding to differing or unforeseen subsurface or physical conditions under which the Work is to be performed or to emergencies. A Work Change Directive will not change the Contract Price or the Contract Times but is evidence that the parties expect that the change ordered or documented by a Work Change Directive will be incorporated in a subsequently issued Change Order following negotiations by the parties as to its effect, if any, on the Contract Price or Contract Times. 50. Written Amendment —A written statement modifying the Contract Documents. signed by OWNER and CONTRACTOR on or after the Effective Date of the A&emeat and normally dealing with the nonengineering or nontechnical rather than strictly construction- related aspects of the Contract Documents. 1.02 Terminology 00700-8 A. Intent of certain Terns or Adjectives 1. Whenever in the Contract Documents the terms was allowed," as approved." or terms of like effect or import are used, or the adjectives "reasonable," "suitable." "acceptable," "proper," "satisfactory" or adjectives of Bike effect or import are used to describe an action or determination of ENGINEER as to the Work, it is intended that such action or determination will be solely to evaluate, in general, the corupieted Work for romplisace with the requirements of and information in the Contract Documeim and conformance with the design concept of the completed Project as a functioning whole as shown or indicated in the Contract Documents (unless there is a specific statement indicating Otherwise)- 'Ihe use of any such term or adjective shall not be effective to assign to ENGINEER any duty or authority to supervise or direct the performance of the Work or any duty or authority to undertake responsibility contrary to the provisions of paragraph 9.10 or any other provision of the Contract Documents. B. Day 1. The word "day" shall constitute a calendar day of 24 hours measured from midnight to the next midnight. C. Defective 1. The word "defective," when modifying the word "Work," refers to Work that is unsatisfactory, faulty, or deficient in that it does not conform to the Contract Documents or does not meet the requirements of any inspection, reference standard, test, or approval referred to in the Contract Documents, or has been damaged prior to ENGINEER's recommendation of final payment (unless responsibility for the protection thereof has been assumed by OWNER at Substantial Completion in accor- dance with paragraph 14.04 or 14.05). D. Furnish, Install, Perform, Provide 1. The word "furnish," when used in connection with services, materials, or equipment, shall mean to supply and deliver said services, materials, or equipment to the Site (or some other specified location) ready for use or installation and in usable or operable condition. 2. The word "install," when used in connection with services, materials, or equipment, shall mean to put into use or place in final position said services, materials, or equipment complete and ready for intended use. 3. The words "perform" or "provide," when used in connection with services, materials, or equipment, shall mean to furnish and install said services, materials, or equipment complete and ready for intended use. 4. When "furnish," "install," "perform," or "pro- vide" is not used in connection with services, materials, or equipment in a context clearly requiring an obligation of CONTRACTOR, 'provide" is implied. E. Unless stated otherwise in the Contract Documents, words or phrases which have a well4mown technical or eonsauction industry or trade meaning are used in the Contract Documents in accordance with such r+ewpized meaning. ARTICLE 2 - PRELIMINARY MATTERS 2.01 Delivery of Bonds A. When CONTRACTOR delivers the executed Agreements to OWNER. CONTRACTOR shall also deliver to OWNER such Bonds as CONTRACTOR may be required to furnish. 2.02 Copies of Documents A. OWNER shall furnish to CONTRACTOR up to ten copies of the Contract Documents. Additional copies will be finrnished upon request at the cost of reproduction. 2.03 Commencement of Contract ?imes, Notice to Proceed A. The Contract Times will commence to run on the thirtieth day after the Effective Date of the Agreement or. if a Notice to Proceed is given, on the day indicated in the Notice to Proceed. A Notice to Proceed may be given at any time within 30 days after the Effective Date of the Agreement. In no event will the Contract Times commence to run later than the sixtieth day after the day of Bid opening or the thirtieth day after the Effective Date of the Agreement, whichever date is earlier. 2.04 Starting the Work A. CONTRACTOR shall start to perform the Work on the date when the Contract Times commence to run. No Work shall be done at cite Site prior to the date on which the Contract Titaes commence to run. 2.0 Before Starting Construction A. CONRACTOR's Review of C Urrau Documents: l3 ibm undertaking each part of the Work, CONTRACTOR shall carefully. study and -compare the Contract Documents and check and verify pertinent figures therein and all applicable field measurements. • CONTRACTOR shall promptly report m writing to ENGU4M any conflict, error. ambiguity, or discrepancy which CONTRACTOR may discover mad shall obtain a written interpretation � or clarification from ENGINEER before proceeding with any Work affected thereby; however, CONTRACTOR shall not be liable to OWNER or ENGINEER for failure to report any conflict, error, ambiguity, or in the Contract Documents stales: CONTRACTOR knew or reasonably should have known thereof. r B. PreU minary Scheduks: Within ten days after the Effective Date of the Agreement (unless otherwise specified in the General Requirements), CONTRACTOR shall submit to ENGINEER for its timely review: 1. a preliminary progress schedule indicating the times (numbers of days or dates) for starting and completing the various stages of the Work, including any Milestones specified in the Contract Documents; 2. a preliminary schedule of Shop Drawing and Sample submittals which will list each required submittal and the times for submitting, reviewing, and processing such submittal; and 3. a preliminary schedule of values for all of the Work which includes quantities and prices of items which when added together equal the Contract Price and subdi- vides the Work into component parts in sufficient detail to serve as the basis for progress payments during performance of the Work. Such prices will include an appropriate amount of overhead and profit applicable to each item of Work. C. Evidence of Insurance: Before any Work at the Site is started, CONTRACTOR and OWNER shall each deliver to the other, with copies to each additional insured identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance which either of them or any additional insured may reasonably request) which CONTRACTOR and OWNER respectively are required to purchase and maintain in accordance with Article S. 2.06 Preconstmctlon Conference A. Within 20 days after the Contract Times start to run, but before any Work at the Site is started, a conference attended by CONTRACTOR. ENGINEER, and others as apptopriate will be held to establish a wa&mg understanding among the parties as to the work and to disatss the schedules referred to in paragraph 2.05.B, procedures for bandling Shop Drawings and other submittals, processing Applications for Payment, and maintaining required records. 2.07 Initial Acceptance of Sclsedules A. Unless otherwise provided in the Contract Docu- ments, at least tea days before submission of the first Application for Payment a conference attended by CON - TRACTOR, ENGINEER, and others as appropriate will be held to review for acceptability to ENGINEER as provided below the schedules submitted in accordance with paragraph 2.05.B. CONTRACTOR shall have as additional ten days to make corrections and adjustments and to complete and reodymit the schedules. No progress payment shall be made to CONTRACTOR until acceptable schedules are submitted to ENGINEER. 1. The progress schedule will be acceptable to ENGINEER if it provides an orderly progression of the Work to completion within any specified Milestones and the Contract Times. Such acceptance will not impose on ENGINEER responsibility for the progress schedule, for sequencing, scheduling. or progress of the Work nor interfere with or relieve CONTRACTOR from CONTRACTOR's full responsibility therefor. 2. CONTRACTOR's schedule of Shop Drawing and Sample submittals will be acceptable to ENGINEER if it provides a workable arrangement for reviewing and processing the required submittals. 3. CONTRACTOR's schedule of values will be .acceptable to. ENGINEER .as to form and substance if it provides a reasonable allocation of the Contract Price to component parts of the Work. ARTICLE 3 - CONTRACT DOCUMENTS: INTENT, AMENDING, REUSE 3.01 Intent A. The Contract Documents are complementary; what is called for by one is as binding as if called for by all. B. It is the intent of the Contract Documents to describe a functionally complete Project (or part thereof) to be constructed in accordance with the Contract Documents. Any labor, doaimeatation. services, materials' or equipment that may reasonably be inferred from the Contract Docu- ments or from prevailing custom or trade usage as being required to produce the intended restili will be provided whether or not specifically called for at no additional cost to OWNER. C. Clarifications.. and .interpretations of the Contract Documents shall be issued by ENGINEER as provided in Article 9. 3.02 Reference Standards A. Standards, Specifications, Codes, Laws, and Regulations 00700-10 1. Reference to standards, specifications, manuals, or codes of any technical society, organize + or association, or to Law: or Regulatioes. whedw r such geferesee be specific or by imputation, shall mean the standard, specification, manual, code, or Laws or Regula- tions in effect at the time of opening of Bids (or on the Effective Date of the Agreement if there were no Bids), except as may be otherwise specifically stated in the 3.04 Amending and Supplementing Contract Documents Contract Documents. 2. No provision of any such standard, specification, manual or code, or any instruction of a Supplier shall be effective to change the duties or responsibilities of OWNER, CONTRACTOR, or ENGINEER, or any of their subcontractors, consultants, agents, or employees from those set forth in the Contract Documents, nor shall any such provision or instruction be effective to assign to OWNER, ENGINEER, or any of ENGINEER's Consultants, agents, or employees any duty or authority to supervise or direct the performance of the Work or any duty or authority to undertake responsibility inconsistent with the provisions of the Contract Documents. 3.03 Reporting and Resolving Discrepancies A. Reporting Discrepancies 1. If, during the performance of the Work, CONTRACTOR discovers any conflict, error, ambiguity, or discrepancy within the Contract Documents or between the Contract Documents and any provision of any Law or Regulation applicable to the performance of the Work or of any standard, specification, manual or code, or of any instruction of any Supplier, CONTRACTOR shall report it to ENGINEER in writing at once. CONTRACTOR shall not proceed with the Work affected thereby (except in an emergency as required by paragraph 6.16.A) until an amendment or supplement to the Contract Documents has been issued by one of the methods indicated in paragraph 3.04; provided, however, that CONTRACTOR shall not be liable to OWNER or ENGINEER for failure to report any such coaffict, error, ambiguity, or dis- crepancy unless CONTRACTOR knew or reasonably should have known-thereof. B. Resolving Discrepancies 1. Except as may be otherwise specifically stated in the Contract Documents, the provisions of the Contract Documents shall take precedence in resolving any conflict, error, ambiguity, or discrepancy between the provisions of the Contract Documents and: a. the provisions of any standard, specification, manual, code, or instniction (whether or act specifi- cally incorporated by reference in the Contract Documents); or b. the provisions of any Laws or Regulations applicable to the performance of the Work (unless such an interpretation of the provisions of the Contract Doctrmeats would result in violation of such Law or Regulation). A. The Contract Documents may be amended w provide for additions, deletions, and revisions in the Work or to modify the terms and conditions thereof in one or more of the following ways: (i) a Written Amendment; (ii) a Change Order; or (iii) a Work Change Directive. B. The requirements of the Contract Documents may be supplemented, and minor variations and deviations in the Work may be authorized, by one or more of the following ways: (i) a Field Order; (ii) ENGINEER's approval of a Shop Drawing or Sample; or (iii) ENGINEER's written interpretation or clarification. 3.05 Reuse of Documents A. CONTRACTOR and any Subcontractor or Supplier or other individual or entity performing or furnishing any of the Work under a direct or indirect contract with OWNER: (i) shall not have or acquire any title to or ownership rights in any of the Drawings, Specifications, or other documents (or copies of any thereof) prepared by or bearing the seal of ENGINEER or ENGINEER's Consultant, including electronic media editions; and (ii) shall not reuse any of such Drawings, Specifications, other documents, or copies thereof on extensions of the Project or any other project without written consent of OWNER and ENGINEER and specific written verification or adaption by ENGINEER. This prohibition will survive fugal payment, completion, and acceptance of the Work, or termination or completion of the Contract. Nothing herein shall preclude CONTRACTOR from retaining copies of the Contract Documents for record purposes- ARTICLE 4 - AVAH ABIIITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; REFERENCE POINTS 4.01 AiWLabifity of Lands A. OWNER shall furnish the Site. OWNER shall notify CONTRACTOR of any encumbrances or restrictions not of general application but specifically related to use of the Site with which CONTRACTOR must comply in performing the Work. OWNER will obtain in a timely manner and pay for easements for permanent structures or permanent changes in existing facilities. If CONTRACTOR and OWNER are mable to agroe on entitlement to or on the amount or extent, if any. of any adjustment in the Contract Price or Contracx Times, or both, as a result of any delay in OWNER's furnishing the Site, CONTRACTOR may make a Claim therefor as provided in paragraph 10.05. 00700-11 B. Upon reasonable written request, OWNER shall furnish CONTRACTOR with a current statement of record legal title and legal description of the lands upon which the Work is to be performed and OWNER's interest therein as necessary for giving notice of or filing a mechanic's or construction lien against such lands in accordance with applicable Laws and Regulations. C. CONTRACTOR shall provide for all additional lands and access thereto that may be required for temporary construction facilities or storage of materials and equipment. 4.02 Subsurface and Physical Conditions A. Reports and Drawings: The Supplementary Conditions identify: 1. those reports of explorations and tests of subsurface conditions at or contiguous to the Site that ENGINEER has used in preparing the Contract Docu- ments; and 2. those drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the Site (except Underground Facilities) that ENGINEER has used in preparing the Contract Documents. B. Limited Reliance by CONTRACTOR on Technical Data Authorized: CONTRACTOR may rely upon the general accuracy of the "technical data" contained in such reports and drawings, but such reports and drawings are not Contract Documents. Such "technical data" is identified in the Supplementary Conditions. Except for such reliance on such 'technical data," CONTRACTOR may not rely upon or make any Claim against OWNER. ENGINEER, or any of ENGMEER's Consultants with respell to: 1. the completeness of such reports and drawings for CONTRACTOR's purposes, including, but not limited to, any aspects of the means, methods, techniques, sequences. and procedures of construction to be employed by CONTRACTOR. and safety precautions and programs incident thereto; or 2. other data, interpretations, opinions, and information contained m such reports or shown or indicated in such drawings; or 3. any CONTRACTOR interpretation of or conclusion drawn from any 'tei:hnical data" or any such other data. interpretations, oPinioaa, or information. 4.03 Differing Subsurface or Physical Conditions A. Notice: if CONTRACTOR believes that any subsur- face or physical condition at or contiguous to the Site that is uncovered or revealed either: 1. is of such a nature as to establish that any "technical data" on which CONTRACTOR is entitled to rely as provided in paragraph 4.02 is materially inaccurate; or 2. is of such a nature as to require a change in the Contract Documents; or 3. differs materially from that shown or indicated in the Contract Documents; or 4. is of an unusual nature, and differs materially from conditions ordinarily encountered and generally recognized as inherent in work of the character provided for in the Contract Documents; then CONTRACTOR shall, promptly after becoming aware thereof and before further disturbing the subsurface or physical conditions or performing any Work in connection therewith (except in an emergency as required by paragraph 6.16.A), notify OWNER and ENGINEER in writing about such condition. CONTRACTOR shall not further disturb such condition or perform any Work in connection therewith (except as aforesaid) until receipt of written order to do so. B. ENGD EM s Review: After receipt of written notice as required by paragraph 4.03.A. ENGINEER will promptly review the pertinent condition, determine the necessity of OWNER's obtaining additional exploration or tests with respect thereto, and advise OWNER in writing (with a copy to CONTRACTOR) of ENGINF. M's f m iags and conclusions. C. Possible Price and Times Adjustments 1. The Contract Price or the Contract Times, or both, will be equitably adjusted to the extent that the existence of such differing subsurface or physical condition causes an increase or decrease in CONTRACTOR's cost of, or time required for, perfor- mance of the Work; subject, however. to the following: 00700-12 a. such condition must meet any one or more of the categories described in paragraph 4.03.A; and b. with respect to Work that is paid for on a Unit Price Basis, any adjustment in Contract Prix will be subject to the provisions of paragraphs 9.08 and 11.03. 2. CONTRACTOR shall not be entitled to any adjustment in the Contract Price or Contract Times if: a. CONTRACTOR knew of the existence of such conditions at the time CONTRACTOR made a final commitment to OWNER in respect of Contract Price and Contract Times by the submission of a Bid or becoming bound under a negotiated contract; or b. the existence of such condition could reasonably have been discovered or revealed as a result of any examination, investigation, exploration, test, or study of the Site and contiguous areas required by the Bidding Requirements or Contract Documents to be conducted by or for CON- TRACTOR prior to CONTRACTOR's making such final commitment; or c. CONTRACTOR failed to give the written notice within the time and as required by paragraph 4.03.A. 3. If OWNER and CONTRACTOR are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, a Claim may be made therefor as provided in paragraph 10.05. However, OWNER, ENGINEER, and ENGINEER's Consultants shall not be liable to CONTRACTOR for any claims, costs, losses, or damages (including but not limited to all fees and charges of engineers, architects. attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by CONTRACTOR on or in connection with any other project or anticipated project. 4.04 Uhdergrntmd Fad hies A. Shown or hubcate& The information and data shown or indicated in the Contract Documents with respect . to existing Underground Facilities at or contiguous to the Site. is based on information and data furnished to OWNER or ENGINEER by the owners of such Underground Facilities, including OWNER, or by others. Unless it is .otherwise expressly provided in the Supplementary Conditions: 1. OWNER and ENGINEER shall not be responsible for the accuracy or completeness of any such information or data, and 2. the cost of all of the following will be included in the Contract Price, and CONTRACTOR shall have full responsibility for. IL reviewing and checldng all such information and data, b- locating all Underground Facilities shown or indicated in the Contract Documents, C. coordination of the Work with the owners of such Underground Facilities, including OWNER, during construction, and d. the safety and protection of all such Under- ground Facilities and repairing any damage thereto resulting from the Work. B. Not Shown or Indicated 1. If an Underground Facility is uncovered or revealed at or contiguous to the Site which was not shown or indicated, or not shown or indicated with reasonable accuracy in the Contract Documents, CONTRACTOR shall. Prosy after becoming aware thereof and before further disturbing conditions affected thereby or performing any Work in connection therewith (except in an emergency as required by paragraph 6.16.A), identify the owner of such Underground Facility and give written notice to that owner and to OWNER and ENGINEER. ENGINEER will promptly review the Underground Facility and determine the extent, if any, to which a change is required in the Contract Documents to reflect and document the consequences of the existence or location of the Underground Facility. During such time, CONTRACTOR shall be responsible for the safety and protection of such Underground Facility. 2. If ENGINEER. concludes that a change in the Contract Documents is required, a Work Change Directive or a Change Order will be issued to reflex and document such consequenm. An equitable adjustment shall be made in the Contract price of Contract Times, or both, to the extent that they are atafttable to the existence or location of nay Underground Facility that was not shown or.indicated or not shown or indicated with reasonable accuracy in the Centeno Documents and that CONTRACTOR did not know of and could not reasonably have been expected to be aware of or to have anticipated. If OWNER and CONTRACTOR are unable to agree on eaddement to or on the amount or extent, if any, of any such adjustment in Contract Price or Contract Times, OWNER or CONTRACTOR may make a Claim therefor as provided in paragraph 10.05. 4.05 Referawe P&vs A. OWNER shall provide engineering surveys to establish reference poinu for conscrtesion which in EARMER's judgment are ne=suy to enable CON- TRACTOR to proceed with the Work. CONTRACTOR shall be rapoostble for laying out the Work, shall protest and preserve the established reference points and property 00700-13 monuments, and shall make no changes or relocations without the prior written approval of OWNER. CONTRACTOR shall report to ENGINEER whenever any reference point or property monument is lost or destroyed or requires relocation because of necessary changes in grades or locations, and shall be responsible for the accurate replacement or relocation of such reference points or property monuments by professionally qualified personnel. 4.06 Hazardous Environmental Condition at Site A. Reports and Drawings: Reference is made to the Supplementary Conditions for the identification of those reports and drawings relating to a Hazardous Environmental Condition identified at the Site, if any, that have been utilized by the ENGINEER in the preparation of the Contract Documents. B. Limited Reliance by CONTRACTOR on Technical Data Authorized: CONTRACTOR may rely upon the general accuracy of the "technical data" contained in such reports and drawings, but such reports and drawings are not Contract Documents. Such "technical data" is identified in the Supplementary Conditions. Except for such reliance on such "technical data," CONTRACTOR may not rely upon or make any Claim against OWNER, ENGINEER or any of ENGINEER's Consultants with respect to: 1. the completeness of such reports and drawings for CONTRACTOR's purposes, including, but not limited to, any aspects of the means. methods, techniques. sequences and procedures of construction to be employed by CONTRACTOR and safety precautions and programs incident thereto; or 2. other data, interpretations, opinions and information contained in such reports or shown or indicated in such drawings; or 3. any CONTRACTOR interpretation of or conclusion drawn from any "technical data" or any such other data, interpretations, opinions or information. C. CONTRACTOR shall not be responsible for any Hazardous En*oamental Condition uncovered or revealed at the Site which was not shown or indicated in Drawings or Specifications or identified is the Contract Documents to be within the scope of the Work. CONTRACTOR shall be responsible for a Hazardots Environmental Condition created with any materials brought to the Site by CONTRACTOR, Subeonura lm, Suppliers, or anyoa else for whom CON - TRACTOR is responsible. D. If CONTRACTOR encounter a Hazardous Ew mnmeatal Condition or if CONTRACTOR or &MIM for whom CONTRACTOR is responsible creaks a Hazardous Environmental Condition, CONTRACTOR shall immedi- ately: (i) secure or otherwise isolate such condition; (ii) stop all Work in connection with such condition and in any area affected thereby (except in an emergency as required by paragraph 6.16); and (iii) notify OWNER and ENGINEER (and promptly thereafter confirm such notice in writing). OWNER shall promptly consult with ENGINEER concerning the necessity for OWNER to retain a qualified expert to evaluate such condition or take corrective action, if any. E. CONTRACTOR shall not be required to resume Work in connection with such condition or in any affected area until after OWNER has obtained any required permits related thereto and delivered to CONTRACTOR written notice: (i) specifying that such condition and any affected area.is.or.has been rendered safe for the resumption of Work; or (ii) specifying any special conditions under which such Work may be resumed safely. If OWNER and CONTRACTOR cannot -agree as to entitlement to or on the amount or extent, if any, of any adjustment in Contract Price or Contract Times, or both, as a result of such Work stop- page or such special conditions under which Work is agreed to be resumed by CONTRACTOR, either party may make a Claim therefor as provided in paragraph 10.05. F. If after receipt of such written notice CONTRACTOR does not agree to resume such Work based on a reasonable belief it is unsafe, or does not agree to resume such Work under such special conditions, then OWNER may order the portion of the Work that is in the area affected by such condition to be deleted from the Work. If OWNER and CONTRACTOR cannot agree as to entitlement to or on the amount or extent, if any. of an adjustment in Coamd price or Contrad Timis as a result of deleting such portion of the Work, then either party may make a Claim therefor as provided in paragraph 10.05. OWNER may have such deleted portion of the Work performed by OWNBR's own-forces or others in accordance with Article 7. G. To the fullest extent permitted by Laws and Regulations, OWNER shall indemnify and hold harmless CONTRACTOR, Subcontractors, ENGINEER, ENGINEER's Consultants and the officers, directors, partners, employees, agents, other consultants. and subcontractors of each and any of them from and against all claims, costs, losses, and damages (Including but not limited to an fen and charges of engineers, mitheats, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition, provided that such Hawdots Environmental Condition: (i) was not shown or iniicated in the Drawtugs or Specifications or identified is the Contract Documents to be included within the scope of the Work. and (u) was not created by CONTRACTOR or by anyone for whom CONTRACTOR is responsible. Nothing 00700-14 in this paragraph 4.06.E shall obligate OWNER to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence. H. To the fullest extent permitted by Laws and Regulations, CONTRACTOR shall indemnify and hold harmless OWNER, ENGINEER, ENGINEER's Consultants, and the officers, directors, partners, employees, agents, other consultants, and subcontractors of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to a Hazardous Environmental Condition created by CONTRACTOR or by anyone for whom CONTRACTOR is responsible. Nothing in this paragraph 4.06.F shall obligate CONTRACTOR to indemnify any individual or entity from and against the consequences of that individual's or entity's own negligence. I. The provisions of paragraphs 4.02, 4.03, and 4.04 are not intended to apply to a Hazardous Environmental Condition uncovered or revealed at the Site. ARTICLE 5 - BONDS AND INSURANCE 5.01 Performance, Payment, and Other Bonds A. CONTRACTOR shall furnish performance and payment Bonds, each in an amount at least equal to the Contract Price as security for the faithful performance and payment of all CONTRACTOR's obligations under the Contract Documents. These Bonds shall remain in effect at least until one year after the date when final payment becomes due, except as provided otherwise by Laws or RegWations or by the Contract Documents. CONTRACTOR shall also furnish such other Bonds as are required by the Contract Documents. B. All Bonds shall be in the form prescribed by the Contract Documents except as provided otherwise by Laws or Regulations, and shall be executed by such sureties as are named in the current list of 'Companies Holding Certificates of Authority as Acceptable Sureties on Federal Bonds and as Acceptable Reinsuring Companies' as published in Circular 57'0 (amended) by dw Financial Management Service, Surety Bond Branch, U.S. Department of the Treasury. All Bonds signed by an agent must be w=ipanied by a certified copy of such agent's authority to act. of paragraph 5.0l.B, CONTRACTOR shall within 20 days thereafter substitute another Bond and surety, both of which shall comply with the requirements of paragraphs 5.01.8 and 5.02. 5.02 Licensed Sureties and Insurers A. All Bonds and insurance required by the Contract Documents to be purchased and maintained by OWNER or CONTRACTOR shall be obtained from surety or insurance companies that are duly licensed or authorized in the jurisdiction in which the Project is located to issue Bonds or insurance policies for the limits and coverages so required. Such surety and insurance companies shall also meet such additional requirements and qualifications as may be provided in the Supplementary .Conditions. 5.03 Certificates of Insurance A. CONTRACTOR shall deliver to OWNER, with copies to each additional insured identified in the Supple- mentary Conditions, certificates of insurance (and other evidence of insurance requested by OWNER or any other additional insured) which CONTRACTOR is required to purchase and maintain. OWNER shall deliver to CONTRACTOR, with copies to each additional insured identified in the Supplementary Conditions, certificates of insurance (and other evidence of insurance requested by CONTRACTOR or any other additional insured) which OWNER is required to purchase and maintain. 5.04 CONMCTOR's Liabifity Insurance A. CONTRACTOR shall purchase and maintain such liability and other insurance as is appropriate for the Work being performed and as. will provide protection from claims set forth below which may arise out of or result from CONTRACTOR's performance of the Work and CONTRACTOR's. other- obligations under . the Contract Documents, whether it is to be performed, by CONTRACTOR, any Subcontractor or Supplier, or by anyone directly or indirectly employed by any of them to perform any of the Work, or by anyone for whose acts any of them may be liable: 1. claims under workers' compensation, disability benefits, and other similar employee benefit acts; 2. claims for damages because of bodily injury, occupational sickness or disease, or death of CONTRACTOR's employees; C. If the surety on any Bond furnished by CON- r 3. claims for damages because of bodily injury, TRACTOR is declared bankrupt or becomes insolvent or its sickness or disease, or death of any person other than right to do business is terminated in any state where any part CONTRACTOR's employees; of the Project is located or it ceases to meet the requirements 00700-15 4. claims for damages insured by reasonably available personal injury liability coverage which are sus- tained: (i) by any person as a result of an offense directly or indirectly related to the employment of such person by CONTRACTOR. or (ii) by any other person for any other reason; 5. claims for damages. other than to the Work itself, because of injury to or destruction of tangible property wherever located, including loss of use resulting therefrom; and 6. claims for damages because of bodily injury or death of any person or property damage arising out of the ownership, maintenance or use of any motor vehicle. B. The policies of insurance so required by this paragraph 5.04 to be purchased and maintained shall: 1. with respect to insurance required by paragraphs 5.04.A.3 through 5.04.A.6 inclusive, include as additional insureds (subject to any ctutomary exclusion in respect of professional liability) OWNER, ENGINEER, ENGINEER's Consultants, and any other individuals or entities identified in the Supplementary Conditions, all of whom shall be listed as additional insureds, and include coverage for the respective officers, directors, partners, employees, agents, and other consultants and subcontractors of each and any of all such additional insureds, and the insurance afforded to these additional insureds shall provide primary coverage for all claims covered thereby; 2. include at least the specific coverages and be written for not less than the limits of liability provided in the Supplementary Conditions or reqtured by Laws or Regulations. whichever is greater; 3. include completed operations insurance; 4. include contractual liability insurance covering CONTRACTOR's indemnity obligations under para- graphs 6.07, 6.11, and 6.20; 5. contain a provision or endorsement that the coverage afforded wdl not be canceled, materially changed or renewal refused until at least thirty days prior written notice has been given to OWNER and CONTRACTOR and to each other additional insured identified in the Supplementary Conditions to whom a certificate of insurance har been issued (and the certificates of insurance furnished by the CONTRAC'T'OR pursuant to paragraph 5.03 will so provide); 6. remain in effect at kart until final payment and at all times thereafter when CONTRACTOR may be correcting, removing, or replacing defective Work in accordance with paragraph 13.07; and 7. with respect to completed operations insurance, and any insurance coverage written on a claims -made basis, remain in effect for at least two years after final payment (and CONTRACTOR shall furnish OWNER and each other additional insured identified in the supple- mentary Conditions, to whom a certificate of insurance has been issued, evidence satisfactory to OWNER and any such additional insured of continuation of such insurance at final payment and one year thereafter). 5.05 OWNER's Uabiliry Insurance A. In addition to the insurance. required to be provided by CONTRACTOR under paragraph 5.04, OWNER, at OWNER's option, may purchase and maintain at OWNER's expense OWNER's own liability insurance as will protect OWNER against claims which may arise from operations under the Contract Documents. 5.06 Property Insurance A. Unless otherwise provided in the Supplementary Conditions, OWNER shall purchase and maintain property insurance upon the Work at the Site in the amount of the full replacement cost thereof (subject to such deductible amounts as may be provided in the Supplementary Conditions or required by Laws and Regulations). This insurance shall: 1. include the interests of OWNER, CONTRAC- TOR, Subcontractors, ENGINEER. ENGINEER's Consultants, and any other individuals or entities kknti- fted in the Supplementary Conditions, and the officers, fin, pin. employees. agents, and other consultants and subcontractors of each and any of them, each of whom is deemed to have an insurable iaterest and shall be listed as an additional insured; 2. be written on a Builder's Risk 'all -risk" or open peril or special causes of loss policy form that shall at least include insurance for physical loss or damage to the Work, temporary btuldmgs, false work, and materials and equipment m transit, and shall insure against at least the following perils or causes of loss: fire, lightning, extended coverage, theft, vandalism and malicious mischief. earthquake, collapse, debris removal, demolition occasioned by enforcement of Laws and Regulations, water damage, and such other perils or causes of loss as may be specifically required by the �rpplementary Conditions; 3. include expenses incurred m the repair or replacement of any insured property Ctncluding but not limited to fees and charges of engineers and architects); 00700-16 4. cover materials and equipment stored at the Site or at another location that was agreed to in writing by OWNER prior to being incorporated in the Work, provided that such materials and equipment have been included in an Application for Payment recommended by ENGINEER; S. allow for partial utilization of the Work by OWNER; 6. include testing and startup; and 7. be maintained in effect until final payment is made unless otherwise agreed to in writing by OWNER, CONTRACTOR, and ENGINEER with 30 days written notice to each other additional insured to whom a certifi- cate of insurance has been issued. B. OWNER shall purchase and maintain such boiler and machinery insurance or additional property insurance as may be required by the Supplementary Conditions -or Laws and Regulations which will include the interests of OWNER, CONTRACTOR, Subcontractors, ENGINEER, ENGINEER's Consultants, and any other individuals or entities identified in the Supplementary Conditions, each of whom is deemed to have an insurable interest and shall be listed as an insured or additional insured. C. All the policies of insurance (and the certificates or other evidence thereof) required to be purchased and maictained in accordance with paragraph 5.06 will contain a provision or endorsement that the coverage afforded will not be canceled or materially changed or renewal refused until at least 30 days prior written notice has been given to OWNER and CONTRACTOR and to each other additional insured to whom a certificate of insurance has been issued and will contain waiver p wAsioos in accordance with paragraph 5.07. D. OWNER shall not be responsffile for purchasing sad maintairgin g any Property insurance specified in this paragraph 5.06 to protect the interests of CONTRACTOR, Subcontractors, or others in the Work to the extent of any deductible amounts that are identified in the Supplementary Conditions. The risk of loss within such identified deductible amount will be borne by CONTRACTOR, Subcontractors, or others suffering any such loss, and if any of them wishes property hwuranc a coverage within the limits of such amounts, each may purchase and maintain it at the purchaser's own expense. E. If CONTRACTOR requests in writing that other special insurance be included in the properly insurance policies provided under paragraph 5.06, OWNER shall, if possibk. include such bsu ranee, and the cost thereof will be charged to CONTRACrOR by appropriate Change Order or Written Amendment. Prior to cemmenocmeat of the Work at the Site, OWNER shall in writing advise CONTRACTOR whether or not such other insurance has been procured by OWNER. 5.07 Waiver of Rights A. OWNER and CONTRACTOR intend that all policies purchased in accordance with paragraph 5.06 will protect OWNER, CONTRACTOR, Subcontractors, ENGINEER, ENGINEER's Consultants, and all other individuals or entities identified in the Supplementary Conditions to be listed as insureds or additional insureds (and the officers, directors, partners, employees, agents, and other consultants and subcontractors of each and any of them) in such policies and will provide primary coverage for all losses and damages caused by the perils or causes of loss covered thereby. All such policies shall contain provisions to the effect that in the event of payment of any loss or damage the insurers will have no rights of recovery against any of the insureds or additional insureds thereunder. OWNER and CONTRAC- TOR waive all rights against each other and their respective officers, directors, partners, employees, agents, and other consultants and subcontractors of each and any of them for all losses and damages caused by, arising out.of or resulting from any of the perils or causes of loss covered by such policies and any other property insurance applicable to the Work; and, in addition, waive all such rights against Subcontract ors, ENGINEER, ENGINEER's Consultants, and all other individuals or entities identified in the Supplemen- tary Conditions to be listed as insureds or additional insureds (and the officers, directors, partners, employees, agents, and other consultants and subcontractors of each and any of diem) under such policies for kisses and damages so caused. None of the above waivers shall extend to the rights that any party making such waiver may have to the proceeds of insurance held by OWNER as trustee or otherwise payable under any policy so issued. B. OWNER waives-all rights against CONTRACTOR, Subcontractors, ENGINEER,-ENGINEER's Consultants, ami the officers, directors, partners, employees, agents, and other consultants and subcontractors of each and any of them for: 00700 -17 1. Iola due to business interruption, loss of use, or other consequential loss extending beyond direct physical loss or damage to . OWNER's property or the Work caused by, arising out of, or resulting from fire or other peril whether or not insured by OWNER, and 2. loss or damage to the completed Project or part dtereof cautsod by, arising out of, or resulting from fire or other insured peril or Muse of loss covered by any party insurance Wined on die completed Project or part thereof by OWNER during partial utilization pursuant to paragraph 14.05, after Substantial Completion pursuant to paragraph 14.04, or after final payment pursuant to paragraph 14.07. C. Any insurance policy maintained by OWNER cover- ing any loss, damage or consequential loss referred to in paragraph 5.07.B shall contain provisions to the effect that in the event of payment of any such loss, damage, or consequential loss, the insurers will have no rights of recovery against CONTRACTOR, Subcontractors, ENGINEER, or ENGINEER's Consultants and the officers, directors, partners, employees, agents, and other consultants and subcontractors of each and any of them. 5.08 Receipt and Application of Insurance Proceeds A. Any insured loss under the policies of insurance required by paragraph 5.06 will be adjusted with OWNER and made payable to OWNER as fiduciary for the insureds, as their interests may appear, subject to the requirements of any applicable mortgage clause and of paragraph 5.08.B. OWNER shall deposit in a separate account any money so received and shall distribute it in accordance with such a&=- ment as the patties in interest may reach. If no other special agreement is reached, the damaged Work shall be repaired or replaced, the moneys so received applied on account thereof, and the Work and the cost thereof covered by an appropriate Change Order or Written Amendment. B. OWNER as fiduciary shall have power to adjust and settle any loss with the insurers unless one of the parties in interest shall object in writing within 15 days afar the occurrence of loss to OWNER's exercise of this power. If such objection be made. OWNER as fiduciary shall make settlement with the insurers in accordance with such agreement as the parties in interest may reach. If no such agreement among the patties in imereat is readied, OWNER as fiduciary shall adjust and settle the loss with tie insurers and, if required in writing by any ply in interest. OWNER as fiduciary shall give bond for the proper performance of such duties. 5.09 Acceptance of Bonds and Insurance; option to Reps A. If either OWNER or CONTRACTOR has any objection to the coverage afforded by or other provisions of the Bonds or insurance required to be purchased and maintained by the other party in accordance with Article 5 on the basis of non-conformance with the Contract Documents. the o*c ing party shall so notify the other party m writing Within 10 days after receipt of the oectificstes (or other evidence requested) required by paragraph 2.05.C. OWNER and CONTRACTOR shall each provide to the other such sdditiooal information in respect of insurance provided as the other may reasonably request. If either party does not purchase or maintain all of the Bonds and insurance required of such parry by the Contract Documents, such party shall notify the other party in writing of such failure to purchase prior to the start of the Work, or of such failure to maintain prior to any change in the required coverage. Without prejudice to any other right or remedy, the other party may elect to obtain equivalent Bonds or insurance to protect such other party's interests at the expense of the party who was required to provide such coverage, and a Change Order shall be issued to adjust the Contract Price accordingly. 5.10 Partial Utilization, Acknowledgment of Property Insurer A. If OWNER finds it necessary to occupy or use a portion or portions of the Work prior to Substantial Completion of all the Work as provided in paragraph 14.05, no such use or occupancy shall- commence before the insurers providing the property insurance.pursuant to paragraph 5.06 have acknowledged notice thereof and in writing effected any changes in coverage necessitated thereby. The insurers providing the property insurance shall consent by endorse- ment on the policy or policies, but the property insurance shall not be canceled or permitted to lapse on account of any such partial use or occupancy. ARTICLE 6 - CONTRACTOR'S RESPONSIBILITIES 6.01 Supervision and Superintendence A. CONTRACTOR shall supervise, inspect, and direct the Work competently and efficiently. devoting such attention thereto and applying such skills and expertise as may be necessary to perform the Work in accordance with the Cona2d Documents. CONTRACTOR shall be solely respoosi'bie for the means...methods, wchnigaes. sequences- and procedures oUoonasw ctiM. hnt CONTRACTOR shall not be responsible: -for : the negligence of. OWNER or ENGINEER in the Aesign'.or. specification of a specific means.. mcdx d, technique, seq w=. or procedure of construction which is shown or indicated in and expressly required by the Contract Documents. CONTRACTOR shall be responsible to see that the completed Work complies accurately with the Contract Documents. B. At all times during the progress of the work, CONTRACTOR shall assign a competent resident superin- tendent thereto who shall not be replaced without written notice to OWNER and ENGINEER except under ems, �. The superintendent will be COVMCTOR's representative at the Site and shall have authority to act on behalf of CONTRACTOR All communications given to or received from the superi shall be binding on CONTRACTOR. 00700-18 6.02 labor, Working Hours A. CONTRACTOR shall provide competent, suitably qualified personnel to survey, lay out, and construct the Work as required by the Contract Documents. CON- TRACTOR shall at all times maintain good discipline and order at the Site. B. Except as otherwise required for the safety or protection of persons or the Work or property at the Site or adjacent thereto, and except as otherwise stated in the Contract Documents, all Work at the Site shall be performed during regular working hours, and CONTRACTOR will not permit overtime work or the performance of Work on Saturday, Sunday, or any legal holiday without OWNER's written consent (which will not be unreasonably withheld) given after prior written notice to ENGINEER. 6.03 Services, Materials, and Equipment A. Unless otherwise specified in the General Re- quirements, CONTRACTOR shall provide and assume full responsibility for all services, materials, equipment, labor, transportation, construction equipment and machinery, tools, appliances, fuel, power, light, heat, telephone, water, sanitary facilities, temporary facilities, and all other facilities and incidentals necessary for the performance, testing, start -up, and completion of the Work. B. All materials and equipment incorporated into the Work shall be as specified or, if not specified, shall be of good quality and new, except as otherwise provided in the Contract Documents. All warranties and guarantees specifically called for by the Specifications shall expressly nm to the benefit of OWNER. If required by ENGINEER, CONTRACTOR shall furnish satisfactory evidence (including reports of required tests) as to the source, kind, and quality of materials and equipment. All materials and equipment shall be stored, applied, installed, connected, erected, protected, used, cleaned, and conditioned in accordance with instructions of the applicable Supplier, except as otherwise may be provided in the Contract Docu- ments. 6.04 Progress Schedule A. CONTRACTOR shall adhere to the progress schedule establishod in accordance with paragraph 2.07 as it may be adjusted from time to time as provided below. 1. CONTRACTOR shall submit to ENG1NM for acceptance (to the extent Indicated in paragraph 2.07) Proposed adjustments in the progress schedule that will not result in changing the Contract Time: (or Weston:). Such adjustments will conform generally to the progress schedule then in effect aced additionally will comply with any provisions of the General Requirements applicable thereto. 2. Proposed adjustments in the progress schedule that will change the Contract Times (or Milestones) shall be submitted in accordance with the requirements of Article 12. Such adjustments may only be made by a Change Order or Written Amendment in accordance with Article 12. 6.05 Substitutes and "Or- Equals' A. Whenever an item of material or equipment is specified or described in the Contract Documents by using the name of a proprietary item or the name of a particular Supplier, the specification or description is intended to establish the type, function, appearance, and quality required. Unless the specification or description contains or is followed by words reading that no like, equivalent, or "or-equal" item or no substitution is permitted, other items of material or equipment or material or equipment of other Suppliers may be submitted to ENGINEER for review under the circum- stances described below. 00700-19 1. 'Or-Equal" Items: If in ENGINEER's sole discretion an item of material or equipment proposed by CONTRACTOR is functionally equal to that named and sufficiently similar so that no change in related Work will be required, it may be considered by ENGINEER as an "or- equal" item, in which case review and approval of the proposed item may, in ENGINEER's sole discretion, be accomplished without compliance with some or all of the requirements for approval of proposed substitute items. For the purposes of this paragraph 6.05.A.1, a proposed item of material or equipment will be considered functionally equal to an item so named if: a. in the exercise of reasonable judgment ENGINEER determines that: n it is at least equal in quality, durability, appearance, strength, and design characteristics; (ii) it will reliably perform at least equally well the function imposed by the design concept of the completed Project as a functioning whole, and; b. CONTRACTOR certifies that: (i) there is no increase in cost to the OWNER; and (h) it will conform substantially, even with deviatioas, to the detailed requirements of the item named in the Contract Documents. r 2. Substitute Items a. If in ENGU ER's sole discretion an item of material or equipment proposed by CONTRACTOR does not gw:Sy as an 'or- equal" item under paragraph 6.05.A.1. it will be considered a proposed substitute item. b. CONTRACTOR shall submit sufficient information as provided below to allow ENGINEER to determine that the item of material or equipment proposed is essentially equivalent to that named and an acceptable substitute therefor. Requests for review of proposed substitute items of material or equipment will not be accepted by ENGINEER from anyone other than CONTRACTOR. c. The procedure for review by ENGINEER will be as set forth in paragraph 6.05.A.2.d, as supplemented in the General Requirements and as ENGINEER may decide is appropriate under the circumstances. d. CONTRACTOR shall first make written application to ENGINEER for review of a proposed substitute item of material or equipment that CONTRACTOR seeks to furnish or use. The application shall certify that the proposed substitute item will perform adequately the functions and achieve the results called for by the general design, be similar in substance to that specified, and be suited to the same use as that specified. The application will state the extent, if any, to which the use of the proposed substitute item will prejudice CONTRACTOR's achievement of Substantial Completion on time, whether or not use of the proposed substitute item in the Work will require a change in any of the Contract Documents (or in the provisions of any otber direct contract with OWNER for work on the Project) to adapt the design to the proposed substitute item and whether or not incorporation or use of the proposed eubstitute-item in connection with the Work is subject to payment of any license fee or royalty. All variations of the pro- posed substitute item from that specified will be identified in the application, and available engineering, sales, maintenance, repair, and replacement services will be indicated. The application will also contain an itemized estimate of all costs or credits that will result directly or indi- rectly from use of such substitute item, including costs of redesign and claims of other contractors affected by any resulting change, all of which will be considered by ENGINEER in evaluating the proposed substitute item. ENGINEER may require CON- TRACTOR to furnish additional data about the pro- posed substitute item. B. Substiade Catmvcdon Methods or Procedures: If a specific means, method, technique. sequence, or procedure of construction is shown or indicated in and expressly required by the Contract Documents, CONTRACTOR may furnish or utilize a substitute means, method, technique, sequence, or procedure of construction approved by ENGI- NEER. CONTRACTOR shall submit sufficient information to allow ENGINEER, in ENGINEER's sole discretion, to determine that the substitute proposed is equivalent to that expressly called for by the Contract Documents. The proce- dure for review by ENGINEER will be similar to that provided in subparagraph 6.05.A.2. C. Engineer's EmIuation: ENGINEER will be allowed a reasonable time within which to evaluate each proposal or submittal made pursuant to paragraphs 6.05.A and 6.05.B. ENGINEER will be the sole judge of acceptability. No "or- equal" or substitute will be ordered, installed or utilized until ENGINEER's review is complete, which will be evidenced by either a Change. Order for a substitute or an approved Shop Drawing for an "or equal." ENGINEER will advise CONTRACTOR in writing of any negative determination. D. Special Guarantee: OWNER may require CON- TRACTOR to furnish at CONTRACTOR's expense a special performance guarantee or other surety with respect to any substitute. E. ENGINEER's Cost Reimbursement: ENGINEER will record time required by ENGINEER and ENGINEER's Consultants in evaluating substitute proposed or submitted by CONTRACTOR pursuant to paragraphs 6.05.A.2 and 6.05.B and in making changes in the Contract Documents (or in the provisions of any other direct contract with OWNER for work on the Project) occasioned thereby. Whether or not ENGINEER approves a substitute item so proposed or submitted by CONTRACTOR. CONTRACTOR shall reimburse OWNER for the charges of ENGINEER and ENGINEE.it's ior.mivaung each such proposed substitute. F. C0NMC7 r Expense: CONTRACTOR shall provide all data in support of any proposed substitute or "or -equal" at CONTRACTOR's expense. 6.06 Concerning Subcontractors, Suppliers, and Others A. CONTRACTOR shall not employ any Subcontractor, Supplier, or other individual or entity (including those acceptable to OWNER as indicated in paragraph 6.06.B). whether initially or as a replacement, against whom OWNER may have reasonable objection. CONTRACTOR shall not be required to employ any Subcontractor, Supplier, or other indidtdual or entity to furnish or perform any of the Work against whom CONTRACTOR has reasonable objection. B. If the Supplementary Conditions require the identity of certain Ste. Supper. or other individuals or entities to be submitted to OWNER in advance for acceptance by OWNER by a specified date prior to the Effective Date of the Agreement, and if CONTRACTOR has submitted a list thereof in accordance with the Supplementary Conditions, OWNER's acceptance (either in writing or by failing to make written objection thereto by the date indicated for acceptance or objection in the Bidding Documents or the Contract Documents) of any such Subcontractor, Supplier. or other individual or entity so identified may be revoked on the basis of reasonable objection after due investigation. CON- TRACTOR shall submit an acceptable replacement for the rejected Subcontractor, Supplier, or other individual or entity, and the Contract Price will be adjusted by the differ- ence in the cost occasioned by such replacement, and an appropriate Change Order will be issued or Written Amendment signed. No acceptance by OWNER of any such Subcontractor, Supplier, or other individual or entity, whether initially or as a replacement, shall constitute a waiver of any right of OWNER or ENGINEER to reject . defective Work. C. CONTRACTOR shall be fully responsible to OWNER and ENGINEER for all acts and omissions of the Subcontractors, Suppliers, and other individuals or entities performing or furnishing any of the Work just as CONTRACTOR is responsible for CONTRACTOR's own ads and omissions. Nothing in the Contract Documents shall create for the benefit of any such Subcontractor. Supplier, or other individual or entity any contractual relationship between OWNER or ENGINEER and any such Subcontractor, Supplier or other individual or entity, nor shall it create any obligation on the part of OWNER or ENGINEER to pay or to .see to the payment of any moneys due any such .Subcon- tractor, Supplier, or other individual or entity except as may otherwise be required by IBws and Regulations. D. CONTRACTOR shall be solely responsible for scheduling and coordinating the Work of Subcontractors, Suppliers. and oilier individuals or entities performing . of . furnishing any of the Work under a direct or indirect eonaacr with CONTRACTOR. E. CONTRACTOR shall require all Subcontractors, Suppliers, and such other individuals or entities performing or furnishing any of the Work to communicate with ENGI- NEER through CONTRACTOR. F. The divisions and sections of the Specifications and the ideas•+ -tom of any Drawings shall nix control CONTRACTOR in dividing the Work among Subcowwtors or Suppliers Of delineadq die Work to be performed by any specific trade. G. All Work performed for CONTRACTOR by a Subcontractor or Supplier will be pursuant to an appropriate agreement between CONTRACTOR and the Subcontractor or Supplier which specifically binds the Subcontractor or Supplier to the applicable terms and conditions of the Contract Documents for the benefit of OWNER and ENGINEER. Whenever any such agreement is with a Subcontractor or Supplier who is listed as an additional insured on the property insurance provided in paragraph 5.06, the agreement between the CONTRACTOR and the Subcontractor or Supplier will contain provisions whereby the Subcontractor or Supplier waives all rights against OWNER, CONTRACTOR, ENGINEER, ENGINEER's Consultants, and all other individuals or entities identified in the Supplementary Conditions to be listed as insureds or additional insureds (and the officers, directors, partners, employees, agents, and other consultants and subcontractors of each and any of them) for all losses and damages caused by, arising out of, relating to, or resulting from any of the perils or causes of loss covered by such policies and any other property insurance .-applicable to the Work. If the insurers on any such policies require separate waiver forms to be signed by any Subcontractor or Supplier, CONTRAC- TOR will obtain the same. 6.07 Patent Fees and Royalties A. CONTRACTOR shall pay all license fees and royalties and assume all costs incident to the use in the performance of the Work or the incorporation in the Work of any invention, design, process, product, or device which is the subject of patent rights or copyrights held by others. If a particular invention, design, process, product, or device is specified in the Contract Documents for use in the performance of the Work and if to the actual knowledge of OWNER or ENGINEER its use is subject to patent rights or copyrights c4flin8 for the payment of any license fee or royalty to others, the existence of such rights shall be disclosed by OWNER in the Contraatx Documents. To the fullest extent permitted by Laws and Regulatiooa. CONTRACTOR.: shall. indemnify and bold harmless OWNF-R.: ENGINEER,: ENGDTMR's Consultants, and the officers - directors,, partners,xmployees or agents. and other consultants ,of each-and airy of-them from and against all cl aims, costs, losses, and damages. includ3lig but not limited to all fees and charges of engineers. ar+chitocts. attorneys. and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any infringement of patent rights or copyrights incident to the use in the performance of the Work or resulting from the incorporation in the Work of any invention, design, process, product, or device not specified in the Contract Documents. 6.08 Permits A.r Unless otherwise provided in the Supplementary Conditions, CONTRACTOR shall obtain and pay for all construction permits and licenses. OWNER shall assist CONTRACTOR, when necessary, in obtaining such permits 00700-21 and licenses. CONTRACTOR shall pay all governmental charges and inspection fees necessary for the prosecution of the Work which are applicable at the time of opening of Bids, or, if there are no Bids, on the Effective Date of the Agreement. CONTRACTOR shall pay all charges of utility owners for connections to the Work, and OWNER shall pay all charges of such utility owners for capital costs related thereto, such as plant investment fees. 6.09 Laws and Regulations A. CONTRACTOR shall give all notices and comply with all Laws and Regulations applicable to the performance of the Work. Except where otherwise expressly required by applicable Laws and Regulations, neither OWNER nor ENGINEER shall be responsible for monitoring CONTRACTOR's compliance with any Laws or Regulations. B. If CONTRACTOR performs any Work knowing or having reason to know that it is contrary to Laws or Regulations, CONTRACTOR shall bear all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such Work; however, it shall not. be CONTRACTOR's primary responsibility to make certain that the Specifications and Drawings are in accordance with Laws and Regulations, but this shall not relieve CONTRACTOR of CONTRACTOR's obligations under paragraph 3.03. C. Changes in Laws or Regulations not known at the time of opening of Bids (or, on the Effective Date of the Agreement if there were no Bids) having an effect on the cost or time of performance of the Work may be the subject of an &jam is Contract price or Contract Pmts. If OWNER and CONTRACTOR are unable to agree on eaatlemeat to or on the amamt or extent, if say, of any such adjustment, a< Claim may W made therefor as provided in paragraph 10.05. 6.10 Taxes A. CONTRACTOR shall pay all sales, consumer. use, and other similar taxes required to be paid by CONTRAC- TOR in accordance with the Laws and Regulations of the place of the Project which are applicable during the performance of the Work. 6.11 Use of Site and Other Areas A. Li dodon on Use of Site and Mier Areas 1. CONTRACTOR shall confine construction equipmeD4 the swage of materials and equipment, and the operations of workers to the Site and other areas permitted by Laws and Regulations, and shall not unreasonably encumber the Site and other areas with construction equipment or other materials or equipment. CONTRACTOR shall assume full responsibility for any damage to any such land or area, or to the owner or occupant thereof, or of any adjacent land or areas resulting from the performance of the Work. 2. Should any claim be made by any such owner or occupant because of the performance of the Work, CONTRACTOR shall promptly settle with such other parry by negotiation or otherwise resolve the claim by arbitration or other dispute resolution proceeding or at law. 3. To the fullest extent permitted by Laws and Regulations, CONTRACTOR shall indemnify and hold harmless OWNER, ENGINEER, ENGINEER's Consultant, and the officers, directors, partners, employees, agents, and other consultants of each and any of them from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to any claim or action, legal or equitable, brought by any such owner or occupant against OWNER, ENGINEER, or any other party indemnified hereunder to the extent caused by or based upon CONTRACTOR's performance of the Work. B. Removal of Debris During Performance of the Work: During the progress of the Work CONTRACTOR shall keep the Site and other areas free from accumulations of waste materials. rubbish, and other debris. Removal and disposal of such waste materials, rubbish, and other debris shall I form to applicable Laws and Regulations. C. Gleaning: prior to Substantial Completion of the Work.CONTRACTOR shall clan the Site and maim it ready for utilization by OWNER. At the completion of the Work CONTRACTOR shall remove from the Site all tools, appliances, construction equipment and machinery, and surplus materials and shall restore to original condition all property not designated for alteration by the Contract Documents. D. Loading Structures: CONTRACTOR shall not load nor permit any part of any structure to be loaded in any mannr that will endanger the structure, nor shall CONTRACTOR subject any part of the Work or adjacent property to stresses or pressures that will endanger it. 6.12 Record Documents r A. CONTRACTOR shall maintain in a safe place at the Site one record copy of all Drawings. Specifications. Addenda, Written Amendments, Change Orders, Work 00700 -22 Change Directives, Field Orders, and written interpretations and clarifications in good order and annotated to show changes made during construction. These record documents together with all approved Samples and a counterpart of all approved Shop Drawings will be available to ENGINEER for reference. Upon completion of the Work, these record documents, Samples, and Shop Drawings will be delivered to ENGINEER for OWNER. 6.13 Safety and Protection A. CONTRACTOR shall be solely responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the Work. CONTRACTOR shall take all necessary precautions for the safety of, and shall provide the necessary protection to prevent damage, injury or loss to: 1. all persons on the Site or who may be affected by the Work; 2. all the Work and materials and equipment to be incorporated therein, whether in storage on or off the Site; and 3. other property at the Site or adjacent thereto, including trees, shrubs, lawns, walks, pavements, roadways, structures, utilities, and Underground Facilities not designated for removal, relocation, or replacement in the course of construction. B. CONTRACTOR shall comply with all applicable Laws and Regulations relating to the safety of persons or property, or to the protection of persona or property from damage, injury, or loss; and shall erect and maintain all necessary safeguards for such safety and protection. CONTRACTOR shall notify owners; of adjacent property and of Underground Facilities and other unlit' y owners when proseattion of the work may affect them, and shall cooperate with them in the protection, removal, relocation, and replaoement of their property. All damage, injury, or loss to any property referred to in paragraph 6.13.A.2 or 6.13.A.3 caused, directly or indirectly, in whole or in part, by CON- TRACTOR, any Subcontractor, Supplier, or any other individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, shall be remedied by CONTRACTOR (e=ept damage or loss attributable to the fault of Drawings or Specificationa or to the acts or omissions of OWNER or ENGINEER or ENGpMM,s Con- sultant. or anyone employed by any of them, or anyone for whose acts any of them may be liable, and not attributable, directly or indirectly, in whole or in part, to the fault or negligence of CONTRACTOR or any Ste. Supplier, or other individual or entity directly or indirectly employed by any of them). CONTRACTOR's duties and responsibilities for safety and for protection of the Work shall continue until such time as all the Work is completed and ENGINEER has issued a notice to OWNER - and CONTRACTOR in accordance with paragraph 14.07.13 that the Work is acceptable (except as otherwise expressly provided in connection with Substantial Completion). 6.14 Safety Representative A. CONTRACTOR shall designate a qualified and experienced safety representative at the Site whose duties and responsibilities shall be the prevention of accidents and the maintaining and 'supervising of safety precautions and programs. 6.15 Hazard Communication Programs A. CONTRACTOR shall be responsible for coordinating any exchange of mate rial-safety.data sheets or other hazard communication information required to be made available to or exchanged between or among employers at the Site in accordance with Laws or Regulations. 6.16 Emergencies A. In emergencies affecting the safety or protection of persons or the Work or property at the Site or adjacent thereto, CONTRACTOR is obligated to act to prevent threatened damage, injury, or loss. CONTRACTOR shall give ENGINEER prompt written notice if CONTRACTOR believes that any significant changes in the Work or variations from the Contract Documents have been caused thereby or are required as a result thereof. If ENGINEER determines that a change in the Contras Documents is required because of the action taken by CONTRACTOR in response to such an emergency, a Work Change Directive or Change Order will be issued. 6:17 M* Draxdngs and Sampks A. CONTRACTOR shall submit Shop Drawings to ENGINEER for review and approval m accordance with the acceptable schedule of Shop Drawings and Sample submittals. All submittals will be identified as ENGINEER may require and in the number of copies specified in the General Requirements. The data shown on the Shop Drawings will be complete with respect to quantities, dimen- sions, specified performance and design criteria, materials. and similar data to show ENGINEER the services, materials, and equipment CONTRACTOR proposes to provide and to enable ENG24M to review tie information for the limited parposes acquired by paragraph 6.17.E. B. CONTRACTOR shall also submit Samples to ENGINEER for review and approval in accordance with the acceptable schedule of Shop Drawings and Sample 00700-23 submittals. Each Sample will be idcntifted clearly as to material, Supplier, pertinent data such as catalog numbers, and the use for which intended and otherwise as ENGINEER may require to enable ENGINEER to review the submittal for the limited purposes required by paragraph 6.17.E. The numbers of each Sample to be submitted will be as specified in the Specifications. C. Where a Shop Drawing or Sample is required by the Contract Documents or the schedule of Shop Drawings and Sample submittals acceptable to ENGINEER as required by paragraph 2.07, any related Work performed prior to ENGINEER's review and approval of the pertinent submittal will be at the sole expense and responsibility of CONTRACTOR. D. Submittal Procedures 1. Before submitting each Shop Drawing or Sample, CONTRACTOR shall have determined and verified: a. all field measurements, quantities, dimen- sions, specified performance criteria, installation requirements, materials, catalog numbers, and similar information with respect thereto; b. all materials with respect to intended use, fabrication, shipping, handling, storage, assembly, and installation pertaining to the performance of the Work; C. all information relative to means, methods, techniques, sequences, and procedures of construc- tion and safety precautions and programs incident thereto; and d. CONTRACTOR shall also have reviewed and coordinated each Shop Drawing or Sample with other Shop Drawings and Samples and with the requirements of the Work and the Contract Docu- ments. 2. Each submittal shall bear a stamp or specific written indica ion that CONTRACTOR has satisfied CONTRACTOR's obligations under the Contract Documents with respect to CONTRACTOR's review and approval of that submittal. 3. At the time of each submittal, CONTRACTOR shall give ENGINEER specific written notice of such variations, if say, that due Shop= Drawing or Sample submi W may have from the requirements of the Contract Documents, such notice to be in a written com- = mication separate from the submittal; and, in addition, shall cause a specific notation to be made on each Shop Drawing and Sample submitted to ENGINEER for review and approval of each such variation. E. ENGINEER's Review 1. ENGINEER will timely review and approve Shop Drawings and Samples in accordance with the schedule of Shop Drawings and Sample submittals acceptable to ENGINEER. ENGINEER's review and approval will be only to determine if the items covered by the submittals will, after installation or incorporation in the Work, conform to the information given in the Contract Documents and be compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. 2. ENGINEER's .review and approval will not extend to means, methods, techniques, sequences, or procedures of construction (except where a particular means, method, technique, sequence, or procedure of construction is specifically and expressly called for by the Contract Documents) or to safety precautions or programs incident thereto. The review and approval of a separate item as such will not indicate approval of the assembly in which the item functions. 3. ENGINEER's review and approval of Shop Drawings or Samples shall not relieve CONTRACTOR from responsibility for any variation from the require- ments of the Contract Documents unless CONTRACTOR has in writing called ENGINEER's attention to each such variation at the time of each submittal as required by paragraph 6.17.D.3 and ENGINEER has given written approval of each such variation by speci5c written notation thereof incorporated in or accompanying the Shop Drawing or Sample approval; nor will any approval by ENGINEER relieve CONTRACTOR from respond t'1rt" y. for complying with the roquiremeM of paragraph 6.17.D.1. F. Resubmittal Procedures 1. CONTRACTOR shall make corrections required by ENGINEER and shall return the required number of corrected copies of Shop Drawings and submit as required new Samples for review and approval. CON- TRACTOR shall direct specific attention in writing to revisions other than the corrections called for by ENGI- NEER on previous submittals. 6.18 C viodng the Nick A.rCONTRACTOR shall carry on the Work and adhere to the progress schedule during all disputes or dWgmetnaft with OWNER. No Work shall be delayed or postponed pending resolution of any disputes or disagreements, except as permitted by paragraph 15.04 or as OWNER and CONTRACTOR may otherwise agree in writing. 6.19 CONTRACTOR's General Warranty and Guarantee A. CONTRACTOR warrants and guarantees to OWNER, ENGINEER, and ENGINEER's Consultants that all Work will be in accordance with the Contract Documents and will not be defective. CONTRACTOR's warranty and guarantee hereunder excludes defects or damage caused by: 1. abuse, modification, or improper maintenance or operation by persons other than CONTRACTOR, Sub- contractors, Suppliers, or any other individual or entity for whom CONTRACTOR is responsible; or 2. normal wear and tear under normal usage. B. CONTRACTOR's obligation to perform and complete the Work in accordance with the Contract Documents shall be absolute. None of the following will constitute an acceptance of Work that is not in accordance with the Contract Documents or a release of CONTRACTOR's obligation to perform the Work in accordance with the Contract Documents: 1. observations by ENGINEER; 2. recommendation by ENGINEER or payment by OWNER of any progress or final payment; 3. the issuance of a certificate of Substantial Completion by ENGINEER or any payment related thereto by OWNER; 4. use or ocxagmq of the Work or any part thereof by OWNER: S. any acceptance by OWNER or any failure to do. so; 6. any review and approval of.a Shop Drawing or Sample submittal or the ksuance of a notice of acceptabil- ity by ENGINEER; 7. any inspection, test, or approval by others; or S. any correction of defective Work by OWNER. 6.20 lndenuuicadon A. To the fullest extent permitted by Laws and Regula- tions. CONTRACTOR shall indemnify and hold harmless OWNER. ENGINEER. ENGINEER's Consultants, and the officers, directors, partners, employees, agents, and other consultants and suboontrWors of each and any of theta from and against all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to the performance of the Work, provided that any such claim, cost, loss, or damage: 1. is attributable to bodily injury, sickness, disease, or death, or to injury to or destruction. of tangible property (other than the Work itself), including the loss of use resulting therefrom; and 2. is caused in whole or in part by any negligent act or omission of CONTRACTOR, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of. them to perform any of the Work or anyone for whose acts . any. of them may be liable, .regardless of - whether or not caused in part by any negligence or omission of an individual or entity indem- nified hereunder or whether liability is imposed upon such indemnified party by Laws and Regulations regardless of the negligence of any such individual or entity. B. In any and all claims against OWNER or ENGINEER or any of their respective consultants, agents, officers, directors, partners, or employees by any employee (or the survivor or personal representative of such employee) of CONTRACTOR, any Subcontractor, any Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work, or anyone for whose acts any of them may be liable, the indemnification obligation under paragraph 6.20.A shall not be limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for CONTRACTOR of any such Ste. Supplier, or other individual or entity ttader workers' compensation acts, disability benefit am, or other employee benefit. acts. :. C. The indemnification.obligations of CONTRACTOR under paragraph 6.20.A,shaff.not extend to the liability of ENGINEER and ENGINEER'; Consultants or to the officers, directors, partners, employees, agents, and other consultants and subcontractors of each and any of them arising out of. 1. the preparation or approval of, or the failure to prepare or approve. maps. Drawings, opinions. reports. surveys, Change Orders, designs, or Specifications; or 2. giving dir=tions or instructions, or failing to - give them. if that it the primary cause of the h0q or dtfnage. 00700-2s ARTICLE 7 - OTHER WORK 7.01 Related Work at Site A. OWNER may perform other work related to the Project at the Site by OWNER's employees, or let other direct contracts therefor, or have other work performed by utility owners. If such other work is not noted in the Con- tract Documents, then: 1. written notice thereof will be given to CON- TRACTOR prior to starting any such other work; and 2. if OWNER and CONTRACTOR are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times that should be allowed as a result of such other work, a Claim may be made therefor as provided in paragraph 10.05. B. CONTRACTOR shall afford each other contractor who is a party to such a direct contract and each utility owner (and OWNER, if OWNER is performing the other work with OWNER's employees) proper and safe access to the Site and a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such other work and shall properly coordinate the Work with theirs. Unless otherwise provided in the Contract Documents, CON- TRACTOR shall do all cutting, fitting, and patching of the Work that may be required to properly connect or otherwise M2ke its several parts come together and properly integrate with such other work. CONTRACTOR shall not endanger any work of others by cutting. excavating, or otherwise altering their work and will only cut or alter their work with the written .consent of ENGINEER and the others whose work will be affected. The duties and responsibilities of CONTRACTOR under this paragraph are for the benefit of such utility owners and other contractors to the extent that there are comparable provisions for the benefit of CONTRACTOR in said direst contracts between OWNER and such utility owners and other contractors. C. If the proper execution or results of any part of CONTRACTOR's Work depends upon work performed by others under this Article 7. CONTRACTOR shall inspect such other work and promptly report to ENGINEER in writing any delays, defects, or deficiencies in such other work that reader it unavailable or unsuitable for die proper exec utm and results of CONTRACTOR's Work. CONTRACTOR's future -to so report will oxistittite an acceptance of such otter work as fit and proper for integration with CONTRACTOR's Work except for latent defects and deficiencies in such other work. 7.02 Coordination A. If OWNER intends to contract with others for the performance of other work on the Project at the Site, the following will be set forth in Supplementary Conditions: 1. the individual or entity who will have authority and responsibility for coordination of the activities among the various contractors will be identified; 2. the specific matters to be covered by such authority and responsibility will be itemized; and 3. the extent of such authority and responsibilities will be provided. B. Unless otherwise provided in the Supplementary Conditions, OWNER shall have sole authority.and respon- sibility for such coordination. ARTICLE 8 - OWNER'S RESPONSIBILITIES 8.01 Communications to Contractor A. Except as otherwise provided in these General Condi- tions, OWNER shall issue all communications to CONTRACTOR through ENGINEER. 8.02 Replacement of ENGINEER A. In case of termination of the employment of ENGI- NEER, OWNER shall appoint an engineer to whom CONTRACTOR makes no reasonable objection. whose status under the Contract Documents shall be that of the former ENGINEER. 8.03 Furnish Data A. OWNER shall promptly furnish the data required of OWNER under the Contract Documents. 8.04 Pay Promptly When Due A. OWNER shall make payments to CONTRACTOR promptly when they are due as provided in paragraphs 14.02.0 and 14.07.C. 8.05 larsdr and Easements, Reports and Tests A( OWNER's duties in respect of providing lands and eauments and providing engineering surveys to establish reference points are set forth in paragraphs 4.01 and 4.05. Paragraph 4.02 refers to OWNER's identifying and making available to CONTRACTOR copies of reports of explorations I and tests of subsurface conditions and drawings of physical conditions in or relating to existing surface or subsurface structures at or contiguous to the Site that have been utilized by ENGINEER in preparing the Contract Documents. 8.06 Insurance A. OWNER's responsibilities, if any, in respect to pur. chasing and maintaining liability and property insurance are set forth in Article 5. 8.07 Change Orders A. OWNER is obligated to execute Change Orders as indicated in paragraph 10.03. 8.08 Inspections, Tests, and Approvals A. OWNER's responsibility in respect to certain inspec- tions, tests, and approvals is set forth in paragraph 13.03.B. 8.09 Limitations on OWNER's Responsibilities A. The OWNER shall not supervise, direct, or have control or authority over, nor be responsible for. CONTRACTOR's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of CON- TRACTOR to comply with Laws and Regulations applicable to the performance of the Work. OWNER will not be responsible for CONTRACTOR's failure to perform the Work in accordance with the Contract Documents. 8.10 Undisclosed Hazardous Environmental Condition A. OWNER's responsibility in respect to an undisclosed Hazardous Fm*omn=al Condition is set forth in paragraph 4.06. - 5.11 Evidence of Financial Arrangements A. If and to the extent OWNER has agreed to furnish CONTRACTOR reasonable evidence that financial arrangements have been made to satisfy OWNER's obligations under the Contract Documents, OWNER's responsibility in respect thereof will be as set forth in the Supplementary Conditions. ARTICLE 9 - ENGINEER'S STATUS DURING CONSTRUCTION 9.01 OWNERS Representative A. ENGINEER will be OWNER's representative during the construction period. The duties and responsibilities and the limitations of authority of ENGINEER as OWNER's representative during construction are set forth in the Contract Documents and will not be changed without written consent of OWNER and ENGINEER. 9.02 14sits to Site A. ENGINEER will make visits to the Site at intervals appropriate to the various stages of construction as ENGINEER deems . necessary. in order to observe as an experienced and qualified- design professional the progress that has been made and the quality of the various aspects of CONTRACTOR's executed Work. Based on information obtained during such visits and observations, ENGINEER, for the benefit of OWNER, will determine, in general, if the Work is proceeding in accordance with the Contract Documents. ENGINEER will not be required to make exhaustive or continuous inspections on the Site to check the quality or quantity of the Work. ENGINEER's efforts will be directed toward providing for OWNER a greater degree Of confidence that the completed Work will conform generally to the Contract Documents. On the basis of such visits and observations, ENGINEER will keep OWNER informed of the progress of the Work and will endeavor to guard OWNER against defective Work. B. ENGINEER's visits and observations are subject to all the limitations on ENGINEER's authority and responsibility set forth in paragraph 9.10, and particularly, but widuatrtlimitadoa,.durring ocis a result of ENGINEER's visits or observations. of CONTRACTOR's Work ENGINEER will not- supervise, direct, control, or have authority over or be responsible for CONTRACTOR's means, methods, techniques, sequences; or procedures of coasirucxian, or the safety precautions and programs incident thereto, or for any failure of CONTRACTOR to comply with Laws and Regulations applicable to the performance of the Work. 9.03 Project Representative A. If OWNER and ENGINEER agree, ENGINEER will furnish a Resident Project Repraentative to assist ENGINEER in providing more extensive observation of thg Work. The responsibilities and authority and limitations thereon of any such Resident proje;t Representative and assistants will be as provided in paragraph 9.10 and in the SuPPICIMelltalY ConMew. If OWNER designates snottier 00700-27 representative or agent to represent OWNER at the Site who is not ENGINEER's Consultant, agent or employee, the responsibilities and authority and limitations thereon of such other individual or entity will be as provided in the Supple- mentary Conditions. 9.04 Mrifications and Interpretations A. ENGINEER will issue with reasonable promptness such written clarifications or interpretations of the require- ments of the Contract Documents as ENGINEER may deter- mine necessary, which shall be consistent with the intent of and reasonably inferable from the Contract Documents. Such written clarifications and interpretations will be binding on OWNER and CONTRACTOR. If OWNER and CON- TRACTOR are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, that should be allowed as a result of a written clarification or interpretation, a Claim may be made therefor as provided in paragraph 10.05. 9.05 Authorized Variations in Work A. ENGINEER may authorize minor variations in the Work from the requirements of the Contract Documents which do not involve an adjustment in the Contract Price or the Contract Times and are compatible with the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. These may be accomplished by a Field Order and will be binding on OWNER and also on CONTRACTOR, who shall perform the Work involved promptly. If OWNER and CONTRAC- TOR are unable to agree on entitlement to or on the amount or extent, if any, of any adjustment in the Contract Price or Contract Mines, or both, as a result of a Field Order, a Claim may be made therefor as provided in paragraph 10.05. 9.06 Rejecting Defectrre Work A. ENGINEER will have authority to disapprove or reject Work which ENGINEER believes to be defective, or that ENGINEER believes will not produce a completed Project that conforms to the Contract Documents or that will prejudice the integrity of the design concept of the completed Project as a functioning whole as indicated by the Contract Documents. ENGINEER will also have authority to require special inspection or testing of the Work as provided in paragraph 13.04, whether or not the Work is fabricated, installed, or completed. 9.07 AW Drawings, Qiange Orders and Payments A. In connexion with ENGINM's authority as to Shop Drawings mW Samples, see paragraph 6.17. B. In connection with ENGINEER's authority as to Change Orders, see Articles 10, 11, and 12. C. In connection with ENGINEER's authority as to Applications for Payment, see Article 14. 9.08 Determinations for Unit Price Work A. ENGINEER will determine the actual quantities and classifications of Unit Price Work performed by CONTRACTOR. ENGINEER will review with CON- TRACTOR the ENGINEER's preliminary determinations on such matters before rendering a written decision thereon (by recommendation of an Application for Payment or otherwise). ENGINEER's written decision thereon will be final and binding .(except as. modified by ENGINEER to reflect changed factual conditions or more accurate data) upon OWNER . and CONTRACTOR, subject to the provisions of paragraph 10.05. 9.09 Decisions on Requirements of Contract Documents and Acceptability of Work A. ENGINEER will be the initial interpreter of the requirements of the Contract Documents and judge of the acceptability of the Work thereunder. Claims, disputes and other matters relating to the acceptability of the Work, the quantities and classifications of Unit Price Work, the interpretation of the requirements of the Contract Documents pertaining to the performance of the Work, and Claims seeking changes in the Contract Price or Contract Times will be referred initially to ENGINEER in writing; in accordance with the provisions of paragraph 10.05, with a request for a formal decision. B. When ftmcxioaing as interpreter and judge under this paragraph 9.09, ENGINEER will not show partiality to OWNER or `CONTRACTOR sand will not be liable in connection with any interpretation or decision rendered in good faith in such capacity. The rendering of a decision by ENGINEER pursuant to this paragraph 9.09 with respect to any such Claim, dispute, or other matter (except any which have been waived by the making or acceptance of final payment as provided in paragraph 14.07) will be a condition precedent to any exercise by OWNER or CONTRACTOR of such rights or remedies as either may otherwise have under the Coma-Ad Documents or by Laws or Regulations in respect of any such Claim, dispute, or other matter. 9.10 Limitations on ENGIMM s Authority and Respon- sibiGties r A. Neither ENGINEER's authority or responsibility under this Article 9 or under any other provision of the Contract Documents nor any decision made by ENGINEER in good fain either to exercise or not exercise such authority 00700-28 or responsibility or the undertaking, exercise, or performance of any authority or responsibility by ENGINEER shall create, impose, or give rise to any duty in contract, tort, or otherwise owed by ENGINEER to CONTRACTOR, any Subcontractor, any Supplier, any other individual or entity, or to any surety for or employee or agent of any of them. B. ENGINEER will not supervise, direct, control, or have authority over or be responsible for CONTRACTOR's means, methods. techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of CONTRACTOR to comply with Laws and Regulations applicable to the performance of the Work. ENGINEER will not be responsible for CONTRACTOR's failure to perform the Work in accordance with the Contract Documents. C. ENGINEER will not be responsible for the acts or omissions of CONTRACTOR or of any Subcontractor, any Supplier, or of any other individual or entity performing any of the Work. D. ENGINEER's review of the final Application for Payment and accompanying documentation and all mainte- nance and operating instructions, schedules, guarantees, Bonds, certificates of inspection, tests and approvals, and other documentation required to be delivered by paragraph 14.07.A will only be to determine generally that their content complies with the requirements of, and in the case of certificates of inspections, tests, and approvals that the results certified indicate compliance with, the Contract Documents. E. The limitations upon authority and responsibility set forth in this paragraph 9.10 shall also apply to ENGMEER's Consultants, Resident Project Representative, and assistants. ARTICLE 10 - CHANGES IN THE WORK; CLAIMS 10.01 Authorized Clitanges in the Work A. Without invalidating the Agreement and without notice to any surety. OWNER may, at any time or from time to time, order additions, deletions, or revisions in the Work by a Written Amendment, a Change Order, or a Work Change Directive. Upon receipt of any such document, CONTRACTOR shall promptly proceed with the Work involved which will be performed under the applicable conditions of the Contract Documents (except as otherwise specifically provided). B. If OWNER std CONTRACTOR are unable to agree on entitlement to, or on the amount or extent. if nay, of an adjustment in the Contract price or Contract Times, or both, that should be allowed as a result of a Work Change Directive, a Claim may be made therefor as provided in paragraph 10.05. 10.02 Unauthorized Changes in the Work A. CONTRACTOR shall not be entitled to an increase in the Contract Price or an extension of the Contract Times with respect to any work performed that is not required by the Contract Documents as amended, modified, or supplemented as provided in paragraph 3.04, except in the case of an emergency as provided in paragraph 6.16 or in the case of uncovering Work as provided in paragraph 13.04.B. 10.03 Execution of Change Orders A. OWNER and CONTRACTOR shall execute appropriate Change Orders recommended by ENGINEER (or Written Amendments) covering: - 1. changes in the Work which are: (i) ordered by OWNER pursuant to paragraph 10.0l.A, (ii) required because of acceptance of defective Work tinder para- graph 13.08.A or OWNER's correction of defective Work under paragraph 13.09, or (iii) agreed to by the parties; 2. changes in the Contract Price or Contract Times which are agreed to by the parties, including any undisputed sum or amount of time for Work actually performed in xcordance with a Work Change Directive; and 3. changes in the Contract Price or Contract Times which embody the substance of any written decision rendered by .ENGINEER pursuant to paragraph 10.05; Provided that, in liar of executing any such Change Order, an appal may be taken from any such decision M accordance with the- -provision: of the Contract Documents -and applicable Laws and Regulations. but during any.such appeal,. CONTRACTOR shall carry on the Work and adhere -to the progress schedule as provided in paragraph 6.18.A. 10.04 Notification to Surety A. If notice of any change affecting the general scope Of the Work or the provisions of the Contract Documents ( including, but trot limited to, Contract Price or Contract Times) is required by the provisions of any Bond to be given to a surety. the giving of any such notice will be CONTRACTOR's responsibility. The amount of each applicable Bond will be adjusted to reflect the effect of any such change. 00700-29 10.05 Claims and Disputes A. Notice: Written notice stating the general nature of each Claim. dispute, or other matter shall be delivered by the claimant to ENGINEER and the other party to the Contract promptly (but in no event later than 30 days) after the start of the event giving rise thereto. Notice of the amount or extent of the Claim, dispute, or other matter with supporting data shall be delivered to the ENGINEER and the other party to the Contract within 60 days after the start of such event (unless ENGINEER allows additional time for claimant to submit additional or more accurate data in support of such Claim, dispute, or other matter). A Claim for an adjustment in Contract Price shall be prepared in accordance with the provisions of paragraph 12.01.13. A Claim for an adjustment in Contract Time shall be prepared in accordance with the provisions of paragraph 12.02.B. Each Claim shall be accompanied by claimant's written statement that the.adjust- ment claimed is the entire adjustment to which the claimant believes it is entitled as a result of said event. The opposing party shall submit any response to ENGINEER and the claimant within 30 days after receipt of the claimant's last submittal (unless ENGINEER allows additional time). B. ENGINEER's Decision: ENGINEER will render a formal decision in writing within 30 days after receipt of the last submittal of the claimant or the last submittal of the opposing party, if any. ENGINEER's written decision on such Claim, dispute, or other matter will be final and binding upon OWNER and CONTRACTOR unless: 1. an appeal from ENGINEER's decision is taken within the time limits and in accordance with the dispute resolution procedures set forth in Article 16; or 2. if no such dispute resolution procedures have been set forth in Article 16, a written notice of intention to appeal from ENGDMER's written decision is. delivered by OWNER or CONTRACTOR to the other. and to ENGINEER within 30 days after the date of such decision, and a formal proceeding is instituted by the appealing party in a . forum of competent jurisdiction within 60 days after the date of such decision or within 60 days after Substantial Completion, whichever is later (unless otherwise agreed in writing by OWNER and CONTRACTOR), to exercise such rights or remedies as the appealing key may have with respect to such Cl aim, dispute, or other matter in accordance with applicable Laws and Regulati ws. C. If ENGINEER does not render a formal. decision in writing within the time "stated in paragraph 10.05.B, a decision denying the Claim in its entirety shall be deemed to have been issued 31 days after receipt of the last submittal of the claimant or the last submittal of the opposing party, if any. D. No Claim for an adjustment in Contract Price or Contract Tunes (or Milestones) will be valid if not submitted in accordance with this paragraph 10.05. ARTICLE 11 - COST OF THE WORK; CASH ALLOWANCES; UNIT PRICE WORK 11.01 Cost of the Work A. Costs Included: The term Cost of the Work means the sum of all costs necessarily incurred and paid by CON- TRACTOR in the proper performance of the Work. When the value of any Work covered by a Change Order or when a Claim for an.adjustment in Contract Price is determined on the basis of Cost of the Work, the costs to be reimbursed to CONTRACTOR will be only those additional or incremental costs .required because of the change in the Work or because of the event giving rise to the Claim. Except as otherwise may be agreed to in writing by OWNER, such costs shall be in amounts no higher than those prevailing in the locality of the Project, shall include only the following items, and shall not include any of the costs itemized in paragraph 11.01.13. 1. Payroll costs for employees in the direct employ of CONTRACTOR in the performance of the Work under schedules of job classifications agreed upon by OWNER and CONTRACTOR. Such employees shall include without limitation superintendents, foremen, and other personnel employed full time at the Site. Payroll costs for .employees not employed full time on the Work shall be apportioned on the basis of their time spent on the Work. Payroll costs shall include, but not be limited to, salaries and wages plus the cost of fringe benefits. which shall include social security contributions, unem- ployment, excise. and payroll taxes, workers' compensation, health and retirement benefits, bonuses, sick leave, vacation and holiday pay applicable thereto. The .expenses._of_perfonming Work outside of regular working hours. on- Saturday, Sunday, or legal holidays, shall be included in the above to the extent authorized by OWNER. 2. Cost of all materials and equipment furnished and incorporated in the Work, including costs of transportation and storage thereof. and Suppliers' field services required in connection therewith. All cash discounts shall accrue to CONTRACTOR unless OWNER deposits funds with CONTRACTOR with which to make payments, m which case the cash Aisootmts shall accrue to OWNER. All trade discounts. rebates and refunds and returns from sale of surplus materials and equipment shall accrue to OWNER, and CONTRACTOR shall make provisions so that they any be obtained. 3. Payments made by CONTRACTOR to Subc onutictors for Work performed by Subcontractors. If required by OWNER, CONTRACTOR shall obtain competitive bids from subcontractors acceptable to OWNER and CONTRACTOR and shall deliver such bids to OWNER, who will then determine, with the advice of ENGINEER, which bids, if any, will be acceptable. If any subcontract provides that the Subcontractor is to be paid on the basis of Cost of the Work plus a fee, the Subcontractor's Cost of the Work and fee shall be determined in the same manner as CONTRACTOR's Cost of the Work and fee as provided in this paragraph 11.01. 4. Costs of special consultants (including but not limited to engineers, architects, testing laboratories, surveyors, attorneys, and accountants) employed for services specifically related to the Work. 5. Supplemental costs including the following a. The proportion of necessary transportation, travel, and subsistence expenses of CONTRACTOR's employees incurred in discharge of duties connected with the Work. b. Cost, including transportation and mainte- nance, of all materials, supplies, equipment, machinery, appliances, office, and temporary facili- ties at the Site, and hand tools not owned by the workers. which are consumed in the performance of the Work, and cost, less market value, of such items used but not consumed which remain the property of CONTRACTOR. c. Rentals of all eonstrtiction equipment and machinery. Sad the part: thereof whether rented from CONTRAC MR or otbets in accordance with rental agreements approved by OWNER with the advice of ENGINEER, and the costs of transportation, loading, unloading, assembly, dismantling. and removal thereof. All such costs shall be in accordance with the terms of said rental agreements. The rental of any such equipment, ma- chinery, or parts shall cease when the use thereof is no longer necessary for the Work. d. Sales, consumer, use, and other similar taxes related to the Work. and for which CON- TRACTOR is liable, imposed by haws and Regu- lations. = e. Deposits lost for causes other than negli- gence of CONTRACTOR, airy Subcontractor, or anyone &=4 or indirectly employed by nay of them or for whose acts any of them may be liable, and royalty payments and fees for permits and licenses. f. Losses and damages (and related expenses) . caused by damage to the Work, not compensated by insurance or otherwise, sustained by CONTRACTOR in connection with the perfor- mance of the Work (except losses and damages within the deductible amounts of property insurance established in accordance with paragraph 5.06.13), provided such losses and damages have resulted from causes other than the negligence of CONTRACTOR, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable. Such losses shall include . settlements made with the written consent and approval of OWNER. No such losses, damages. and expenses shall be. included in the Cost of the Work for the purpose of determining CONTRACTOR's fee. g. The cost of utilities, fuel, and sanitary facilities at the Site. h. Minor expenses such as telegrams, long distance telephone calls, telephone service at the Site, expressage, and similar petty cash items in connection with the Work. i. When the Cost of the Work is used to determine the value of a Change Order or of a Claim, the cost of premiums for additional Bonds and insurance required because of the changes in the Work or caused by the event giving rise to the Claim. j.. When all the Work is performed as the basis of -cost -plus, the. costs of ptemiutns for all Bonds and insivance CONTRACTOR is sequined by the. Contract • Documents to purchase and maintain. B. Costs Excluded: The term Cost oT the Work shall not include any of the following items; 00700-31 1. Payroll costs and other compensation of CONTRACTOR's officers, executives, principals (of partnerships sad sole ProPrictorshiPs), general manag- ers, engineers, architects, estimators, attorneys, audi- tOfs, Sccotmtaats. Purchasing and contracting agents. expediters, dmcbq s, clerb, and other personnel eatpbyed by CONTRAC M& wbedwr at the Site at in CQNTRACTOR's principal or breach office for generitl administration of the Work and not specifically included in the agreed upon schedule of job classifications referred to is paragraph 11.01.A.1 or specifically covered by paragraph 11.01. k.4, all of which are to be considered administrative costs covered by the CONTRACTOR's fee. 2. Expenses of CONTRACTOR's principal and branch offices other than CONTRACTOR's office at the Site. 3. Any part of CONTRACTOR's capital expenses, including interest on CONTRACTOR's capital employed for the Work and charges against CONTRACTOR for delinquent payments. 4. Costs due to the negligence of CONTRACTOR, any Subcontractor, or anyone directly or indirectly employed by any of them or for whose acts any of them may be liable, including but not limited to,.. the correction of defective Work, disposal of materials or equipment wrongly supplied, and making good any damage to property. 5. Other overhead or general expense costs of any kind and the costs of any item not specifically and expressly included in paragraphs 1 LOLA and I1.O1.B. C. CONMACTOR's Fee: When all the Work is performed on the basis of cost -plus, CONTRACTOR's fee shall be determined as set forth in the Agreement. When the value of any Work covered by a Change Order or when a Claim for an adjustment in Contract Price is determined on the basis of Cost of the Work, CONTRACTOR's fee shall be determined as set forth in paragraph 12.01.C. D. Doamwaatlon: Whenever the Cost of the Work for ,my Pulse is to be determined pursuant to paragraphs 11.01.A and 11.01.B, CONTRACTOR will establish and maintain records thereof in accordance with generally accepted accounting practices and submit in a form acceptable to ENGD;EE.R an itemized cost breakdown .: together with supporting data. 11.02 Cash AAowances A. It is understood that CONTRACTOR has included in the Contract Price all allowances so named in the Contract Documents and shall cause the Work so covered to be performed for such sums as may be acceptable to OWNER and ENGDWML CONTRACTOR agrees that: 1. the allowances include the cost to CONTRAC- TOR (I= any applicable trade discounts) of materials and equipment required by the allowances to be delivered at the Site, and all applicable taxes; and 2. CONTRACTOR's costs for unloading and handling on the Ske, labor, installation costs, overhead, proms, &M odwr eV=es contemplated for the allow- antes have been included in the Contract Price and not in the allowances, and no demand for additional payment on account of any of the foregoing will be valid. B. Prior to final payment, an appropriate Change Order will be issued as recommended by ENGINEER to reflect actual amounts due CONTRACTOR on account of Work covered by allowances, and the Contract Price shall be correspondingly adjusted. 11.03 Unit Price Work A. Where the Contract Documents provide that all or part of the Work is to be Unit Price Work, initially the Contract Price will be deemed to include for all Unit Price Work an amount equal to the sum of the unit price for each separately identified item -of .Unit Price Work times the estimated quantity of each.item as indicated in the Agree- ment. The estimated quantities of items of Unit Price Work are not guaranteed and are solely for the purpose of comparison of Bids and determining an initial Contract Price. Determinations of the actual quantities and classifications of Unit Price Work performed by CONTRACTOR will be made by ENGINEER subject to the provisions of paragraph 9.08. B. Each unit price will be deemed to include an amount considered by CONTRACTOR to be adequate to cover CONTRACTOR's overhead and profit for each separately identified item. C. OWNER or CONTRACTOR may make a Claim for an adjustment in the Contract Price in accordance with paragraph 10.05 if: 00700 -32 1. the quantity of any item of Unit Price Work performed by CONTRACTOR differs materially and sigaificantly:from the estimated quantity of such item indicated in the Agreement; and 2. there is no corresponding adjustment with respect any other item of Work; and 3. if CONTRACTOR believes that CONTRACTOR is entitled to an increase in Contract Price as a result of having incurred additional expense or OWNER believes that OWNER is entitled to a decrease in Contract Price and the parties are unable to agree as to the amount of any such increase or decrease. ARTICLE 12 - CHANGE OF CONTRACT PRICE; CHANGE OF CONTRACT TIMES 12.01 Change of Contract Prig A. The Contract Price may only be changed by a Change Order or by a Written Amendment. Any Claim for an adjustment in the Contract Price shall be based on written notice submitted by the party making the Claim to the ENGINEER and the other party to the Contract in accor- dance with the provisions of paragraph 10.05. B. The value of any Work covered by a Change Order or of any Claim for an adjustment in the Contract Price will be determined as follows: 1. where the Work involved is covered by unit prices contained in the Contract Documents, by applica- tion of such unit prices to the quantities of the items involved (subject to the provisions of paragraph 11.03 ); or 2. where the Work involved is not covered by unit prices contained in the Contract Documents, by a mutually agreed lump sum (which may include an allowance for overhead and profit not necessarily in accordance with paragraph 12.01.C.2); or 3. where the Work involved is not covered by unit prices contained in the Contract Documents and agree- ment to a lump sum is not reached under paragraph 12.0l.B.2, on the basis of the Cost of the Work (determined as provided in paragraph 11.01) plus a CONTRACTOR's fee for overhead and profit (deter- mined as provided in paragraph 12.01.C). C. COM7U C70R's Fee. The CONTRACTOR's fee for overhead and profit shall be determined as follows: 1. a mutually acceptable fixed fee; or 2. if a fixed fee is not agreed upon, then a fee based on the following percentages of the various portions of the Cost of the Work: a. for costs incurred under paragraphs 11.01.A.1 and 11.0I.A.2. the CONTRACTOR's fee shall be 15 percent; b. for costs incurred tinder paragraph 11.O1.A.3, the CONTRACTOR's fee shall be five Pte: C. where one or more tiers of subcontracts are on the basis of Cost of the Work plus a fee and no fixed fee is agreed upon, the intent of paragraph 12.01.C.2.a is that the Subcontractor who actually performs the Work, at whatever tier, will be paid a fee of 15 percent of the costs incurred by such Subcontractor under paragraphs 11.01.A.1 and 11.01.A.2 and that any higher tier Subcontractor and CONTRACTOR will each be paid a fee of five percent of the amount paid to the next lower tier Subcontractor; d. no fee shall be payable on the basis of costs itemized under paragraphs I LO1.AA, 11.O1.A.5, and 11.01.B; e. the amount of credit to be allowed by CONTRACTOR to OWNER for any change which results in a net decrease in cost will be the amount of the actual net decrease.in cost plus a deduction in CONTRACTOR's fee by an amount equal to five percent of such net decrease; and f. when both additions and credits are in- volved in any one change, the adjustment in CONTRACTOR's fee shall be computed on the basis of the net change in accordance with para- graphs 12.01.C.2.a through 12.01.C.2.e, inclu- sive. 12.02 Change of Contract Times A. The Contract Tithes (or Milestones) may only be changed by a Change Order or by a Written Amendment. Any Claim for an adjustment in the Contras Tithes (or Milestones) shall be based on written notice submitted by the party making the claim to the ENGINEER and the other party to the Contract in accordance with the provisions of paragraph 10.05. B. Any adjustment of the Contract Times (or Milestones) covered by a Change Order or of any Claim for an adjustment in the Contract Times (or Milestones) will be determined in accordance with 'the provisions of this Article 12. 12.03 Delays Beyond COMRACTOR's Control A. Where CONTRACTOR is prevented from completing any part of the Work within the Contract rinses (or Milestones) due to delay beyond the contral of CONTRACTOR, the Caatrtct Times (or Milestones) will be extended in an amotmt equal to the time last due to such delay 9 a Claim is made therefor as provided in paragraph 12.02.A. Delays beyond the control of CONTRACTOR shall include, but not be limited to, acts or neglect by OWNER, acts or neglect of utility owners or other contractors performing other work as contemplated by 00700-33 Article 7. fires, floods, epidemics, abnormal weather conditions, or acts of God. 12.04 Delays Within CONTRACTOR's Control A. The Contract Tunes (or Milestones) will not be extended due to delays within the control of CONTRACTOR. Delays attributable to and within the control of a Subcontractor or Supplier shall be deemed to be delays within the control of CONTRACTOR. 12.05 Delays Beyond OWNER's and CONIRACTOR's Control A. Where CONTRACTOR is prevented from complet- ing any part of the Work within the Contract Times (or Milestones) due to delay beyond the control of both OWNER and CONTRACTOR. an extension of the Contract Tithes (or Milestones) in an amount equal to the time lost due to such delay shall be CONTRACTOR's sole and exclusive remedy for such delay. 12.06 Delay Damages A. In no event shall OWNER or ENGINEER be liable to CONTRACTOR, any Subcontractor, any Supplier, or any other person or organization, or to any surety for or employee or agent of any of them, for damages arising out of or resulting from: 1. delays caused by or within the control of CON- TRACTOR; or 2. delays beyond the control of both OWNER and CONTRACTOR including but not limited to fires. floods, epidemics, abnormal weather conditions, ads of God, or acts or neglect by utility owners or other contractors performing other work as contemplated by Article 7. B. Nothing in this paragraph 12.06 bars a change in Contract price pursuant to this Article 12 to compensate CONTRACTOR due to delay, interference, or disruption directly attributable to actions or inactions of OWNER or anyone for whom OWNER is responsible. ARTICLE 13 - TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK_ 13.01 Notice oJDefius A. Prompt notice of all defective Work of which OWNER or ENGINEER has actual knowledge will be give= to CONTRACTOR. All defective Work may be rejected, corrected, or accepted as provided in this Article 13. 13.02 Access to Work A. OWNER, ENGINEER, ENGINEER's Consultants, other representatives and personnel of OWNER, independent testing laboratories, and governmental agencies with jurisdictional interests will have access to the Site and the Work at reasonable times for their observation, inspecting, and testing. CONTRACTOR shall provide them proper and safe conditions for such access and advise them of CONTRACTOR's Site safety procedures and programs so that they may comply therewith as applicable. 13.03 Tests and Inspections A. CONTRACTOR. shall give ENGINEER timely notice of readiness of the Work for all required inspections, tests, or approvals and shall cooperate with inspection and testing personnel to facilitate required inspections or tests. B. OWNER shall employ and pay for the services of an independent testing laboratory to perform all inspections, tests, or approvals required by the Contract Documents except: I. for inspections, tests, or approvals covered by paragraphs 13.03.0 and 13.03.1) below; 2. that costs incurred in connection with tests or inspections conducted pursuant to paragraph 13.04.13 shall be paid as provided in said paragraph 13.04.13; and 3. as otherwise specifically provided in the Con- tract Documents. C. If Laws or Regulations of any public body having jurisdiction require any Work (or part thereof) specifically to be inspected, -tested, or approved by an employee or other representative of such public body, CONTRACTOR shall assume full responsibility for arranging and obtaining such inspections, tests, or approvals, pay all coats in connection therewith, and furnish ENGINEER the required certificates of inspection or approval. D. CONTRACTOR shall be responsible for arranging and obtaining and shall pay all costs in connection with any inspections, tests, or approvals required for OWNER's and ENGINEER's acceptance, of materials or equipment to be incorporated in the Work; or acceptance of matet'ia1s, mist designs, or equipment submitted for approval prior to CONTRACTOR's purchase thereof for incorporation in the Work. Such inspections, tests, or approvals shall be performed by organizations acceptable to OWNER and ENGINEER. 00700 -34 E. If any Work (or the work of others) that is to be inspected, tested, or approved is covered by CONTRACTOR without written concurrence of ENGINEER, it must, if requested by ENGINEER, be uncovered for observation. F. Uncovering Work as provided in paragraph 13.03.E shall be at CONTRACTOR's expense unless CON- TRACTOR has given ENGINEER timely notice of CONTRACTOR's intention to cover the same and ENGI- NEER has not acted with reasonable promptness in response to such notice. 13.04 Uncovering Work A. If any Work is covered contrary to the written request of ENGINEER, it must, if requested by ENGINEER, be uncovered for ENGINEER's observation and replaced at CONTRACTOR's expense. B. If ENGINEER considers it necessary or advisable that covered Work be observed by ENGINEER or inspected or tested by others, CONTRACTOR, at ENGINEER's request, shall uncover, expose, or otherwise make available for observation, inspection, or testing as ENGINEER may require, that portion of the Work in question, furnishing all necessary labor, material, and equipment. If it is found that such Work is defective, CONTRACTOR shall pay all Claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or relating to such uncovering, exposure, observation, inspection, and testing, and of satisfactory replacement or reconstruction (including but not limited to all costs of repair or replacement of work of others); and OWNER shall be entitled to an appropriate decrease in tine Contract Price. If the parties are unable to agree as to the amount thereof. OWNER may make a Claim therefor as provided in paragraph 10.05. If, however, such Work is not found to be defective, CONTRACTOR shall be Allowed an increase in the Contract Price or an extension,of the Contract Times (or Milestones), or both, directly aaribuu- able to such uncovering, exposure, observation, inspection, testing, replacement, and reconstniction, If the parties are unable to agree as to the amount or extent thereof. CONTRACTOR may make a Claim therefor as provided in paragraph 10.05. 13.05 OWNER May Stop the Work A. If the Work is defective, or CONTRACTOR fails to supply sufficient skilled workers or suitable materials or equipment, or fails to perform the Work in such a way that the completed Work will conform to the Contract Docuunents, OWNER may order CONTRACTOR to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of OWNER to stop the Work shall not give rise to any duty on the part of OWNER to exercise this right for the benefit of CONTRACTOR, any Subcontractor, any Supplier, any other individual or entity, or any surety for, or employee or agent of any of them. 13.06 Correction or Removal of Defective Work A. CONTRACTOR shall correct all defective Work, whether or not fabricated, installed, or completed, or, if the Work has been rejected by ENGINEER, remove it from the Project and replace it with Work that is not defective. CONTRACTOR shall pay all Claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and .all court. or. arbitration. or . other dispute resolution costs) arising .out of or relating to such correction or removal (including but not limited. to all. costs of repair or. replacement of work of others). 13.07 Correction Period A. If within one year after the date of Substantial Completion or such longer period of time as may be prescribed by Laws or Regulations or by the terms of any applicable special guarantee required by the Contract Documents or by any specific provision of the Contract Documents, any Work is found to be defective, or if the repair of any damages to the land or areas made available for CONTRACTOR's use by OWNER or permitted by Laws and Regulations as contemplated in paragraph 6.1LA is found to be defective. CONTRACTOR shall promptly, without cost to OWNER and in accordance with OWNER's written instructions: (J) repair such defective land or areas, or (ii) correct such defective Work or, if the defective Work has been rejected by OWNER, remove it fiom the Project-MW replace .it with Work that is act defective, and (vii) satisfac- ..tonly correct oe.repair.or.-remove=d replace any damage to other..-Work, to the-work.-Of others or other land or areas .resulting thereftom:.-,IfMNTRACTOR does not promptly comply with the terms of such instructions, or in an emergency where delay would cause serious risk of loss or damage, OWNER may have the defective Work corrected or repaired or may have the rejected Work removed and replaced, and all Claims, costs, losses, . and damages (including but not limited to all fees and charges of M&etn, uddtects, attomeys, and other professionals and all court or arbitration or other dispute resolution costs) arising out of or elating to suich conution or repair or such removal and replacement (including but not limited to all costs of repair or nglaeement of work of others) will be paid by CONTRACTOR. B. In special circumstances whert~ a particular item of equipment is placed in continuous service before Substantial Completion of all the Work, the cornet:: 3n period for that 00700-35 item may start to run from an earlier date if so provided in the Specifications or by Written Amendment. C. Where defective Work (and damage to other Work resulting therefrom) has been corrected or removed and replaced under this paragraph 13.07, the correction period hereunder with respect to such Work will be extended for an additional period of one year after such correction or removal and replacement has been satisfactorily completed. D. CONTRACTOR's obligations under this paragraph 13.07 are in addition to any other obligation or warranty. The provisions of this paragraph 13.07 shall not be construed as a substitute for or a waiver of the provisions of any applicable statute of limitation or repose. 13.08 Acceptance of Defective Work A. If, instead of requiring correction or removal and replacement of defective Work, OWNER (and, prior to ENGINEER's recommendation of final payment, ENGINEER) prefers to accept it, OWNER may do so. CONTRACTOR shall pay all Claims, costs, losses, and damages (including but not limited to all fees and charges of deers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) attributable to OWNER's evaluation of and determination to accept such defective Work (such costs to be approved by ENGINEER as to reasonableness) and the diminished value of the Work to the extent not otherwise paid by CONTRACTOR pursuant to this sentence. If any such acceptance occurs prior to ENGINEER's recommendation of final payment, a Change Order will be issued incorporating the necessary revisions in the Contact Documents with respect to the Work, and OWNER shall be entitled to as AWL opriate decrease in the Comtracx Price, reflecting the diminished value of Work so accepted. If the parties are unable lo agree as to die amount thereof. OWNER may make a Claim therefor as provided in paragraph 10.05. If the acceptance occurs afar such recommendation, an appropriate amount will be paid by CONTRACTOR to OWNER. 13.09 OWNER May Correct Defective Work A. If CONTRACTOR fails within a reasonable time after written notice from ENGINEER to correct defective Work or to remove and replace rejected Work as required by ENGINEER in accordance with paragraph 13.06.A, or if CONTRACTOR fails to perform the Work in accordance with the Contract Documents. or if CONTRACTOR fails to comply with any other provision of the Contract Documents, OWNER may, after seven days written notice to CONTRACTOR, correct and remedy any such deficiency. B. In exercising the tights and remedies under this paragraph, OWrJER shall proceed expeditiously. In connection with such corrective and remedial action. OWNER may exclude CONTRACTOR from all or part of the Site, take possession of all or part of the Work and suspend CONTRACTOR's services related thereto.- take possession of CONTRACTOR's tools, appliances, con - suwAion equipment and machinery at the Site, and incorpo- rate in the Work all materials and equipment stored at the Site or for which OWNER has paid CONTRACTOR but which are stored elsewhere. CONTRACTOR shall allow OWNER, OWNER's representatives, agents and employees, OWNER's other contractors, and ENGINEER and ENGINEER's Consultants access to the Site to enable OWNER to exercise the rights and remedies under this paragraph. C. .All Claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other.professionals and all court or arbitration or other dispute resolution costs) incurred or sustained by OWNER in exercising the rights and remedies under this paragraph 13.09 will be charged against CON- TRAC'T'OR, and a Change Order will be issued incorporating the necessary revisions in the Contract Documents with respect to the Work; and OWNER shall be entitled to an appropriate decrease in the Contract Price. If the parties are unable to agree as to the amount of the adjustment, OWNER may make a Claim therefor as provided in paragraph 10.05. Such claims, costs, losses and damages will include but not be limited to all costs of repair, or replacement of work of others destroyed or damaged by correction, removal, or replacement of CONTRACTOR's defective Work. D. CONTRACTOR shall not be allowed an extension of the Contract Times (or Milestones) because of any delay in the performance of the Work attributable to the exercise by OWNER of OWNER's rights and remedies under this paragraph 13.09. ARTICLE 14 : PAYMENTS TO CONTRACTOR AND COMPLETION 14.01 Schedule of Values A. The schedule of values established as provided -in paragraph 2.07.A will serve as the basis for progress payments and will be incorporated into a form of Application for Payment acceptable to ENGINEER Progress payments on account of Unit Price Work will be based on the number of units completed. r - T 14.02 Progress Payments A. applications for Payments 1. At least 20 days before the date established for each progress payment (but not more often than once a month), CONTRACTOR shall submit to ENGINEER for review an Application for Payment filled out and signed by CONTRACTOR covering the Work completed as of the date of the Application and accompanied by such supporting documentation as is required by the Contract Documents. If payment is requested on the basis of materials and equipment not incorporated in the Work but delivered and suitably stored at the Site or at another location agreed to in writing, the Application for Payment shall also be accompanied by a bill of sale, invoice, or other docu- mentation warranting that OWNER has received the materials and equipment free and clear of all Liens and evidence that the materials and equipment are covered by appropriate property insurance or other arrangements to protect OWNER's interest therein, all of which must be satisfactory to OWNER. 2. Beginning with the second Application for Payment, each Application shall include an affidavit of CONTRACTOR stating that all previous progress payments received on account of the Work have been applied on account to discharge CONTRACTOR's legitimate obligations associated with prior Applications for Payment. 3. The amount of retainage with respect to pro- gress payments will be as stipulated in the Agreement. B. Review of Applicadons 1. ENGINEER will. within 10 days after receipt of each Application for Payment, either indicate in writing. a recommendation of payment and present : the Application to OWNER or return the Application to CONTRACTOR indicating in writing ENGINEER's reasons for refusing to recommend payment. In the latter case. CONTRACTOR may make the necessary corrections and resubmit the Application. 2. ENGINEER's recommendation of any payment requested in an Application for Payment will constitute a representation by ENGINEER to OWNER, based on ENGINEER's observations on the Site of the executed Work id an experienced and qualified design profession- al and on ENGWEER's review of the Application for Payment and the accompnying data and schedules, that to the best of ENGINEER's knowledge, information and belief. 00700 -37 a. the Work has progressed to the point indicated; b. the quality of the Work is generally in accordance with the Contract Documents (subject to an evaluation of the Work as a functioning whole prior to or upon Substantial Completion, to the results of any subsequent tests called for in the Contract Documents, to a final determination of quantities and classifications for Unit Price Work under paragraph 9.08, and to any other qualifications stated in the recommendation); and c. the conditions precedent to CONTRACTOR's being entitled to such payment appear to have been fulfilled in so far as it is ENGINEER's responsibility to observe the Work. 3. By recommending any such payment ENGI- NEER will not thereby be deemed to have represented that: (i) inspections made to check the quality or the quantity of the Work as it has been performed have been exhaustive, extended to every aspect of the Work in progress, or involved detailed inspections of the Work beyond the responsibilities specifically assigned to ENGINEER in the Contract Documents; or (ii) that there may not be other matters or issues between the parties that might entitle CONTRACTOR to be paid additionally by OWNER or entitle OWNER to withhold payment to CONTRACTOR. 4. Neither ENGINEER's review of CONTRACTOR's Work for the purposes of recom- mending payments nor ENGINEER's recommendation of any payment, including final payment, will impose responsibility on ENGINEER to supervise, direct. or control the Work or for the means, methods, techniques. sequences.-or procedures of.constnkxion, or the safety Precautions and programs.incideat thereto, or for CON - TRACTOR's failure to-comply with Laws and Regu- lations applicable to CONTRACTOR's performance of the Work. Additionally, said review of recommendation will not impose responsibility on ENGINEER to make any examination to ascertain how or for what purposes CONTRACTOR has used the moneys paid on account of the Contract Price, or to determine that title to any of the Work, materials, or equipment has passed to OWNER free and clear of any Liens. S. ENGINEER may refuse to recommend the whole or any part of any payment if. In ENGDMER's opinion, it would be incorrect to make the rgmmnfa- tions to OWNER referred to in paragraph 14.02.13.2. ENGINEER may also refuse to recommend any such payment or, because of subsequently discovered evdence or the results of subsequent 13sper„tions or tests. revise or revoke any such payment recommendation previously trade, to such extent as may be necessary in ENGINEER's opinion to protect OWNER from loss because: a. the Work is defective, or completed Work has been damaged, requiring correction or replace- ment; b. the Contract Price has been reduced by Written Amendment or Change Orders; c. OWNER has been required to correct defective Work or complete Work in accordance with paragraph 13.09; or d. ENGINEER has actual knowledge of •the occurrence of any of the events enumerated in para- graph 15.02.A. OWNER shall promptly pay CONTRACTOR the amount so withheld, or any adjustment thereto agreed to by OWNER and CONTRACTOR, when CONTRAC- TOR corrects to OWNER's satisfaction the reasons for such action. 3. If it is subsequently determined that OWNER's refusal of payment was not justified, the amount wrongfully withheld shall be treated as an amount due as determined by paragraph 14.02.C.1. 14.03 CONTRACTOR's Warranty of 7711e A. CONTRACTOR warrants and guarantees that title to all Work, materials, and equipment covered by any Application for Payment, whether incorporated in the Project or not, will pass to OWNER. no later than the time of payment free and-clear of all Liens. 14.04 Substantial Completion C. Payment Becomes Due A. When CONTRACTOR considers the entire Work 1. Ten days after presentation of the Application ready for its intended use CONTRACTOR shall notify for Payment to OWNER with ENGINEER's recom- OWNER and ENGINEER in writing that the entire Work is mendation, the amount recommended will (subject to the substantially complete (except for items specifically listed by provisions of paragraph 14.02.D) become due, and when CONTRACTOR as incomplete) and request that ENGINEER due will be paid by OWNER to CONTRACTOR. issue a certificate of Substantial Completion. Promptly thereafter, OWNER, CONTRACTOR, and ENGINEER D. Reduction in Payment shall make an inspection of the Work to determine the status of completion. If ENGINEER does not consider the Work 1..OWNER may refuse to make payment of the substantially complete, ENGINEER will notify full amount recommended by ENGINEER because: CONTRACTOR in writing giving the reasons therefor. If ENGINEER considers the Work substantially complete, a. claims have been made against OWNER on ENGINEER will prepare and deliver to OWNER a tentative account of CONTRACTOR's performance or fur- certificate of Substantial Completion which shall fix the date nishing of the Work; of Substantial Completion. There shall be attached to the certificate . a tentative .list . of items to be completed or b. Liens have been filed in connection with�the.-. r corrected beforefinal - payments OWNER shall have seven Work, except where CONTRACTOR has delivered days -after receipt of. die tentative certificate during which to a specific Bond satisfactory to OWNER to secure make written objection to ENGINEER as to any provisions the satisfaction and discharge of such Liens; of the certificate or attached list. If, after considering such objections, ENGINEER concludes that the Work is not c. there are other items entitling OWNER to substantially complete, ENGINEER will within 14 days after a set -off against the amount recommended; or submission of the tentative certificate to OWNER notify CONTRACTOR in writing, stating the reasons therefor. If, d. OWNER has actual knowledge of the occur- after consideration of OWNER's objections, .ENGINEER rence of any of the events enumerated in paragraphs considers the Work substantially complete, ENGINEER will 14.02.B.5.a through 14.02.B.5.c or paragraph within said 14 days execute and deliver to OWNER and 15.02.A. CONTRACTOR a definitive certificate of Substantial Completion (with a revised tentative list of items to be 2. If OWNER refuses to make payment of the full amount recommended by ENGINEER, OWNER must give CONTRACTOR immediate written notice (with a copy to ENGINEER) stating the reasons for such action and promptly pay CONTRACTOR any amount remaining aftt. deduction of the amount so withheld. completed or corrected) reflecting such changes from tentative certificate as ENGINEER believes justified after consideration of any objections from OWNER. At the time of delivery of the tentative certificate of Substantial Comple- tion ENGINEER will deliver to OWNER and CONTRAC- TOR a written recommendation as to division of rapomb"i- 00700 -38 ties pending final payment between OWNER and CONTRACTOR with respect to security, operation, safety, and protection of the Work, maintenance, heat, utilities, insurance, and warranties and guarantees. Unless OWNER and CONTRACTOR agree otherwise in writing and so inform ENGINEER in writing prior to ENGINEER's issuing the definitive certificate of Substantial Completion, ENGINEER's aforesaid recommendation will be binding on OWNER and CONTRACTOR until final payment. B. OWNER shall have the right to exclude CONTRACTOR from the Site after the date of Substantial Completion, but OWNER shall allow CONTRACTOR reasonable access to complete or correct items on the tentative list. 14.05 Partial Utilization A. Use by OWNER at OWNER's option of any substantially completed part of the Work which has specifically been identified in the Contract Documents, or which OWNER, ENGINEER, and CONTRACTOR agree constitutes a separately functioning and usable part of the Work that can be used by OWNER for its intended purpose without significant interference with CONTRACTOR's performance of the remainder of the Work, may be accomplished prior to Substantial Completion of all the Work subject to the following conditions. 1. OWNER at any time may request CON- TRACTOR in writing to permit OWNER to use any such part of the Work which OWNER believes to be ready for its intended use and substantially complete. If CONTRACTOR agrees that such part of the Work is substantially complete, CONTRACTOR will certify to OWNER and ENGINEER that such part of the Work is substantially complete and request ENGINEER to issue a certificate of Substantial Completion for that part of the Work. CONTRACTOR at any .time may notify OWNER and ENGINEER in writing that CONTRACTOR considers any such part of the Work ready for its intended use and substantially complete and request ENGINEER to issue a certificate of Substantial Completion for that part of the Work. Within a reasonable time after either such request, OWNER, CONTRACTOR, and ENGINEER shall make an inspection of that part of the Work to determine its status of completion. If ENGINEER does not consider that part of the Work to be substantially complete, ENGINEER will notify OWNER and CONTRACTOR in writing giving the reasons therefor. If ENGINEER considers that part of the Work to be substantially complete, the provisions of paragraph 14.04 will apply with respect to certification of Substantial Completion of that part of the Work and the division of responsibility in respect thereof and access thereto. 00700 -39 2. No occupancy or separate operation of part of the Work may occur prior to compliance with the requirements of paragraph 5.10 regarding property insurance. 14.06 Final Inspection A. Upon written notice from CONTRACTOR that the entire Work or an agreed portion thereof is complete, ENGINEER will promptly make a final inspection with OWNER and CONTRACTOR and will notify CON- TRACTOR in writing of all particulars in which this inspection reveals that the Work is incomplete or defective. CONTRACTOR shall immediately take such measures as are necessary to complete such Work or remedy such deficiencies. 14.07 Final Payment A. Application for Payment 1. After CONTRACTOR has, in the opinion of ENGINEER, satisfactorily completed all corrections identified during the final inspection and has delivered, in accordance with the Contract Documents, all main- tenance and operating instructions, schedules, guaran- tees, Bonds, certificates or other evidence of insurance certificates of inspection, marked -up record documents (as provided in paragraph 6.12), and other documents, CONTRACTOR may make application for final payment - following the procedure for progress payments. 2. The final Application for payment shall be accompanied (except as previously delivered) by: (i) all documentation pilled for in the Contract Documents, including but not limited to the evidence of inatiranc e required by subparagraph 5:04.8.7: (d) consent of the surety, . if any, to -final payment: and (1h) complete No legally effective--releases-or waivers .(satisfactory to OWNER) of all Lien rights -arising out of or Liens filed in connection with the Work. _ 3. In lieu of the releases or waivers of Liens specified in paragraph 14.07.A.2 and as approved by OWNER, CONTRACTOR may furnish receipts or releases in full and an affidavit of CONTRACTOR that: (i) the releases and receipts include all labor, services, material, and equipment for which a lien could be filed, and (n) all payrolls, material and equipment bills, and other indebtedness connected with the Work for which OWNER or OWNER's property might in any way-be Aponsible have been paid or otherwise satisfied. If any Subcontractor or Supplier fails to furnish such a release or receipt in full, CONTRACTOR- may furnish a Bond or other collateral satisfactory to OWNER to indemnify OWNER against any Lien, B. Review of Application and Acceptance 1. If, on the basis of ENGINEER's observation of the Work during construction and final inspection, and ENGINEER's review of the final Application for Payment and accompanying documentation as required by the Contract Documents, ENGINEER is satisfied that the Work has been completed and CONTRACTOR's other obligations under the Contract Documents have been fulfilled, ENGINEER will, within ten days after receipt of the final Application for Payment, indicate in writing ENGINEER's recommendation of payment and present the Application for Payment to OWNER for pay- ment. At the same time ENGINEER will also give written notice to OWNER and CONTRACTOR that the Work is acceptable subject to the provisions of paragraph 14.09. Otherwise, ENGINEER will return the Application for Payment to CONTRACTOR. indicating in writing the reasons for refusing to recommend final payment, in which case CON- TRACTOR shall make the necessary corrections and resubmit the Application for Payment. C. Payment Becomes Due 1. Thirty days after the presentation to OWNER of the Application for Payment and accompanying docu- mentation, the amount recommended by ENGINEER will become due and, when due, will be paid by OWN- ER to CONTRACTOR. 14.08 Final Completion Delayed A. If, through no fault of CONTRACTOR, final completion of the Work is signifw=dy delayed, and if ENGINEER so confirms, OWNER shall, upon receipt of CONTRACTOR's final Application for Payment and recommendation of ENGINEER, and without terminating the Agrexment, make paymeat of the balance due for that portion of the Work fully completed and accepted. If the remaining balance to be held by OWNER for Work not fully completed or corrected is less than the retainage stipulated in the Agreement, and if Bonds have been furnished as required in paragraph 5.01, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by CON- TRACTOR to ENGINEER with the Application for such payment, Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of Claims. 14.09 Waiver of daims A. The making and acceptance of final payment will constitute: 1. a waiver of all Claims by OWNER against CONTRACTOR. except Claims arising from unsettled Liens, from defective Work appearing after final inspection pursuant to paragraph 14.06, from failure to comply with the Contract Documents or the terms of any special guarantees specified therein, or from CONTRACTOR's continuing obligations under the Contract Documents; and 2. a waiver of all Claims by CONTRACTOR against OWNER other than those previously made in writing which are still unsettled. ARTICLE 15 - SUSPENSION OF WORK AND TERMINATION 15.01 OWNER May Suspend Work A. At any time and without cause, OWNER may suspend the Work or any. portion thereof for a period of not more than 90 consecutive days by notice in writing to CON- TRACTOR and ENGINEER which will fix the date on which Work will be resumed. CONTRACTOR shall resume the Work on the date so fixed. CONTRACTOR shall be allowed an adjustment in the Contract Price or an extension of the Contract Times, or both, directly attributable to any such suspension if CONTRACTOR makes a Claim therefor as provided in paragraph 10.05. 15.02 OWNER May Terntinate for Cause A. The occurrence of any one or more of the following events will justify termination for cause: . .1. CONTRACTOR's persistent failure to perform -. •the Work in accordance with the Contract Documents (including, butnot limited to, failure to supply sufficient skilled. workers or suitable materials or equipment or failure to adhere to the progress schedule established tinder paragraph 2.07 as adjusted from time to time pursuant to paragraph 6.04); 2. CONTRACTOR's disregard of Laws or Regulations of any public body having jurisdiction; 3. CONTRACTOR's disregard of the authority of ENGINEER; or 4. CONTRACTOR's violation in any substantial r way of any provisions of the Contract Documents. B. If one or more of the events identified in paragraph 15.02.A occur, OWNER may, after giving CONTRACTOR (and the qty, if any) seven days written notice, terminate 00700 -40 the services of CONTRACTOR, exclude CONTRACTOR from the Site, and take possession of the Work and of all CONTRACTOR's tools, appliances, construction equipment, and machinery at the Site, and use the same to the full extent they could be used by CONTRACTOR (without liability to CONTRACTOR for trespass or conversion), incorporate in the Work all materials and equipment stored at the Site or for which OWNER has paid CONTRACTOR but which are stored elsewhere, and famish the Work as OWNER may deem expedient. In such case, CONTRACTOR shall not be entitled to receive any further payment until the Work is finished. If the unpaid balance of the Contract Price exceeds all claims, costs, losses, and damages (including but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) sustained by OWNER arising out of or relating to completing the Work, such excess will be paid to CONTRACTOR. If such claims, costs, losses, and damages exceed such unpaid balance, CONTRACTOR shall pay the difference to OWNER. Such claims, costs, losses, and damages incurred by OWNER will be reviewed by ENGINEER as to their reasonableness and, when so approved by ENGINEER, incorporated in a Change Order. When exercising any rights or remedies under this paragraph OWNER shall not be required to obtain the lowest price for the Work performed. C. Where CONTRACTOR's services have been so terminated by OWNER, the termination will not affect any rights or remedies of OWNER against CONTRACTOR then existing or which may thereafter accrue. Any retention or payment of moneys due CONTRACTOR by OWNER will M release CONTRACTOR from liability. 15.03 OWNER May Terminate For Convenience A. Upon seven days written notice to CONTRACTOR and ENGINEER, OWNER may, without cause and-inthout prejudice to any other right or remedy of OWNER, elect to terminate the Contract. In such case, CONTRACTOR shall be paid (without duplication of any items): 1. for completed and acceptable Work executed in accordance with the Contract Documents prior to the effective date of termination, including fair and reasonable sums for overhead and profit on such Work; 2. for expenses sustained prior to the effective date of termination in performing services and furnishing labor. materials, or equiptom as required by the Contract Docttttuats in connection with uncompleted Work, plus fair and reasonable sums for overhead and profit on such expenses; 3. for all claims, costs, losses, and damages (mcluding but not limited to all fees and charges of engineers, architects, attorneys, and other professionals and all court or arbitration or other dispute resolution costs) incurred in settlement of terminated contracts with Subcontractors, Suppliers, and others; and 4. for reasonable expenses directly attributable to termination. B. CONTRACTOR shall not be paid on account of loss of anticipated profits or revenue or other economic loss arising out of or resulting from such termination. 15.04 CON77L4CTOR May Stop Work or Terminate A. If, through no act or fault of CONTRACTOR, the Work is suspended for more than 90-consecutive days by OWNER or-.under•an order of court orotherpublic-authority, or ENGINEER fails to. act. on any.Application for Payment within 30 days after it-is submitted; -or OWNER fails for 30 days to pay CONTRACTOR any sum finally determined to be due, then CONTRACTOR may, upon seven days written notice to OWNER and ENGINEER, and provided OWNER or ENGINEER do not remedy such suspension or failure within that time, terminate the Contract and recover from OWNER payment on the same terms as provided in paragraph 15.03. In lieu of terminating the Contract and without prejudice to any other right or remedy, if ENGI- NEER has failed to act on an Application for Payment within 30 days after it is submitted, or OWNER has failed for 30 days to pay CONTRACTOR any sum finally determined to be due, CONTRACTOR may, seven days after written notice to OWNER and ENGINEER, stop the Work until payment is made of all such amounts due CONTRACTOR, including interest thereon. The provisions of this paragraph 15.04 are not intended to preclude CONTRACTOR from making a Claim under paragraph 10.05 for an adjustment in Contract Price or Contract Ttmes or otherwise -forte or damage directly attra'butable-to CONTRACTOR's-.t toppinrahe Work as permitted by this paragraph. ARTICLE 16 - DISPUTE RESOLUTION 16.01 Methods and Procedures A. Dispute resolution methods and procedures, if any, shall be as set forth in the Supplementary Conditions. If no method and procedure has been set forth, and subject to the provisions of paragraphs 9.09 and 10.05, OWNER and CONTRACTOR may exercise such rights or remedies as either may otherwise have under the Contract Documeata or by Laws or Regulations in respect of any dispute. 00700-41 ARTICLE 17 - MISCELLANEOUS 17.01 Giving Notice A. Whenever any provision of the Contract Documents requires the giving of written notice, it will be deemed to have been validly given if delivered in person to the individual or to a member of the firm or to an officer of the corporation for whom it is intended, or if delivered at or sent by registered or certified mail, postage prepaid, to the last business address (mown to the giver of the notice. 17.02 Computation of Times A. When any period of time is referred to in the Contract Documents by days, it will be computed to exclude the first and include the last day of such period. If the last day of any such period falls on a Saturday or Sunday or on a day made a legal holiday by the law of the applicable jurisdiction, such day will be omitted from the computation. 17.03 Cumulative Remedies A. The duties and obligations imposed by these General Conditions and the rights and remedies available hereunder to the parties hereto are in addition to, and are not to be construed in any way as a limitation of, any rights and remedies available to any or all of them which are otherwise imposed or available by Laws or Regulations, by special warranty or guarantee, or by other provisions of the Contract Documents, and the provisions of this paragraph will be as effective as if repeated specifically in the Contract Documents in connection with each particular duty, obligation. right, and remedy to which they apply. 17.04 Survival of Obligations A. All representations, indemnifications, warranties, and guarantees made in, required by, or given in accordance with the Contract Documents, as well as all continuing obligations indicated in the Contract Documents, will survive final payment, completion, and acceptance of the Work or termination or completion of the Agreement. 17.05 Controlling Law A. This Contract is to be governed by the law of the state in which the Project is located. 00700 - 42 181 ST ACTIVE PARK SECTION 00800 SUPPLEMENTARY CONDITIONS APRIL 10, 2005 The following supplements modify, change from or add to the Standard General Conditions of the Construction Contract, EJCDC Document 1910 -8, 1996 Edition. Where any Article of the General Conditions is modified or any Paragraph, Subparagraph or Clause thereof is modified or deleted by these supplements, the unaltered provisions shall remain in effect. ARTICLE 1 - DEFINITIONS AND TERMINOLOGY Add the following sentence to 1.28 Notice of Award: "When requested by OWNER, the Notice of Award may be issued by the ENGINEER." Add the following sentence to 1.29 Notice to Proceed: "When requested by OWNER, the Notice to Proceed may be issued by ENGINEER." Add the following terms after Paragraph 1.50: 1.51 ARCHITECT /ENGINEER - The person, firm or corporation named as the ENGINEER in the Agreement. 1.52 Provide - As used in the Project Manual, means to furnish and install, complete and ready for intended use. 1.53 Product - As used in the Project Manual, includes materials, fabrications, systems and equipment. 1.54 Project Manual - The volume of written construction documents, including the Bidding Documents, sample forms, and the Contract Documents, such as the Conditions of the Contract and the Specifications. ARTICLE 2 - PRELIMINARY MATTERS Add the following to Paragraph 2.01.: "If the Work is to be commenced prior to execution of the Agreement in response to a letter of intent, CONTRACTOR shall, prior to commencement of the Work, submit evidence satisfactory to OWNER that such bonds will be furnished." In the first line of Paragraph 2.02., change the term "...ten..." to read "...six... ". Delete Paragraph 2.03. and replace with the following: 2.03. The date of commencement of the Work is the date established in a Notice to Proceed. If there is no Notice to Proceed, it shall be the date of the OWNER- CONTRACTOR Agreement or such other date as may be established therein. Add the following to Paragraph 2.05.: D. CONTRACTOR shall perform no portion of the Work at any time without Contract Documents or, where specified, approved Shop Drawings for such portion of the Work. SUPPLEMENTARY CONDITIONS 00800 -1 181ST ACTIVE PARK APRIL 10, 2005 E. By executing the Contract, CONTRACTOR represents that he has visited the site, familiarized himself with the local conditions under which the Work is to be performed, and cor- related his observations with the requirements of the Contract Documents. ARTICLE 3 - CONTRACT DOCUMENTS: INTENT, AMENDING, REUSE Add the following to Paragraph 3.02.A.: 3. Sections of Division One - General Requirements govern the execution of all sections of the Specifications. ARTICLE 4 - AVAILABILITY OF LANDS; SUBSURFACE AND PHYSICAL CONDITIONS; REFERENCE POINTS In Paragraph 4.02.A., change the term "...Supplementary Conditions..." to read "...bidding requirements... ". In Paragraph 4.02.8., change the term "Supplementary Conditions..." to read "...bidding requirements... ". ARTICLE 5 - BONDS AND INSURANCE In the first line of Paragraph 5.04., following the word "...maintain... ", insert the words, "...in a company or companies licensed to do business in the State of Florida,... ". In the last line of Paragraph 5.04.A.6., following the word "...vehicle. ", insert the words ...1 "..., or arising out of operation of laws and regulations for damages because of bodily injury or death of any person or for damage to property." Add the following after Paragraph 5.04.B.7.: 8. Include all major divisions of coverage and be on a comprehensive basis including: i. Premises Operations (including X, C and U coverages as applicable. ii. Independent contractor's Protective. iii. Products and Completed Operations. iv. Personal Injury Liability with Employment Exclusion deleted. V. Contractual Liability. vi. Owned, non -owned and hired motor vehicles. vii. Broad Form property Damage including Completed Operations. 9. Provide coverage for not less than the following amounts. a. Workers' Compensation, etc. under paragraphs 5.4.1 and 5.4.2: 1. State Statutory 2. Applicable Federal (e.g. Longshoreman's) Statutory and /or Maritime) SUPPLEMENTARY CONDITIONS 00800 -2 181sT ACTIVE PARK 3. Employer's Liability b. Contractor's Liability Insurance APRIL 10, 2005 $ 100.000.00 under Article 5.4, which shall also include completed operations and product liability coverages and eliminate the exclusion with respect to property under the care, custody and control of Contractor: 1. General Aggregate (Except Products - Completed Operations) $ 1,000,000.00 2. Products - Completed Operations Aggregate $__1,000,000.00 3. Personal and Advertising Injury (Per Person/ Organization) $_ 1,000,000.00 4. Each Occurrence (Bodily Injury and Property Damage) $_ 1,000,000.00 5. Property Damage liability insurance will provide Explosion, Collapse and Underground coverages where applicable. 6. Excess Liability General Aggregate $ 1,000,000.00 Each Occurrence $_ 1,000,000.00 C. Automobile Liability under paragraph 5.4.6: 1. Bodily Injury: Each Person $ 1,000,000.00 Each Accident $ 1,000,000.00 Property Damage: Each Occurrence $ 1,000,000.00 m SUPPLEMENTARY CONDITIONS 00800 -3 181ST ACTIVE PARK APRIL 10, 2005 2. Bodily Injury and Property Damage Combined Single Limit: Each Occurrence $ 1,000,000.00 Aggregate $ 1,000,000.00 d. Additional liability coverage for OWNER and ENGINEER shall be provided by endorsement as additional insureds on Contractor's General Liability Policy. Add the following names: OWNER - City of Sunny Isles Beach 18070 Collins Avenue Sunny Isles Beach, Florida 33160 ENGINEER - Calvin, Giordano & Associates, Inc. Engineers, Planners & Surveyors 1800 Eller Drive, Suite 600 Fort Lauderdale, Florida 33316 OTHER - The additional liability coverage for ENGINEER is not to be construed as to requiring, in any way, that either OWNER or CONTRACTOR be obligated to supply insurance protecting ENGINEER for its liability emanating from professional errors or omissions. In conformance with the requirements of Section 725.06, Florida Statutes, the specific considerations for CONTRACTOR's promises are: a. One dollar ($1.00) in hand paid by OWNER, ENGINEER, and ENGINEER's employees to CONTRACTOR, receipt whereof is hereby acknowledged and the adequacy of which CONTRACTOR accepts as completely fulfilling the obligations of OWNER, ENGINEER, and ENGINEER's employees under the requirements of Section 725.06, Florida Statutes, and; b. The entry of OWNER and CONTRACTOR into the construction contract because, but for CONTRACTOR's promises as contained in the General Conditions, OWNER would not have entered into the construction contract with CONTRACTOR. Add the following after Paragraph 5.06.E: F. The form of policy for this coverage shall be Completed Value. G. If under the provisions of this insurance there are mandatory deductibles, or if OWNER elects to increase the mandatory deductibles or purchase this insurance with voluntary deductible amounts, then OWNER shall be responsible for payment of the full amount of the deductible in the event of a paid claim. SUPPLEMENTARY CONDITIONS 00800 -4 181ST ACTIVE PARK APRIL 10, 2005 ARTICLE 6 - CONTRACTOR'S RESPONSIBILITIES Add the following after Paragraph 6.05.F: G. The use of asbestos or asbestos -based fiber materials is prohibited in this Project. Add the following after Paragraph 6.08: 6.08.A. The OWNER will secure and pay for only the following governmental charges and inspection fees: a. special assessments, b. capital connection fees, C. threshold and special inspection fees, d. permanent utility meter installation fees, e. permanent utility hook -up fees, and f. impact fees. 6.08.8. CONTRACTOR shall pay for all building permits and charges of utility owners for connections to the Work, and OWNER will pay charges of such utility owners for capital costs related thereto such as plant investment fees. Delete the last sentence of Paragraph 6.12. and substitute the following: "These shall be available to ENGINEER for examination during construction and shall be delivered "to ENGINEER for OWNER upon Substantial Completion of the Work." At the end of Paragraph 6.13.B, add the following sentences: "The Occupational Safety and Health Administration excavation safety standards, 29 CFR 1926.650 Subpart P trench safety standards are in effect during the period of construction of the Project. In compliance with current State of Florida statutes, the Contractor or subcontractor performing trench excavation work on the Project shall comply with the applicable trench safety standards." In the sixth line of Paragraph 6.20.A., change the parenthetical insert to read as follows: "...(including but not limited to fees and charges of ENGINEER, other engineers, architects, attorneys and other professionals, particularly including, but not limited to reasonable ENGINEER's attorney's fees, and court costs)... ". ARTICLE 9 - ENGINEER'S STATUS DURING CONSTRUCTION Change the first sentence of Paragraph 9.01.A. to read as follows: "If OWNER and ENGINEER agree, ENGINEER will be OWNER's representative during the construction period." ARTICLE 10 - CHANGES IN THE WORK; CLAIMS Add the following: 10.06. Without invalidating the agreement, Owner may, at any time execute appropriate Change Orders for additions and /or deletions in the work of up to 25% of the total contract amount, without a change in the contract unit prices bid. SUPPLEMENTARY CONDITIONS 00800 -5 181ST ACTIVE PARK APRIL 10, 2005 ARTICLE 13 - TESTS AND INSPECTIONS; CORRECTION, REMOVAL OR ACCEPTANCE OF DEFECTIVE WORK 13.03. TEST AND INSPECTIONS: Replace 13.03.B. with "All testing shall be paid for by the Contractor." Add the following sentence to Paragraph 13.07.A.: "Specific and special warranties specified in the Contract Documents are in addition to, and not in lieu of, the contractors general warranty. CONTRACTOR shall not be relieved of general warranty obligations by the specification of specific products or procedures." 13.09. OWNER MAY CORRECT DEFECTIVE WORK: Change the first line from: If Contractor fails within a reasonable time after written notice of Engineer To read: If Contractor fails within ten (10) calendar days after written notice of Engineer... ARTICLE 14 - PAYMENTS TO CONTRACTOR AND COMPLETION In the first sentence of Paragraph 14.02.A.1., change the phrase "At least twenty days before each progress payment is scheduled (but not more often than once a month), ..." to read "By no later than the first day of the month, ... ". Add 14.02.A.4: "An original Partial Release of Lien is required from the General Contractor along with the application for Payment No. 1 and for each subsequent application thereafter. For each application for payment (excluding Application No. 1) the Contractor shall submit with the application Partial Releases of Liens for all Notice to Owners that have been received for the project by the Owner and Engineer ". In Paragraph 14.02.8., change the beginning of the sentence from "Ten days..." to read "Forty - five days... ". In the first sentence of Paragraph 14.05.A.2., following the word "...Work... ", insert the words "...or to place and install equipment... ". At the end of Paragraph 14.07.A.2. after, ...with the Work. Insert, "(iv) acceptance by the Owners and governing agencies." ARTICLE 15 - SUSPENSION OF WORK AND TERMINATION In the twentieth line of Paragraph 15.02.B., insert the following after the words ... such excess...; "...(including but not limited to fees and charges of ENGINEER, other engineers, architects, attorneys and other professionals, particularly including, but not limited to reasonable Engineer's attorney's fees, and court costs)... ". SUPPLEMENTARY CONDITIONS 00800 -6 181sT ACTIVE PARK ARTICLE 16 - DISPUTE RESOLUTION Delete in its entirety. ARTICLE 17 — MISCELLANEOUS Add 17.05.6: `The venue for any cause of action shall be Dade County." END OF DOCUMENT SUPPLEMENTARY CONDITIONS APRIL 10, 2005 00800 -7 181sT ACTIVE PARK THIS PAGE LEFT INTENTIONALLY BLANK. SUPPLEMENTARY CONDITIONS APRIL 10, 2005 00800 -8 181" ACTIVE PARK SECTION 00900 Addendum No. 1 to Contract documents CITY OF SUNNY ISLES BEACH 181 ST DRIVE ACTIVE PARK 18115 NORTH BAY ROAD MLA PROJECT NO.: 114122 CITY BID NO.: 05 -04 -01 To All Bidders: APRIL 10, 2005 Bidders for the above - referenced project shall take note of the following changes, additions, deletions, clarifications, etc. to the Plans and Specifications, which in accordance with the Contract Documents shall become a part of and have precedence over anything shown or described otherwise. All other documents, specifications, drawings, terms and conditions remain the same. Bidders must acknowledge receipt of Addendum on Page 00300 -3. END OF SECTION ADDENDA 900 -1 181sT ACTIVE PARK THIS PAGE LEFT INTENTIONALLY BLANK. ADDENDA APRIL 10, 2005 900 -2 181" ACTIVE PARK APRIL10, 2005 CERTIFICATE AS TO AUTHORIZED CORPORATE PERSONNEL I certify that I am the of who signed the Bid with City of Sunny Isles Beach, Dade County Florida for the project titled , Miller Legg Project No. 114122, and that the following persons have the authority to sign payment requests on behalf of the Corporation: (Signature) (Signature) (Signature) Signed and sealed this day of (SEAL) 20 (Typed Name w/Title) (Typed Name w/Title) (Typed Name w/Title) Signature ryped w/Title STATE OF FLORIDA COUNTY OF DADE SWORN TO AND SUBSCRIBED before me this — day of My Commission Expires: Notary Public 20 EJCDC STANDARD FORM OF AGREEMENT 00500 -9 181ST ACTIVE PARK THIS PAGE INTENTIONALLY LEFT BLANK. EJCDC STANDARD FORM OF AGREEMENT APRILI0, 2005 00500 -10