Loading...
HomeMy WebLinkAboutReso 2011-1742 RESOLUTION NO. 2011 - ~2 A RESOLUTION OF THE CITY COMMISSION OF THE CITY OF SUNNY ISLES BEACH, FLORIDA, APPROVING AN AGREEMENT WITH DADE CONTRACTING, INC. FOR THE INSTALLATION OF A W ALKW A Y WITHIN GOLDEN SHORES PARK, IN AN AMOUNT NOT TO EXCEED SEVENTEEN THOUSAND NINE HUNDRED DOLLARS ($17,900.00), ATTACHED HERETO AS EXHIBIT "A"; AUTHORIZING THE MAYOR TO EXECUTE SAID AGREEMENT; AUTHORIZING THE CITY MANAGER TO DO ALL THINGS NECESSARY TO EFFECTUATE THIS RESOLUION; PROVIDING FOR AN EFFECTIVE DATE. WHEREAS, the City of Sunny Isles Beach desires to have a walkway through the Golden Shores area in order for citizens and visitors to safely cross under the William Lehman Causeway to Heritage Park; and WHEREAS, the City is in need of a Contractor to provide the desired services, and received quotes from three contractors; and WHEREAS, Dade Contracting, Inc. had the lowest responsive responsible quote, and was willing and able to provide the desired services; and WHEREAS, the City wishes to enter into an Agreement with Dade Contracting, Inc. to install a walkway within Golden Shores Park, in an amount not to exceed Sixteen Thousand Nine Hundred Dollars ($16,900.00), including a contingency in the amount of One Thousand Dollars ($1,000.00) for a total amount not to exceed Seventeen Thousand Nine Hundred Dollars ($17,900.00), attached hereto as Exhibit "A". NOW THEREFORE, BE IT RESOLVED BY THE CITY COMMISSION OF THE CITY OF SUNNY ISLES BEACH, FLORIDA, AS FOLLOWS: Section 1. Approval of Agreement. The City Commission hereby approves an Agreement with Dade Contracting, Inc. to install a walkway within Golden Shores Park, in a total amount not to exceed Seventeen Thousand Nine Hundred Dollars ($17,900.00), attached hereto as Exhibit "A". Section 2. Authorization of Mayor. The Mayor is hereby authorized to execute said Agreement. Section 3. Authorization of City Manager. The City Manager is hereby authorized to do all things necessary to effectuate this Resolution. Section 4. Effective Date. This Resolution will become effective upon adoption. PASSED AND ADOPTED this 21 st day of July 2011. RZOII- Dade Contracting Inc Agmt Walkway thru Golden Shores Page 1 of2 ~ , I ATTEST: . . ~A.~ . Jane A. Hipes, CMC, City Clerk \ .~ I ~ ~..! . . .... .. . ~ J APPROVED AS TO FORM AND EG L S FICIENCY: Vote: S-t> Mayor Edelcup Vice Mayor Thaler Commissioner Aelion Commissioner Gatto Commissioner Scholl 0Yes) ~Yes) ~Yes) ~(Y es) ~(Yes) RZO 11- Dade Contracting Inc Agmt Walkway thru Golden Shores Moved by: ~ ~~L\Ot0 Seconded by: 'V\C,p 'N\~ W~ _(No) _(No) _(No) _(No) _(No) Page 2 of2 CITY OF SUNNY ISLES BEACH MAINTENANCE SERVICE AGREEMENT WITH DADE CONTRACTING, INC. CONTRACT NO. CIOII-062 TillS CONTRACTUAL AGREEMENT (hereinafter referred to as the "Agreement") is made in duplicate, this _ day of ,2011, by and between the CITY OF SUNNY ISLES BEACH, Florida, (hereinafter referred to as "City"), and DADE CONTRACTING, INe., a corporation authorized to do business in the State of Florida (hereinafter referred to as "Contractor") whose Federal I.D. # is RECIT ALS WHEREAS, the City is in need of a contractor to provide site preparation and installation of a fence and gate located at the Golden Shores Community Park, 201-191 Terrace, Sunny Isles Beach ("Services"); and WHEREAS, Contractor has expressed the ability and desire to provide theses Services subject to the terms and conditions contained herein; and WHEREAS, the City desires to contract with Contractor to provide the Services, as more fully described in Attachment "A" which is attached hereto; and WHEREAS, the City desires to enter into an Agreement with Contractor to provide the Services in a total amount not to exceed Sixteen Thousand Nine Hundred Dollars ($16,900.00). NOW THEREFORE, in consideration of the promises and the mutual covenants herein name, the parties agree as follows: 1. RECIT ALS. The Recitals set forth above are hereby incorporated into this Agreement and made a part hereof for reference. 2. SERVICES. Contractor agrees to furnish all labor and materials in a good workmanlike and professional manner and to perform the Services designated in Attachment "A" attached hereto, and incorporated herein by reference. The Services shall be performed by Contractor to the full satisfaction of the City. Contractor agrees to have a qualified representative to audit and inspect the Services provided on a regular basis to ensure all Services are being performed in accordance with the City's needs and pursuant to the terms of this Agreement, and shall report to the City accordingly. Contractor agrees to immediately inform the City via telephone and in writing of any problems that could cause damage to the City's property, improvements and persons. Contractor will require its employees to perform their work in a manner befitting the type and scope of work to be performed. In the event that the Contractor fails to complete the Services pursuant to the terms of this contract and City must undertake the completion of performance of Services, Contractor agrees to indemnify the City for all costs incurred with respect to the completion of those Services and any damages the City may suffer as a result of the Contractor's failure to perform the Services. ClOII-062 - AGREEMENT WITH DADE CONTRACTING, INC. SIB City of Sunny Isles Beach 18070 Collins Avenue, Sunny Isles Beach, Florida 33160 (305) 947-0606 phone (305) 949-3 I 13 Fax 3. TERM. Subject to the provisions relating to the termination of this Agreement as set forth hereunder, the term of this Agreement shall begin upon issuance of Notice to Proceed from the City Manager or his designee and the Services shall be completed no later than 45 (Forty- Five) days thereafter. Payment will be made only for work completed to the satisfaction of the City. Contractor is to commence performance of work on the Commencement Date and continue in a diligent manner until work is complete. Contractor acknowledges that compliance with the commencement and completion schedule is the essence of this Agreement. The terms of Sections 17 and 18 entitled "Indemnification and Waiver of Liability" and "Compliance with Law" respectively, shall survive termination of this Agreement. 4. COMPENSATION. Payment to Contractor for all charges and tasks under this Agreement shall be in accordance with this Agreement and the schedule of charges reflected in Attachment "A", which fee shall be disbursed on a monthly basis and under the following conditions: a. Disbursements. There are no reimbursable expenses associated with this contract. b. Payment Schedule. Invoices received from the Contractor pursuant to this Agreement will be reviewed by the initiating City Department. If Services have been rendered in conformity with the Agreement, the invoice will be sent to the Finance Department for payment. Invoices must reference the contract number assigned hereto. Invoices will be paid in accordance with the State of Florida Prompt Payment Act. c. Availability of Funds. The City's performance and obligation to pay under this Agreement is contingent upon an annual appropriation for its purpose by the City Commission. d. Final Invoice. In order for both parties herein to close their books and records, the Contractor will clearly state "final invoice" on the Contractor's final/last billing to the City. This certifies that all services have been properly performed and all charges and costs have been invoiced to the City. Since this account will thereupon be closed, any other additional charges, if not properly included on this final invoice, are waived by the Contractor. Contractor shall make no other charges to the City for supplies, labor, taxes, licenses, permits, overhead or any other expenses or costs unless any such expense or cost is incurred by Contractor with the prior written approval of the City. If the City disputes any charges on the invoices, it may make payment of the uncontested amounts and withhold payment on the contested amounts until they are resolved by agreement with Contractor. 2 C 1 0 11-062 - AGREEMENT WITH DADE CONTRACTING, INC. SIB City of Sunny Isles Beach 18070 Collins Avenue, Sunny Isles Beach, Florida 33160 (305) 947-0606 phone (305) 949-3113 Fax Contractor shall not pledge the City's credit or make it a guarantor of payment or surety for any contract, debt, obligation, judgment, lien, or any form of indebtedness. The Contractor further warrants and represents that it has no obligation or indebtedness that would impair its ability to fulfill the terms of this Agreement. 5. AVAILABILITY OF FUNDS. The City's performance and obligation to pay under this Agreement is contingent upon an annual appropriation for its purpose by the City Commission. 6. INDEPENDENT CONTRACTOR RELATIONSHIP. The Contractor IS an independent Contractor and shall be treated as such for all purposes. Nothing contained in this Agreement or any action of the parties shall be construed to constitute or to render the Contractor an employee, partner, agent, shareholder, officer or in any other capacity other than as an independent Contractor other than those obligations which have been or shall have been undertaken by the City. Contractor shall be responsible for any and all of its own expenses in performing its duties as contemplated under this Agreement. The City shall not be responsible for any expense incurred by the Contractor. The City shall have no duty to withhold any Federal income taxes or pay Social Security services and that such obligations shall be that of the Contractor, other than those set forth in this Agreement. Contractor shall furnish its own transportation, office and other supplies as it determines necessary in carrying out its duties under this Agreement. 7. OWNERSHIP OF DOCUMENTS AND EQUIPMENT. All documents prepared by the Contractor pursuant to this Agreement and related Services to this Agreement are intended and represented for the ownership of the City only. Any other use by Contractor or other parties shall be approved in writing by the City. If requested, Contractor shall deliver the documents to the City within fifteen (15) calendar days. 8. INSURANCE. Contractor shall, at its sole cost and expense, during the period of any work being performed under this Agreement, procure and maintain the following minimum insurance coverage to protect the City and Contractor against all loss, claims, damage and liabilities caused by Contractor, its agents, sub-Contractor s or employees, as indicated below: o Comprehensive General liability insurance, including broad form contractual liability coverage for all operations, including, but not limited to, contractual, products, and completed operations, personal injury and property damage liability with minimum limits of One Million Dollars ($1,000,000) per occurrence and Two Million Dollars ($2,000,000) aggregate. o Worker's Compensation, as required by law, but with no less than $1,000,000 for Employer's Liability. 3 C 1 0 11-062 - AGREEMENT WITH DADE CONTRACTING. INC. SIB City of Sunny Isles Beach 18070 Collins Avenue, Sunny Isles Beach, Florida 33160 (305) 947-0606 phone (305) 949-3113 Fax o Business Automobile Liability which shall include coverage for all owned, non- owned and hired vehicles for minimum limits of not less than One Million Dollars ($1,000,000) per occurrence, One Million Dollars ($1,000,000) per accident for bodily injury and Five Hundred Thousand Dollars ($500,000) per accident for property damage. Insurance required of the Contractor shall be primary to, and not contribute with, any insurance or self-insurance maintained by the City. Such insurance shall not diminish Contractor's indemnification and obligations hereunder. The insurance policy(ies) shall be issued by companies authorized to do business under the laws of the State of Florida and acceptable to the City with a minimum A.M. Best rating of A-Excellent. Before any work under this Agreement is performed, and at any time upon request, Contractor shall furnish to the City certificates of insurance evidencing the minimum required coverage and shall be appropriately endorsed for contractual liability, with the City named as additional insured. All policies shall contain a waiver of subrogation endorsement. All policies and certificates shall be in forms and issued by insurance companies acceptable to the City Manager or his designee. All insurance policies and certificates of insurance shall provide that the policies may not be canceled or altered without thirty (30) days prior written notice to the City. The City reserves the right from time to time to change the insurance coverage and limits of liability required to be maintained by Contractor hereunder. Contractor shall also require and ensure that each of its sub-Contractor s providing services hereunder (if any) procures and maintains, until the completion of the services, insurance of the types and to the limits specified herein. ANY EXCEPTIONS TO THE INSURANCE REQUIREMENTS IN THIS SECTION MUST BE APPROVED IN WRITING BY THE CITY. 9. TERMINATION AND REMEDIES FOR BREACH. A. If, through any cause within reasonable control, the Contractor shall fail to fulfill in a timely manner or otherwise violate any of the covenants, agreements or stipulations material to this Agreement, the City shall have the right to terminate the Services then remaining to be performed. Prior to the exercise of its option to terminate for cause, the City shall notify the Contractor of its violation of the particular terms of the Agreement and grant Contractor ten (10) days to cure such default. If the default remains uncured after ten (10) days the City may terminate this Agreement, and the City shall receive a refund from the Contractor in an amount equal to the actual cost of a third party to cure such failure. If Contractor fails, refuses or is unable to perform any term of this Agreement, City shall pay for services rendered as of the date of termination. (i.) In the event of termination, all finished and unfinished documents, data and other work product prepared by Contractor (and sub Contractor (s)) shall be 4 C 10 J 1-062 - AGREEMENT WITH DADE CONTRACTING. INC. SIB City of Sunny Isles Beach 18070 Collins Avenue, Sunny Isles Beach, Florida 33160 (305) 947-0606 phone (305) 949-3113 Fax delivered to the City and the City shall compensate the Contractor for all Services satisfactorily performed prior to the date of termination, as provided in Paragraph 4 herein. (ii.) Notwithstanding the foregoing, the Contractor shall not be relieved of liability to the City for damages sustained by it by virtue of a breach of the Agreement by Contractor and the City may reasonably withhold payment to Contractor for the purposes of set-off until such time as the exact amount of damages due the City from the Contractor is determined. B. Termination for Convenience of City. The City may, for its convenience and without cause terminate the Services then remaining to be performed at any time by giving Contractor ten (10) days written notice. The terms of Paragraph 9 A(i) and A(ii) above shall be applicable hereunder. C. Termination for Insolvency. The City also reserves the right to terminate the remaining Services to be performed in the event the Contractor is placed either in voluntary or involuntary bankruptcy or makes any assignment for the benefit of creditors. 10. ARBITRATION. It is the intention of the parties that whenever possible, if a dispute or controversy arises hereunder then such dispute or controversy shall be settled by arbitration in accordance with the procedures, rules and regulations of the American Arbitration Association. The decision rendered by the Arbitrator shall be final and binding upon the parties and judgment upon the award rendered by the arbitrator may be entered in any court having jurisdiction. Arbitration shall be held in Miami-Dade County, Florida. All costs of arbitration and attorneys' fees incurred by the parties shall be paid by the non-prevailing party or, if neither party prevails on the whole, each party shall be responsible for a portion of the costs of arbitration and their respective attorneys' fees as may be determined by the court on confirmation. 11. CONFIDENTIAL INFORMATION. The Contractor shall not, either during the term of this Agreement or any time for a period of ten (10) years subsequent to that date upon which the Contractor shall leave the employment of the City for any reason whatsoever, disclose to any person or entity, other than in the discharge of the duties of the Contractor under this Agreement, any information which the City designates in writing as "confidential." As a violation by the Contractor of the provisions of this Section could cause irreparable injury to the City and there is no adequate remedy at law for such violation, the City shall have the right, in addition to any other remedies available to it at law or in equity, to enjoin the Contractor from violating such prOVISIons. 12. NOTICES.. All notices and other communications required or permitted to be given under this Agreement by either party to the other shall be in writing and shall be sent (except as otherwise provided herein) (i) by certified or registered mail, first class postage prepaid, return 5 ClOll-062 - AGREEMENT WITH DADE CONTRACTING. INC. f"'rn 010 City of Sunny Isles Beach 18070 Collins Avenue, Sunny Isles Beach, Florida 33160 (305) 947-0606 phone (305) 949-3113 Fax receipt requested, (ii) by guaranteed overnight delivery by a nationally recognized courier service, or (iii) by facsimile with confirmation receipt (with a copy simultaneously sent by certified or registered mail, first class postage prepaid, return receipt requested or by overnight delivery by traditionally recognized courier service), addressed to such party as follows: If to the City: Alan J. Cohen With a copy to: City Manager Hans Ottinot City of Sunny Isles Beach City Attorney 18070 Collins A venue City of Sunny Isles Beach Fourth Floor 18070 Collins A venue Sunny Isles Beach, Florida 33160 Fourth Floor Tel: (305)-792-1701 Sunny Isles Beach, Florida 33160 Tel: (305)-792-1702 If to the Contractor: Wayne Bearden Dade Contracting, Inc. 7000 NW 53rd Terr Miami, Florida 33166 Tel: (305) 885-8851 13. GOVERNING LA W. This Agreement shall be governed by and construed in accordance with the laws of the State of Florida. Venue shall be in Miami-Dade County, Florida. 14. AUDIT. The Contractor shall make available to the City or its representative all required financial records associated with the Agreement for a period of THREE (3) years. 15. NON-DISCRIMINATION. The Contractor agrees to comply with all local and state civil rights ordinances and with Title VI of the Civil Rights Act of 1984 as amended, Title VIII of the Civil Rights Act of 1968 as amended, Title 1 of the Housing and Community Development Act of 1974 as amended, Section 504 of the Rehabilitation Act of 1973, the Americans with Disabilities Act of 1990, the Age Discrimination Act of 1975, Executive Order 11063, and with Executive Order 11248 as amended by Executive Orders 11375 and 12086. The Contractor will not discriminate against any employee or applicant for employment because of race, color, creed, religion, ancestry, national origin, sex, disability or other handicap, age, marital/familial status, or status with regard to public assistance. The Contractor will take affirmative action to insure that all employment practices are free from such discrimination. Such employment practices include but are not limited to the following: hiring, upgrading, demotion, transfer, recruitment or recruitment advertising, layoff, termination, rates of payor other forms of compensation, and selection for training, including apprenticeship. The Contractor agrees to post in conspicuous places, available to employees and applicants for employment, notices to be provided by the City setting forth the provisions of this non- discrimination clause. 6 C I 0 1 1-062 - AGREEMENT WITH DADE CONTRACTING. INC. n<<;:, \JIU City of Sunny Isles Beach 18070 Collins Avenue, Sunny Isles Beach, Florida 33160 (305) 947-0606 phone (305) 949-3113 Fax The Contractor agrees to comply with any Federal regulations issued pursuant to compliance with Section 504 of the Rehabilitation Act of 1973 (29 U.S.c. 708), which prohibits discrimination against the handicapped in any Federally assisted program. 16. CONFLICT OF INTEREST. The Contractor agrees to adhere to and be governed by the Miami-Dade County Conflict of Interest Ordinance Section 2-11.1, as amended; and by the City of Sunny Isles Beach Ordinance No. 99-82, which are incorporated by reference herein as if fully set forth herein, in connection with the Agreement conditions hereunder. The Contractor covenants that it presently has no interest and shall not acquire any interest, directly or indirectly which should conflict in any manner or degree with the performance of the Services. The Contractor further covenants that in the performance of this Agreement, no person having any such interest shall knowingly are employed by the Contractor. The Contractor guarantees that he/she has not offered or given to any member of, delegate to the Congress of the United States, any or part of this contract or to any benefit arising therefrom. 17. INDEMNIFICATION AND WAIVER OF LIABILITY. The Contractor agrees, to the fullest extent permitted by law, to defend, indemnify and hold harmless the City, its agents, representatives, officers, directors, officials and employees from and against claims, damages, losses and expenses (including but not limited to attorney's fees, arbitration costs, and costs of appellate proceedings) relating to, arising out of or resulting from the Contractor's negligent acts, errors, mistakes or omissions relating to professional services in the performance of this Agreement. The Contractor's duty to defend, hold harmless and indemnify the City, its agents, representatives, officers, directors, officials and employees shall arise in connection with any claim, damage, loss or expense that is attributable to bodily injury; sickness; disease; death; or injury to impairment, or destruction of tangible property including loss of use resulting therefrom, caused by any negligent acts, errors, mistakes or omissions related to professional services in the performance of this Agreement including any person for whose acts, errors, mistakes or omissions the Contractor may be legally liable. The parties agree that One Hundred Dollars ($100.00) represents specific consideration to the Contractor for the indemnification set forth in this Agreement. 18. COMPLIANCE WITH LAW. Contractor shall comply with all laws, regulations and ordinances of any federal, state, or local governmental authority having jurisdiction with respect to this Agreement ("Applicable Laws") and shall obtain and maintain any and all material permits, licenses, approvals and consents necessary for the lawful conduct of the activities contemplated under this Agreement. 19. CONFLICTING PROVISIONS. The terms and conditions in this Agreement supersede any other conflicting provisions that are contained in any other document, including any attachments hereto. 7 C 1 0 11-062 - AGREEMENT WITH DADE CONTRACTING. INC. S;B - - - -- - --- City of Sunny Isles Beach 18070 Collins Avenue, Sunny Isles Beach, Florida 33160 (305) 947-0606 phone (305) 949-3113 Fax 20. LIQUIDATED DAMAGES AND OTHER REMEDIES FOR DELAY. In the event the Services are not completed within 45 (Forty-Five) days from the issuance date of a Notice to Proceed from the City Manager or his designee, and in the absence of any extensions granted by City, then the Contractor shall be required to pay a liquidated damage penalty of $300.00 (Three Hundred Dollars) for each calendar day beyond the 45 (Forty-Five) days completion period, continuing to the time at which the Services are complete. Such amount is the actual cash value agreed upon as the loss to City resulting from Contractor's delay. Additionally, the City shall also be entitled to withhold 50% of the total Compensation to be paid to Contractor until final completion and acceptance of the Services. 21. MISCELLANEOUS. A. In the event any proVIsIOn of this Agreement is found to be void and unenforceable by a court of competent jurisdiction, the remaining provisions of this Agreement shall nevertheless be binding upon the parties with the same effect as though the void or unenforceable provisions had been severed and deleted. B. This Agreement may be executed in multiple identical counterparts, each of which shall be deemed an original for all purposes. C. This Agreement shall constitute the entire agreement between the parties with respect to the subject matter hereof, and it shall supersede all previous and contemporaneous oral and written negotiations, commitments, agreements and understandings relating hereto. D. Any modification of this Agreement shall be effective only if in writing and signed by the parties to this Agreement. E. No waiver of any provision of this Agreement shall be valid or enforceable unless such waiver is in writing and signed by the party granting such waiver. F. Under no circumstances shall the Contractor be entitled to incidental, punitive, indirect or consequential damages, including but not limited to lost revenue or lost profits, as a result of termination of its Services under this Agreement. 8 CIOII-062 - AGREEMENT WITH DADE CONTRACTING. INC. [\ n i"') viD City of Sunny Isles Beach 18070 Collins Avenue, Sunny Isles Beach, Florida 33160 (305) 947-0606 phone (305) 949-3113 Fax IN WITNESS WHEREOF, the parties hereto have executed this Agreement in triplicate on the day and year first written above. JrESSEm Sign ure 1 ~'C",-...h ~ -~\k..L Print Name CONTRACTOR: DADE CONTRACTING, INe. BY. . ~ ~me & Title -~ '" . t WITNESSES: Signature Print Name ATTEST: C. B'~~ 1\ ~) Jane A. Hines, CMC, City Clerk . . CITY OF SUNNY ISLES BEACH / , fl ., ~ ,'1 . . APPROVED AS TO FORM AND LEGAL S ENCY 9 CIOII-062 - AGREEMENT WITH DADE CONTRACTING. INC. t""" ~ '" 'v ~ U . yo,. 1" Giovanni Batista '-~j".~t." From: Sent: To: Subject: Wayne [dcibearden@bellsouth.netJ Friday, July 01, 20114:29 PM Giovanni Batista City of Sunny Isles Beach 7.1.11 Dade Contracting, Inc. 7000 NW 53rd Tr. Miami, FL 33166 Phone 305-885-8851 Fax 305-885-8871 Proposal DATE: July 1,2011 Proposal Submitted to: City of Sunny Isles Beach 18070 Collins Ave. Fourth Floor Sunny Isles Beach, FL 33160 Ph. 305-947-2150 Attn: Giovani Batista Email: 2batista(ii)sibtl.net Job: Park work llWjQ ~8UiRII A "e.~()l.-Iq I I e{.,o.C&- . n L8kBlRlI:::CaIl8~'a" PaFkQc.)~ 0~ ~M\J.\'):tV1 t'o.~lL Sunny Isles Beach, FL I SCOPE: 1.0 Remove Grass Fill and topsoil and haulaway 1.1 Install 8-inch crush limerock 1.2 Install 8" x 6" concrete band 1.3 Install pavers over concrete band to enclose walkway 1.4 Install P. Gravel 1.5 InstaU aluminum fence 4-inch high LS LS 210 LF 210 LF LS 110 LF a. 2" x 2" Posts @ 6' on center b.o Top/Bottom rail to be 1" x 2" c. Pickets to be % inch 1.6 Cut doorway in CBS wall and instaIl4'x 8' aluminum gate 1 ea CLeM. ~um-t (f') 1.7 Final clean LS . ~D~ Go..... ~ CoOI1.~ 5'f/U(~. Total = $16,900.00 . 1 ATTACHMENT "A"I""I ~ ~) 01tJ " . . Exclusions: I. Permits 2. Permit fees 3. Surveying 4. Density Tests S. As-builts All matcrial is gullTantccd to be as specified. All work to be completed in a workmanlikc manner according to standard practices. Any alteration or deviation from above specifications involving extra costs. will be exccuted only upon written orders, and will become an charge over and above the estimate. All agreements contingent upon strikes, accidents. or delays beyond our control. This proposal Subject to acceptance within 60 days and is void thcreafter at the option of the undennanned. Authorized Signature Acceptance of Proposal: The above prices, specifications and conditions are hereby accepted. You are authorized to do the work as specified. Payment will be made as outlinc above. Accepted: DATE: Signature: 2 ~ f.' r .) I U Preview Page 1 of 1 City of Sunny Isles Beach 18070 Collins Avenue Sunny Isles Beach, Florida 33160 (305) 947-0606 City Hall (305) 949-3113 Fax MEMORANDUM TO: The Honorable Mayor and City Commission FROM: Giovanni Batista, Public Works Director DATE: 7/21/2011 RE: Bid A ward to Dade Contracting Inc. for the installation of a walkway within Golden Shores Park. RECOMMENDATION: It is recommended that the City Commission approve the bid award to Dade Contracting, Inc. for the installation of a walkway within Golden Shores Park in an amount not to exceed $16,900.00 plus a $1,000.00 contingency. REASONS: The construction of the proposed walkway in Golden Shores Park will provide access from Golden Shores Park to Heritage Park and the basketball court located under the Lehman Causeway. The proposed walkway at Golden Shores Park will connect directly to the system of sidewalks under the causeway which direct pedestrian traffic to Heritage Park and/or Collins Avenue. Three proposals for the improvements were obtained and are as follows: 1. Maggolc, Inc.: $16,978.00 2. Dade Contracting, Inc. (DCI): $16,900.00 3. Construct Group Corp. (CGC): $17,928.50 FUNDING SOURCE: Funding is available in 20-600-5612. A TT ACHMENTS: . Park Rendering . Resolution . Agreement http://sibagenda.sibfl.net/agenda/Preview.aspx?ItemID=53 7 &MeetingID=O&MeetingDate... 7/15/2011 $ f I '" ~ " ':a - ~ 2 .... t~ II Sea- u....., :r ~~: \01 "i..9i C'\)~ ~ ~ ~ 3 z