HomeMy WebLinkAboutJVA Engineering 00(71 L
[ P f :VED
J�.1NY iS<
OAS <s) 222012
3
U =
/9
9) * FLO '- Q
CITY OF SUNNY ISLES BEACH
Newport Fishing Pier and Restaurant Utilities
Prepared by:
OA Calvin, Giordano & Associates, Inc.
t C L E X C E P T I O N A L S O L U T I O N S
1
CGA Project No. 11-4179
City of Sunny Isles Beach Bid No. !TB 12-10-01
August 2012
SECTION 00300
BID FORM
Bid of JVA Engineering Contractor, Inc.
Address 6600 NW 32nd Avenue, Miami, FL 33147
Phone 305-696-7902
Sealed bids for the construction of water & sewer, telecommunications (AT&T, ABB),
service utilities for the new City of Sunny Isles Beach Newport Fishing Pier and
Restaurant Utilities. The scope of work shall include installation of approximately 400
linear feet of an eight (8) inch PVC water main, 70 linear feet of four (4 inch) PVC fire
main, fire hydrant assembly and a 60 linear feet of a four (4) inch PVC sewer lateral
extension. All paver driveway/ parking area restoration, landscape restoration, curb &
gutter restoration, and maintenance of traffic shall be considered and included in this
bid.
To: CITY OF SUNNY ISLES BEACH
18070 Collins Avenue, Suite 250
Sunny Isles Beach, Florida 33160
The undersigned Bidder has carefully examined the Bidding Documents and the site of
the proposed work and is familiar with the nature and extent of the work and any local
conditions that may in any manner affect the work to be done.
The undersigned Bidder agrees to do all the work and furnish all materials called for by
the Bidding Documents, in the manner prescribed therein and to the standards of quality
and performance established by the Engineer for the unit price amounts stated in the
spaces herein provided, for each of the items or combination of items stipulated. Unit
price line items shall include cost of implementing all applicable safety requirements.
Bidder acknowledges that estimated quantities scheduled are approximated for the sole
purpose of obtaining comparative bids for determination of the lowest responsible and
responsive bidder whose bid best serves the interest of, and represents the best value
to, the Owner pursuant to the criteria set forth in Section 62-8 of the City Code, and that
actual quantities required may increase or decrease. Bidder further agrees that
payments will be made on the basis of actual quantities placed and accepted in the
construction. Bidder acknowledges that price is only a factor in determining the lowest
responsible and responsive bidder.
BID SECURITY
Accompanying this Bid is a certified or cashier's check or a bid bond in the amount of 555% of the
bid made payable to the Owner which may be forfeited as liquidated damages if, in the event
this proposal is accepted, the undersigned fails to execute the Agreement and furnish and pay
for the required performance and payment bonds for the Owner within 10 days after acceptance
of the Bid; otherwise said certified or cashier's check or bid bond will be returned to the
undersigned.
08/12 00300-1 11-4179
The undersigned Bidder agrees to commence work within 30 days after the date of written
Notice to Proceed, and further agrees to substantially complete the work within 90 consecutive
calendar days after the date of written Notice to Proceed, subject to such extensions of time
allowed by the Conditions of the Contract.
The undersigned Bidder also agrees to complete the entire work within 90 days after the
Contract time commences to run.
The undersigned Bidder agrees that this Bid shall be good and may not be withdrawn for a
period of 90 days after the scheduled closing time for receiving bids.
The undersigned further agrees to forfeit to the Owner, as liquidated damages for each calendar
day elapsing between the date established as the date of final completion and the actual date of
final completion of the contract work, the amount of $2,000.00 per calendar day.
08/12 00300-2 11-4179
ADDENDA
Bidder acknowledges the receipt of Addendum No.'s
1. (1/13/12,2. , 3. , 4. , 5.
Dated thi&0th day oNovember 2012
(month) (year)
Contractor: JVA Engineering Contractor, Inc.
Address: 6600 NW 32nd Avenue
SEAL Miami, FL 33147
•
Attachments:
Subcontractor List
Bid Security
Trench Safety Act documentation
END OF DOCUMENT
08/12 00300-3 11-4179
DOCUMENT 00401
BID BOND
BIDDER(Name and Address):
JVA ENGINEERING CONTRACTOR. INC.
6600 N.W. 32nd Avenue
Miami, Florida 33147
SURETY (Name and Address of Principal Place of Business):
WESTERN SURETY COMPANY
P. 0. Box 5077
Sioux falls, SD 57117-5077
OWNER(Name and Address):
CITY OF SUNNY ISLES BEACH
18070 Collins Avenue
Sunny Isles Beach, Florida 33160
BID
BID DUE DATE: 11-13-2012 at 10:00 am
PROJECT (Brief Description including Location):
Sealed bids for the construction of water & sewer, telecommunications (AT&T, ABB), for
the new City of Sunny Isles Beach Newport Fishing Pier and Restaurant Utilities. The
scope of work shall include installation of approximately 400 linear feet of an eight (8)
inch PVC water main, 70 linear feet of four (4 inch)PVC fire main, fire hydrant assembly
and a 60 linear feet of a four (4) inch PVC sewer lateral extension. All paver driveway/
parking area restoration, landscape restoration, curb & gutter restoration, and
maintenance of traffic shall be considered and included in this bid.
BOND NUMBER: N/A
DATE: (Not later than Bid Due Date): 11/13/2012
PENAL SUM: Five Percent of Bid Proposal Submitted (5%)
IN WITNESS WHEREOF, Surety and Bidder, intending to be legally bound hereby, subject to the terms
printed on the reverse side hereof, do each cause this Bid Bond to be duly executed on its behalf by its
authorized officer, agent,or representative.
BIDDER SURETY
JVA ENGINEERING CONTRACTOR, INC. (Seal) WESTERN SURE OMPANY (SeAI)
Bidder's Name" rporate Seal r Surety's Na and par Sea it
By: �, Pitribtdc%1T B': - r
.lure and Title y gna�Titter Charles J. ,Nielson, Atty.-In-
(Attach Power of Attorney) Fact
Attest: Attest.
Si ature and Title Signature and Title Secretary
Note: (1) Above addresses are to be used for giving required notice.
(2) Any singular reference to Bidder. Surety. Owner or other party shall be
considered plural where applicable.
08/12 00401-1 11-4179
FISHING PIER AND RESTAURANT UTILITIES
UNIT PRICE BID SCHEDULE
Bid Estimated Estimated
Item Description Quantity Unit Unit Price Total
I. General Conditions
1 Mobilization and Demobilization (Includes general
conditions, permit fees, NPDES Compliance,
administration, etc.) 1 LS _ 2/Xoo0 ZCCO.CD
2 Maintenance of traffic per FDOT including temporary
striping and signage, barricades, barriers, arrow
panels, etc. as required, in coordination with FDOT&
Sunny Isles Beach Police Department.
1 Ls 3,OcO.CO Acco.CO
3 Utility Location Soft Digs Prior to Excavation 5 EA SCOW 2,Scbtk)
Sub-Total General Conditions 115C0.C:0
II. Civil
4 Furnish and Install 8° PVC Water Main
(Inclusive of all bends, fittings, appurtenances,
backfill, compaction, excavation, bedding,
compaction, testing, certification permitting/approval
and restoration) 450 LF 56-00 25r2co.co
5 Furnish and Install 12"x8"TS&V On FDOT ROW) 1 LS 4,etc.co 4,803-O0
6 Furnish and Install FH Assembly(complete)
(Inclusive of all backfill, compaction, excavation,
bedding, compaction, testing, certification
permitting/approval and restoration) 1 LS 3,2CO.co 3r20c•co
7 Furnish and Install 8' gate valve in FDOT r/w 1 EA 4,SCO.CO 4,500.Op
B Furnish and Install 8"x6"tee 1 EA 45r),03 x.00
9 Furnish and Install 6°gate valve 1 EA 4,20.00 1,2m.00
10 Furnish and Install 4°gate valve 1 EA iAXt co 1.Dm.t O
11 8" DIP fittings (complete w/restraints) 10 EA 2coo.03 2,000.OD
08112 00300-2 Addendum 81 11-4179
FISHING PIER AND RESTAURANT UTILITIES
UNIT PRICE BID SCHEDULE
Bid Estimated Estimated
Item Description Quantity Unit Unit Price Total
12 Sample Points 3 EA .4,OOD. t 5,cco.00
13 Furnish and Install 1° HDPE Service
(Inclusive of saddle, corp. stop, all backfill,
compaction, excavation, bedding, testing, certification
permitting/approval, restoration and connection at
existing bathroom) 90 LF 'x$,00 4r'Eo.co
14 Furnish and Install 5/8" Meter w/backflow 1 LS 3,1tw.0.3 51100.00
15 Furnish and Install 2° HDPE Service
(Inclusive of saddle, corp. stop, all backfill,
compaction, excavation, bedding, testing, certification
permitting/approval, restoration and connection at
building service) 90 LF 2o.co 1,ett.CU
16 Furnish and install 1° meter w/backflow 1 LS 6,SOD-tX) 6,Soo Cp
17 Furnish and install 8"x4" Reducer 1 LS 21/4co. u 4co.03
18 Connect and Test 8°WM 1 LS Q,cep.00 2,000.3)
19 Furnish and Install three (3) 2" PVC Communications
Conduits(450 LF trench)(Inclusive of all backfill,
compaction, excavation, bedding, compaction, and
restoration) 1,350 LF (LW 14,2co.co
20 Furnish and Install 4° PVC Clean Out 1 EA 4w.0) '4ct.cO
21 Sidewalk Restoration (per FDOT)
1 LS 41500.00 i,S00.00
22 Curb &Gutter Restoration _ _
1 LS _ 1500.00 _ 4,SOD.cz
23 Paver Restoration 1 LS 'tj/ .co 25403,00
24 Landscape& Irrigation Restoration 1 LS 3,5oo.0U 3,500.Co
25 Pavement Restoration (per FDOT specs, full lane
width 100') 1 LS cm co 6,CDO.e p
26 Sod Restoration 1 LS A,205.06 Vc0.o
27 Pavement Marking Restoration 1 LS A,5rc.tp 'I.`x040
28 Concrete Flume 1 EA $CD(p 50000
29 Flare End Curb 6 EA Ai:041V 4,00.00
Sub-Total Civil 41514CO.00
TOTAL BASE BID(Items I Thru II) StQz w0.c01
OWE H4NOMED -t'Vf_)+tt-tvK�W1o+JND. Nt ►1ut.c cd) poLuse/r'm t.Es
']VL\E.NG, w w a c]nuC¢AGZoi •Iuc Written tl-Zo•It
(Contractor) (Date)
08/12 00300-3 Addendum#1 11-4179
FISHING PIER AND RESTAURANT UTILITIES
UNIT PRICE BID SCHEDULE
Bid Estimated Estimated
Item Description Quantity Unit Unit Price Total
Additional Alternative
1 Secure site &stand-by for 24 hours (M-F) (up to 4 per 24
consecutive weekdays.) hours 2,400 CO
2 Secure site& stand-by for 5 consecutive weekdays.
3,cCo.R)
3 Furnish and Install 4' DIP Fire Main
(Inclusive of all backfill, compaction, excavation,
bedding, compaction, testing, certification
permitting/approval and restoration)
85 LF G3O.ta7
4 Furnish and Install 4°x4"tee 1 EA 4 .w 4cc.CC
5 Furnish and Install 4" DDCV 1 EA Z2co•w g,2oCO
6 Furnish and Install 4" FDC (Siamese)with check valve
4,01DO.00 2troto.00
7 4" DIP Fittings(complete w/restraints) 10 EA 1$0.00 -245C0.00
8 Connect and Test 4° FDC Line 1 LS '(/g00,c0 VicO to
9 Furnish and Install 4° Sanitary PVC Lateral 60 LF 45.CO 2,gootO
10 Furnish and Install 4" PVC Wye 1 EA 2,(dn.00 2,GW.CO
Notes:
1. Quantities are not guaranteed.
2.Unit price adjustments only after 125% increase/decrease.
3.All pricing is inclusive of excavation, installation, material, bedding,compaction, testing, certification,
4. Work includes chlorination Bac Ts.
5. DOH acceptance, MDFR acceptance.
6. Paver& landscape restoration with equal or better material as approved via submitted and sample.
7. Contractor to reuse existing pavers, if new pavers are required sample of material and color match must be
08/12 00300-4 Addendum#1 11-4179
SWORN STATEMENT PURSUANT TO SECTION 287.133(3)(a),
FLORIDA STATUTES, ON PUBLIC ENTITY CRIMES
THIS FORM MUST BE SIGNED AND SWORN TO IN THE PRESENCE OF A NOTARY PUBLIC OR
OTHER OFFICIAL AUTHORIZED TO ADMINISTER OATHS.
1. This sworn statement is submitted to sunny Isles Beach
by
Jose M. Alvarez, President [print name of the public entity]
[print individual's name and title)
for JVA Engineering Contractor, Inc.
[print name of entity submitting sworn statement)
whose business address is
6600 NW 32nd Avenue
Miami, FL 33147
and (if applicable) its Federal Employer Identification Number(FEIN) is 48-1277685
(If the entity has no FEIN, include the Social Security Number of the individual signing this
sworn statement: .)
2. I understand that a "public entity crime" as defined in Paragraph 287.133(1)(g), Florida Statutes,
means a violation of any state or federal law by a person with respect to and directly related to
the transaction of business with any public entity or with an agency or political subdivision of
any other state or of the United States, including, but not limited to, any bid or contract for goods
or services to be provided to any public entity or an agency or political subdivision of any other
state or of the United States and involving antitrust, fraud, theft, bribery, collusion, racketeering,
conspiracy, or material misrepresentation.
3. I understand that "convicted" or "conviction" as defined in Paragraph 287.133(1)(b), Florida
Statues, means a finding of guilt or a conviction of a public entity crime, with or without an
adjudication of guilt, in any federal or state trial court of record relating to charges brought by
indictment or information after July 1, 1989, as a result of a jury verdict, nonjury trial, or entry of
a plea of guilty or nolo contendere.
4. I understand that an "affiliate" as defined in Paragraph 287.133(1)(a), Florida Statutes, means:
1. A predecessor or successor of a person convicted of a public entity crime; or
2. An entity under the control of any natural person who is active in the management of the
entity and who has been convicted of a public entity crime. The term "affiliate" includes those
officers, directors, executives, partners, shareholders, employees, members, and agents who
are active in the management of an affiliate. The ownership by one person of shares
constituting a controlling interest in another person, or a pooling of equipment or income among
persons when not for fair market value under an arm's length agreement, shall be a prima fade
case that one person controls another person. A person who knowingly enters into a joint
venture with a person who has been convicted of a public entity crime in Florida during the
preceding 36 months shall be considered an affiliate.
5. I understand that a "person" as defined in Paragraph 287.133(1)(e), Florida Statutes, means
any natural person or entity organized under the laws of any state or of the United States with
the legal power to enter into a binding contract and which bids or applies to bid on contracts for
the provision of goods or services let by a public entity, or which otherwise transacts or applies
to transact business with a public entity. The term "person" includes those officers, directors,
executives, partners, shareholders, employees, members, and agents who are active in
management of an entity.
08/12 00402-1 11-4179
6. Based on information and belief, the statement which I have marked below is true in relation to
the entity submitting this sworn statement. [Indicate which statement applies]
Neither the entity submitting this sworn statement, nor any of its officers, directors,
executives, partners, shareholders, employees, members, or agents who are active in the
management of the entity, nor any affiliate of the entity has been charged with and convicted of
a public entity crime subsequent to July 1, 1989.
The entity submitting this sworn statement, or one or more of its officers, directors,
executives, partners, shareholders, employees, members, or agents who are active in the
management of the entity, nor any affiliate of the entity has been charged with and convicted of
a public entity crime subsequent to July 1, 1989.
The entity submitting this sworn statement, or one or more of its officers, directors,
executives, partners, shareholders, employees, members, or agents who are active in the
management of the entity, nor any affiliate of the entity has been charged with and convicted of
a public entity crime subsequent to July 1, 1989. However, there has been a subsequent
proceeding before a Hearing Officer of the State of Florida, Division of Administrative Hearings
and the Final Order entered by the Hearing Officer of the State of Florida, Division of
Administrative Hearings and the Final Order entered by the Hearing Officer determined that it
was not in the public interest to place the entity submitting this sworn statement on the
convicted vendor list. [attach a copy of the final order)
I UNDERSTAND THAT THE SUBMISSION OF THIS FORM TO THE CONTRA G OFFICER FOR
THE PUBLIC ENTITY IDENTIFIED IN PARAGRAPH 1 (ONE) ABOVE IS FO- H•T PUBLIC ENTITY
ONLY AND, THAT THIS FORM IS VALID THROUGH DECEMBER 31 OF T ' C•LEN"AR YEAR IN
WHICH IT IS FILED. I ALSO UNDERSTAND THAT I AM REQUIRED To IN•oRM THE PUBLIC
ENTITY PRIOR TO ENTERING INTO A CONTRACT IN EXCESS OF THE TH'.: SHOW AMOUNT
PROVIDED IN SECTION 287.017, FLORIDA STATUTES FOR CATEGORY TWOI•F •NY CHANGE
IN THE INFORMATION CONTAINED IN THIS FORM.
A
[sign-lure]
I
Sworn to and subscribed before me this 20th day of Nov: in -U 2012
Personally known x vaJ 'ft ,
OR Produced identification Notary Public - St-oof F ridalf
My commission expires 08/23/2013
(Type of identification)
Maria G. Gutierrez
(Printed typed or stamped
s$%%unuuai commissioned name of notary public)
* va� Ac'�
% : # :a :i*z.
08/12 00402-2 11-4179
DOCUMENT 00403
TRENCH SAFETY ACT
(90-96, Laws of Florida)
Bidder acknowledges that included in the appropriate bid items of the proposal and in the Total
Bid Price are costs for complying with the Florida Trench Safety Act (90-96, Laws of Florida)
effective October 1, 1990. The bidder further identifies the costs of such compliance to be
summarized below:
Trench Safety Unit of Unit Unit Extended
Measure Measure (Quantity) Cost Cost
(Description) (LFSF)
A. Trench Box LF 10 $10.00 $100.00
B.
C.
D.
Total $ 100.00
If applicable, the Contractor certifies that all trench excavation done within his control in excess
of five feet in depth shall be in accordance with the Florida Department of Transportation's
Special Provisions Article 125-1 and Subarticle 125-4.1 (TRENCH EXCAVATION SAFETY
SYSTEM AND SHORING, SPECIAL - TRENCH EXCAVATION).
Failure to complete the above may result in the bid being declared non-re.pon. -
Contractor agrees that the above safety compliances and costs are incl •ed i ',id package.
A
Signature of Bidd g Contr. for
END OF DOCUMENT
08/12 00403-1 11-4179 '
DOCUMENT 00420
INFORMATION REQUIRED FROM BIDDERS
GENERAL INFORMATION
The Bidder shall furnish the following information. Failure to comply with this requirement may cause its
rejection. Additional sheets shall be attached as required.
1. Contractors Name/Address: JVA Engineering Contractor, Inc.
6600 NW 32nd Avenue
Miami FT 3 147
2. Contractors Telephone Number 305-696-7902
3. Contractors License: CUC1224696 & CGC1516849
Primary Classification: General Contractor & Underground Utilities Contractor
4. Number of years as a Contractor in construction work of the type involved in this Contract:
11 Years
5. List the names and titles of all officers of Contractor's firm:
Jose M. Alvarez
6. Name of person who inspected site or proposed work for your firm:
Name: Manuel Maquira
Date of Inspection: 11/12/2012
7. What is the last project of this nature you have completed?
36" Raw Water Main for Miami-Dade County
8. Have you ever failed to complete work awarded to you: if so,where and why?
Never
08/12 00420-1 11-4179
9. Name three individuals or corporations for which you have performed work and to which you refer
Daniel Fm Morretti-Village of Pinecrest 305-669-6916
Bart Sanfilipo-Port of Miami 305-347-4988
Nestor Milian-Miami Dade County Public Works- 786-375-0004
10. List the following information concerning all contracts on hand as of the date of submission of this
proposal. (In case of co-venture, list the information for all co-ventures).
NAME TOTAL CONTRACTED °h
OF CONTRACT DATE OF COMPLETION
PROJECT CITY VALUE COMPLETION TO DATE
See attached detail of active and performed projects for the past
five years.
(Continue list on inset sheet,if necessary)
11. What equipment do you own that is available for the work?
JVA Engineering owns all equipment necessary to perform this job
to its completion.
12. What equipment will you purchase for the proposed work?
No need to purchase Equipment, JVA owns all equipment necessary.
NOTE:Attach additional sheets if required.
If requested by the City, the Bidder shall fumish a notarized financial statement, references and other
information,sufficiently comprehensive to permit an appraisal of his current financial condition.
08/12 00420-2 11-4179
LIST OF SUBCONTRACTORS
The Bidder SHALL list below the name and address of each Subcontractor who will perform work under this
Contract in excess of one-half percent of the total bid price, and shall also list the portion of the work which
will be done by such Subcontractor. After the opening of Proposals,changes or substitutions will be allowed
with written approval of the City of Sunny Isles Beach. Subcontractors must be properly licensed.
Work to be Performed Subcontractors Name/Address
1.
2.
NO SUBCONTRACTORS
3.
4.
5.
6.
7.
8.
9.
10.
NOTE: Attach additional sheets if required.
08/12 00420-3 11-4179
VNNY I SC
Oc S
a F
ti 7
V I
•a
SF 99)* FLOP �P
ya.
C//Y OF SUS nSO
Addendum No.1
CITY OF SUNNY ISLES BEACH
Newport Fishing Pier and Restaurant Utilities
CITY ITB NO. 12-10-01
To All Bidders:
Bidders for the above-referenced project shall take note of the following changes,
additions, deletions, clarifications, etc. to the Plans and Specifications, which in
accordance with the Contract Documents shall become a part of and have precedence
over anything shown or described otherwise.
Please note that the new opening date will be Tuesday. November 20. 2012 at
10:00 a.m. All Sealed Bids must be received by the City Clerk no later than
10:00 AM, on Tuesday, 11/20/2012 at the Sunny Isles Beach Government
Center located at 18070 Collins Avenue, 4th floor, Sunny Isles Beach, Florida,
33160. Bids received after this time will not be considered.
The Bid Document has been replaced in its entirety with the attached.
END OF SECTION
Tuesday, November 13, 2012
•..
P4 53 it OF
E22130 ,., `
1
r L rune tifo COURIf TpjtWOr
ALVA- JOSS,IC ` "k i
. agslrii n whisk",dcr.vhirtoto a ";
cr
WriO4
II
STATE OF FLORIDA
g ; :� DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION
•
"lrM CONSTRUCTION INDUSTRY LICENSING BOARD (850) 487-1395
�'.'007 TALLAHASSEEMONROE STREET
cop
ALVAREZ, JOSE M
‘TVA ENGINEERING CONTRACTOR INC
6600 NW 32ND AVE
MIAMI FL 33147
I STATE OF FLORIDA AC1l 6255900
Congratulations! With this license you become one of the nearly one million I - i'y•.
Floridians licensed by the Department of Business and Professional Regulation. 4� DEPARTMENT OF REGULATI AND
Our professionals and businesses range from architects to yacht brokers, from PROFESSZONALr REGULATION
boxers to barbeque restaurants, and they keep Florida's economy strong.
CUC1224696%`: •108/OB4512 118208900
Every day we work to improve the way we do business in order to serve you bette '
For information about our services,please log onto www.myfloridalicense.com. CERT UNDERGROUND &XCAV CNTR
There you can find more information about our divisions and the regulations that ALVAREZ, -JO9t:M4-'•
,
ENGINEE L•,. ��
impact you, subscribe to department newsletters and learn more about the JVA RING¢CONTRACTOR INC
Department's initiatives.
Our mission at the Department is: License Efficiently, Regulate Fairly. We
constantly strive to serve you better so that you can serve your customers.
Thank you for doing business in Florida, and congratulations on your new license!
nIS CSRiZPIRD Pt,atto, data. AUG 3 1, 2014 L L1 ca. P:ovi•t of cn.2080801 489 r9
311925
DETACH HERE
rb it}ti t <t,--'r: THIS DOCUMENT HAS A COLORED BACKGROUND.MICROPRINTING'•
LINEMARKP PATENTED PAPER X';;'. n':14r..�`P::•••••cfir._1-5};
kC# 6255900 STATE OF FLORIDA
DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION
CONSTRUCTION INDUSTRY LICENSING BOARD
SEQ#L12080801925
DATE BATCH NUMBER LICENSE NBR- I t:: `,),f:...
08/08/2012 118208900 CUC1224696ti'
The UNDERGROUND UTILITY & EXCAVATION;-Ca' II` • `'
Named below IS CERTIFIED >,
Under the provisions of Chapteri-489 tF9. s : w ,
Expiration date : AUG 31, 2014' :; x.� ;>,S•� i
ALVAREZ, JOSE M �. • _ y •-.
JVA ENGINEERING CONTRACTOR INC
6600 NW 32ND AVE j
MIAMI FL 33147 'r' '
it
RICR SCOTT KEN LAWSON
GOVERNOR SECRETARY
DISPLAY AS REQUIRED BY LAW
STATE OF FLORIDA
5. ± DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION
. CONSTRUCTION INDUSTRY LICENSING BOARD
.�y ' 1940 NORTH MONROE STREET (850) 487-1395
TALLAHASSEE FL 32399-0783
ALVAREZ, JOSE M
JVA ENGINEERING CONTRACTOR INC
6600 NW 32ND AVE
MIAMI FL 33147
Congratulations! With this license you become one of the nearly one million STATE OF FLORIDA AC# 6 2 5 5 4 6 3
Floridians licensed by the Department of Business and Professional Regulation. DEPARTMENT OF BUSINESS AND
Our professionals and businesses range from architects to yacht brokers, from \° PROFBSSIONALr REGULATION
boxers to barbeque restaurants, and they keep Florida's economy strong.
Every day we work to improve the way we do business in order to serve you bette CGC1516849?!g 1:11,8/0811.2 118208900
For information about our services,please log onto www.myfloridallcense.com. '' • -x0"
There you can find more information about our divisions and the regulations Nat ALVAIEISD"G {.'CONTRACTOR
impact you, subscribe to department newsletters and learn more about the ALVAREZ EERI G4CON
Departments initiatives. JVA ENGZN=gRINGaCONTRACTOR INC
Our mission at the constantly strive o0ser ounbetter{so that you can yserve your customers. 1
I
Thank you for doing business in Florida, and congratulations on your new license! 1B CERTIFIED wader the provisions L1 0 80148 P9
°gtr.etw a.e., AUG 31, 2014 L12080801488
DETACH HERE
-4•x.a(!;:: ,.vr,)zy-„ v THIS DOCUMENT HAS A COLORED BACKGROUND•MICROPRINTING•LINEMARK°PATENTED PAPER?t:?y t'fry'^+y1�..;;;y'yCtt,
IC#6255463 STATE OF FLORIDA
DEPARTMENT OF BUSINESS AND PROFESSIONAL REGULATION
CONSTRUCTION INDUSTRY LICENSING BOARD
DATE BATCH NUMBER LICENSE NBR;'LL: \ tr*• SEQ#L12080801488
08/08/2012 118208900 CGC151684 ..- ;rJa ?.� P ..
n% =lU
The GENERAL CONTRACTOR '�`% �
Named below I3 CERTIFIED ''1 " �� p� f, ri" 1
Under the provisions of Chapter 489r FS I i
Expiration date: AUG 31, 2014 14 17.rr_.,L -w ;
•
d1c='. v t.,.' ' -•\:>I ":yYi9F' + -.... l r... .7 ...... S.SP'[4 .
` NUlfK0ADE a �' •.+MUWGITAI[CONTRACT00.'t '- Ht �fa4
TAX CCLLECTORC:cW`S -% C v "' ` E rr ,%
1<-140.W:FLAMER Ere•sr YUIM•CAOE°coUNT'STATE OP koala CAI+
Ai,
in aoow,. 2 s' ,P$ e PURSUAta go'.COUNLy000asEC.S1?2A;I - .
`y.JINNI.. 331 ��j1yI,... ....... .. EXPIREWS '- ;4At3 l+ s +„'i`t e-
{.4.a 'l w r.. Sfl.4eir;: �+b:c%._.
i y '$ .F s i f'k--? --Fi CYTHIS S tA 1311.1:z-1 DO,NO •PAY` Br U iii-V�"
i444 C�` q A ,' >,NOT_lr ` r.aau<i. T.w - i
FEPTO - 0 31411358eCCkNOs_ . E22130Orift � 6.4
BUSIN NAM {v LOCATONf egt 3 ?tom"'L _"�' ECEPTE0l
D
leis-t, ra .t .�1 T -AZ'r - ?-; ae i 13"ySSA9'
.iwo,ENGINEERINGSCONTRACTOR:41NC,'tMi A Sit&l n
OWNER NJVAZENGI EERINBe TONTRACTOR CI4":_c,,-o T`F t aT
S' - f ,sE.3.A.�r-, , 1 -4-*, ela*x't._zi� .r t.
T.to SEE38ACK.OF RECEIPT,FOR_&4 `LgSS SPEC!ALTY,TENGINEERING'C0
FaA L'IST OFa NON PARTICIPATING 1 trs.�u '�'ctw,t„ �E'
eM it---, ALITIE . , (.tags -t: yr.:.e'.'" 5''r 'y{5 Y N t'Y '
,-e, . ,,vw.,. DO NOT FORWARD
Reakt Mulder.m s
Es`a' JVA ENGINEERING CONTRACTOR INC
Eong"I>Y >-3,x; € JOSE M ALVAREZ PRES
". *,w'(��S4c• •nC 6600 NW 32 AVE
q.-4.di;}ni;.71- MIAMI FL 33147
t.PATIENT T •lj
:+LUIM FOAGE
COUNTY TAN:
C° ff7fl4%2012-I T
;02240005004 Cif':.:
I•.IL..ILL.IIJX.IITIIIII.ILIL...ILI6TTIh.IILT.I Ili.I
Se 0002501001 3
,L74t•1&— FY '• h. - v ;rt: ',7ry 1 _ i
aMIAMFDADE-:COUNTY"' .,", 2012 1LOCAL'•.BUSINESStTAX RECEIPTt 7013 ^r/'
`s TAX COLLECTOR 1 .v{MIAMI•DADECOUNTYI STATE OKF RaRIDA. a N
T lclT4D\W FCAOLER ST 4-...-g7:EXP.IRESSEPT130;2013,'I4i-T`'�i`i;,SO, j 7
•1-Y motet FYOFOOR { +a-r , MUSTIBE DISP.I:AYED-ATLPLACEORBUSINESS.ta, k{_
r w� ,-y R•SUANT TOCOUNI'CODE CHAPTEIta8AtzARg9ya 10
THIS IS NOT A BILL-DO NOT PAY
492516-1 RENEWAL
BUSINESS NAME/LOCATION: RECEIPT NO. 514
JVA ENGINEERING CONTRACTOR INC CC • E221300
6600 NW 32 AVE
33147 UNIN DADE COUNTY
OWNER •
JVA ENGINEERING CONTRACTOR INC
Sec.Ty eo1 Bu,lnes. WORKER/S
196 SPECIALTY ENGINEERING CONTRACT 1
ran a OPRA A LOCAL
DULNESS TAX RECEIPT.IT
DOES NOT PERIOT all
HOLDER TO POLAR AN1
ERVING REGINA TORT CR
ZWCXO lAVES OF TIE DO NOT FORWARD
COONEY OR NOR
OCES IT EIEIWT.E4Pr THE JVA ENGINEERING CONTRACTOR INC
MOLDER fPOR ANY OThER
PERMIT OR .Sf'SE
OI A C er LAN THE IS JOSE M ALVAREZ PRES
[H! A CERCFlC40N GE 6600 NW 32 AVE
!NE HOLCERL OVAIIEKA-
"O ' MIAMI FL 33147
io FENT RECCE.E0
•SA41 OAOE COUNTY TAX
CIALECIOR:
07/24/2012
02240005003 I,IIII..II.ITIIIIII.III”ill AIL I nab.IIIT,I111114)1,,!
2 M1 DDADE COUNTY64".•?1 .` IBUSI.eLE•'.+FTA .REC-'.y" 3)::3A"g" :.
� I TAX cou z CDUt Mf%•t t f(fM,AJdLOCANBUSINESS TA TEECEIPT' �r,2013�`3' 1&
yA TAR COLLECTOR MIAMLOADE COUI•fiYl, STATE-OFFLORION-it& 'Cr
1„•„14D-W FLAGLEA ST 5aa; 1EXPIRES-SEPT 30;2U13 n"sE 5
1 ist FLOOR ' 5 1CMUST.BE OISPCAYEI ATIPLACE OF BUSINESS%
MUIMI Pl•313P I PURSUANT TO-COUNTYCODE CHAPTER BAA ART='S&y1O -
4.�.I..Ls_'t '',rr•�•l``"rw;3: ,.�.. a. `4t. ^CMS-T3..eeYYEr. ro+cT: e'.e n'3.Saas'� 3EII53 r^-
•
THIS IS NOT A BILL-DO NOT PAY'
656211-1 RENEWAL
BUSINESS NAME/LOCATION RECEIPT NO. • 68327
JVA ENGINEERING. CONTRACTOR• INC STATE* CGC1516849
6600 NW 32 AVE'
33147 UNIN DADE COUNTY
OWNER
JVA ENGINEERING CONTRACTOR INC
Sce. ry of Business WORKER/S
19rGENERAL BUILDING CONTRACTOR 1
THIS 1 CMS A LOCAL
ROSINESS TAE RECEIPT.IT
COES MOT PERMIT ME
HOLDER TO VIOLATE AM
EERT:MO REGULATORY OR
ZONING LAWS Or THE DO NOT FORWARD
COUNTY OR CITIES :1019
COES IT EYEING THE
HOLDER ERCIE ANY OMER
TEPYR OR LICENSE
REOLCAEDRR LAM TIPS IS JVA ENGINEERING CONTRACTOR INC
ROI IHE A LERRS(XIAUF OP JOSE M ALVAREZ PRES
.HE HOLLER S OUMIEC f
°M1 6600 NW 32 AVE
RA•NEMTRECUVSO MIAMI FL 33147
'AIAILLDAOE COUNTY TAX
COLLECTOR
02240005001 IIIIII II III I I IIII1111111 111111I11I11111I11I1111I11111,11111111
000075.00 193
SEE OTHER SIDE
Ti >TLn.ifiti::$L . 3N EE t ia PA 1 1 s-1 S 'sX k 1 lai„ESA iti.eC•
- �
.
I MAM/-DADECOUNR 20 e,4-9CAL BUINESSCTA /RE CEIpT C2013 p TAX COLLECTO AMt-0ADECOUNTY STATEOP FtOR10 "
f 140 LF W FARGCER
ST f„y4 ' A WEXPIRESSEP77.30.!2013 B S -
.iN MAM FL 1r� 1 MUSTSE DISPAYED AT PLACEO1€ SINESS
fr Zs ' r PURSUANT TDCOUNT Y;CODE'CHAPTER BA=ARf9
arm -5.. r
THIS IS NOT A BILL-DO NOT PAY
656212-9 RENEWAL
BUSINESS NAME/LOCATION RECEIPT NO. 68327
JVA ENGINEERING CONTRACTOR INC STATES CUC1224696
6600 NW 32 AVE •
33147 UNIN DADE COUNTY
OWNER
JVA ENGINEERING CONTRACTOR INC
SOU.Type of Business WORKER/S
nm a 114A StcCIALTY ENGINEERING CONTRACT 1
1.9U9MESS TAX RECEIPT.IT
WES :qr PERMIT RIE
I'OLDER TO 11OLAR ANY
31911/10 REGULATORY OR
:cNING LAWS OF THE DO NOT FORWARD
COUNTY OR CITIES NOR
sees IT EXEMPT ME
HERDER FROM ANT OTHER
FERRIC OR L.CETISE
NEOLARED P JVA ENGINEERING CONTRACTOR INC
SOT A CEPRFICATIDN C•
DNS. fOOA" A JOSE M ALVAREZ PRES
6600 NW 32 AVE
PA1.JENTRECERED YT Alai CI
IIJ a
E N G I N E E R I N G
CONTRACTOR . I N C
November 20, 2012
City of Sunny Isles Beach
Attn: City Clerk
Re: JVA Engineering Contractors' Past Experience and Corporate References
Please allow this letter to serve as an official listing of our active and completed
jobs for the past five years. The following list provides corporate References for
each project and show professional competency, manpower and financial
capability to perform your project identified as ITB No. 12-10-01.
The following is an official list of JVA's completed and active projects from
private and government sectors and corporate references that can verify our
competence and reliability. All of the projects below were fully executed and
submitted on a timely manner. JVA Engineering Contractor, Inc. provided all
manpower, equipment, and maintenance facilities for the completion of these:
Tri-C Construction Co, Inc.
100 W. Cypress Creek Rd.
Ft. Lauderdale, FL 33309
Contact: Chris Lawrence
Phone: (954) 677-0356
Fax: (954) 677-0359
2005 Tri - C Construction Co, Inc. - CVS Pharmacy #5897 37th & 199th
Completion Date: January 2006
Amount: $371,260.00
Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation &
Grading, Asphalt Pavement, Concrete Pavement.
2005 Tri - C Construction Co, Inc. - CVS Pharmacy #7131 Kendall & 127th
Completion Date: February 2006
Amount: $323,856.31
Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation &
Grading, Asphalt Pavement, Concrete Pavement.
6600 NW 32nd Ave
Miami, FL 33147
Tel: 305-696-7902'Fax: 305-696-7903
Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation &
Grading, Asphalt Pavement, Concrete Pavement.
2007 Tri - C Construction Co, Inc. - CVS Pharmacy # 6732 87th & Flagler
Completion Date: August 2007
Amount: $688,823.45
Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation &
Grading, Asphalt Pavement, Concrete Pavement.
John Moriarty & Associates of Florida, Ind.
1942 Tyler Street
Hollywood, FL 33020
Contact: Bill Suarez
Phone: (954) 261-0781
Fax: (305) 944-5352
2006 John Moriarty & Associates of Florida, Inc. — Trump Tower II
Amount: $288,359.00
Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation &
Grading, Asphalt Pavement, Concrete Pavement.
2006 John Moriarty & Associates of Florida, Inc. — Trump Tower III
Amount: $ 298,024.00
Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation &
Grading, Asphalt Pavement, Concrete Pavement.
MAD Construction Corp.
3930 NW 26th Street
Miami, FL 33142
Contact: Alan Janney
Phone: (305) 871-6410
Fax: (305) 871-1293
2006 Trademark Metal Recycling
Completion Date: January 2007
Amount: $365,820.00
Scope of work: Asphalt Pavement, Drainage Distribution.
2007 3939 NW 25th Street
Completion Date: August 2007
Amount: $91,600.00
Scope of work: Storm Water Dist., Excavation & Grading, Asphalt Pavement,
Concrete Pavement.
City of Sweetwater
500 SW 109th Avenue
Sweetwater, FL 33174
Contact: Antero Espinosa
Phone: (305) 221-0411
Fax: (305) 480 3849
2007 Various Locations Improvements (Drainage, Concrete & Asphalt
Pavement).
Amount: $55,786.25
Completion Date: July 2007
Kimley-Horn and Associates, Inc.
1691 Michigan Avenue
Suite 400
Miami Beach, FL 33139
Contact: Walter Lugo
Phone: (305) 673-2025
Fax: (305) 673-4882
2007 Retail Building 87th & Flagler
Completion Date: August 2007
Amount: $3,500,000
Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation &
Grading, Asphalt Pavement, Concrete Pavement.
Village of Pinecrest
12645 Pinecrest Parkway
Pinecrest, Florida 33156
Contact: Daniel F. Moretti
Phone: (305) 669-6916
Fax: (305) 669-6919
2007 SW 79th Ave Roadway Improvements
Completion Date: November 2007
Amount: $280,196.50
Scope of work: Storm Water System, Asphalt Pavement, Concrete Pavement.
2007 SW 70th Ave Improvements
Completion Date: August 2007
Amount: $10,700.000
Scope of work: Storm Water System, Asphalt Pavement, Concrete Pavement.
KM Plaza Construction Services
120 NE 27th Street
Suite 600
Miami, FL 33137
Contact: Robert Lalle
Phone: (786) 693-8717
Fax: (786) 693-8738
2007 Town Center One at Dadeland
Completion Date: December 2008
Amount: $490,000.00
Scope of work: Water Distribution, Storm Water Dist., Sewer Dist., Excavation
& Grading, Asphalt Pavement, Concrete Pavement.
Miami-Dade County Aviation Department
4200 NW 36st Street, Building 5A
Miami, FL
Contact: Johnny Peterson
Phone:
MIA- NW 67th Ave & NW 36`h Street Intersection Improvements
Completion Date: October 2011
Value: $977,000.00
Scope: Storm Sewer Distribution and Roadway Reconstruction
Miami-Dade County-Park & Recreation Department
11395 SW 79th Street
Miami, FL 33173
Contact: Dan Crawford
Phone: 305-596-4460 Ext: 239
2007 Biscayne Garden Park Improvement
Completion Date: November 2007
Amount: $329,601.10
Scope of work: Storm Water Dist., Sewer Dist., Excavation & Grading, Asphalt
Pavement, Concrete Pavement.
Miami Dade County Public Works Department
111 NW 1 Street
Miami, FL 33128
Contact: Jesus Gonzalez
Phone: 305 375 2172
2008 WASD Roadway Rehabilitation Contract
Completion Date: June 2008
Amount: $323,000.00
Scope of work: Asphalt Pavement
Miami Dade County Public Works Department
111 NW 1 Street
Miami, FL 33128
Contact: Nestor Melian
Phone: 786-375-0004
PTP Pavement Marking Installation
Completion Date: October 2011
Amount: $ 356,572.78
Scope of Work: Pavement Markings
2008 97th Ave Roadway Widening
Completion Date: January 2009
Amount: $ 514,615.63
Scope of work: Asphalt Pavement, Clearing, Grubbing, Earthwork, Utility
Adjustments, Fencing & Guardrail, and Concrete
Miami Dade County Water & Sewer Department
3071 SW 38 Ave,
Miami, Fl 33146
Contact: Nelson Cespedes
Phone: 786 552 8142
Perrine Cutler Ridge Water & Sewer Improvements
Completion Date: Active
Project Number: TP0067
Amount: $2,254,103.10
Scope of Work: Water Main, Gravity Sewer and Force Main
Furnish and Install 36-Inch DI Water Main in NW 87th Ave
Completion Date: Active
Project Number: T1562
Amount: $907,216.57
Scope of Work: Water Main, Gravity Sewer and Force Main
Install 24" DI Water Main
Project Number: ER# 15865
Amount: $698,858.67
Scope of work: Water Distribution, Asphalt Pavement
NAP Misc.-12 Sanitary Sewer Improvements
Project Number: RPQ T1026
Amount: $ 838,558.26
Scope of work: Gravity Sewer, Force Main, Asphalt Pavement Restoration,
Concrete
City of South Miami
4795 SW 75th Avenue
Miami, FL 33155
Contact: Ajibola Balogun
Phone: (305) 668-7355
City Hall 12-Inch Water Main Extension
Amount: $217,851.15
Scope of work: Water Distribution, Asphalt Pavement
Citywide Resurfacing Project Phase II
Project Number: SM-2011-16-PW
Amount: $195,788.34
Scope of Work: Road Resurfacing, Milling, Clearing and Grubbing, Asphalt
Placement, Retro Reflective Pavement Markers and Striping
City of Miami
444 NW 2nd Ave,
Miami, FL 33131
Contact: Eric Rush
2011 Kinloch Storm Sewer Improvements PH-II
Completion Date: November 2011
Amount: $898,630.00
Scope of Work: Storm Sewer Distribution and Roadway Reconstruction
Port of Miami
1015 North America Way
Miami, FL 33132
Contact: Bart Sanfilipo
Phone: 305-347-4988
Contact: Juan Bergouignan
Phone: 305-347-4974
Scope of work: Various Site and Marine Construction
Opa Locka Head Start Facility
Amount: $165,000.00
Scope of work: Water Distribution, Storm Water Dist., Excavation & Grading,
Asphalt Pavement.
YEMC Construction
14750 SW 24th Street
Miami, FL
Contact: Carlos Armas
Phone: (305) 219 0862
Coral Way Offices
Amount: $105,067.50
Scope of work: Storm Water Dist. Sewer Dist., Excavation & Grading, Asphalt
Pavement, Concrete Pavement.
Gamma Construction
4850 SW 72 Ave
Miami, FL 33155
Contact: Jorge Jones
Phone: 305 661 1569
Community Bible Baptist Church
Amount: 214,417.00
Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation &
Grading, Asphalt Pavement, Concrete Pavement.
VP Construction
7600 Red Rd #128
Miami Fl 33143
Contact: George Perendes
Phone: (305) 667- 6060
Valencia Village
Amount: $218,276.50
Scope of work: Water Distribution, Storm Water Dist. Sewer Dist., Excavation &
Grading, Asphalt Pavement, Concrete Pavement.
FDOT
1000 NW 111th Ave, Room 6203
Miami, FL 33172
Contact: John Bolton
Phone: 305-654-7019
Fax: 305-654-7020
Roadway Improvements on SR 959 Coral Way to SW 22nd Street
Amount $73,932.00
Scope of Work: Drainage, and Asphalt Restoration, Striping and Signage.
Alvarez Engineers, Inc.
10305 NW 41 St.
Suite 103
Doral, FL 33178
305-640-1345
Waterstone Way
Amount $1,054,313.50
Scope of Work: Concrete, Drainage, Asphalt Striping, Manhole, Manhole,
Sanitary Sewer, and 8" Water Main
Beacon Tradeport Development District
Amount $120,000
Scope of Work: Concrete
City of OPA-LOCKA
780 Fisherman Street
Opa-Locka, FL 33054
Contact: Nasir Mohammad
Phone: 786-382-7917
Fax: 305-953-2824
NW 143`d Street Drainage & Roadway Improvements Project
Completion Date: Active
Project Number: 11-2012100
Amount: $468,644.80
Scope of Work: Installation of new Drainage System, Road Rehabilitation, Repair
and Renovations of existing Sidewalks
City of Hollywood
2600 Hollywood Blvd.
Hollywood, FL
Contact: Clece Aurelus
Phone: 954-805-3681
Fax: 954-921-3258
Distribution Piping Upgrades on N 56th Ave from Douglas Street to Stirling Road
to N 58th Ave.
Completion Date: Active
Amount: $930,000.00
Scope of Work: 8" Water Main and Site Restoration
If you have any questions, please do not hesitate to contact us.
Sincerely,
Jose M. Alvarez, President
JVA Engineering Contractor, Inc.
JlittialTar.vor
E N G I N E E R I N G
CONTRACTOR , INC .
JVA ENGINEERING CONTRACTOR, INC.
CORPORATE CAPABILITY STATEMENT
JVA Engineering Contractor, Inc is a family operated business based in Miami, FL. It was
established in 2002 by a Hispanic Minority. This past performance includes successfully
managing and implementing projects for a wide variety of public and private sector clients along
Southeast United States. It functions as a civil, general, commercial, and industrial contractor.
As an CSBE, SBE, DBE and 8(a) Business Development Program certified company with the
U.S. Small Business Administration,JVA Engineering Contractor, Inc is capable of
implementing public sector contracts, with a bonding capacity of$12,000,000 on a single project
and S21,000,000 aggregate allowing JVA to maintain a level of control over quality, schedule,
and client relations.
JVA Engineering's key personnel have experience completing projects for a number of
governmental and non-governmental clients. These include the Miami-Dade County
Departments, Broward County Departments, Monroe County Departments Florida Department
of Transportation and many more.
KEY PERSONNEL
Jose M. Alvarez, President, Quality Control Manager
Juan C. Cardenas, General Manager
Cesar Gonzalez, E.I.T., Estimator, General Project Manager
Roger Milian, Superintendent and Site Safety Officer
Jenny Fiallo, Office Manager, Quality Control Manager
PAST PERFORMANCE
Key personnel of JVA Engineering have past performance with the following agencies:
Public Sector
Florida Department of Transportation City of South Miami
Miami-Dade County Public Works City of Sweetwater
Miami-Dade County Water& Sewer Town of Medley
Department Village of Pinecrest
Miami-Dade County Parks and Recreation Village of Palmetto Bay
Miami-Dade County Seaport Monroe County
Miami-Dade County School Board Palm Beach County
Broward County School Board Broward County
City of Miami
•
Private Sector
MAD Construction John Moriarty and Associates of South
Alvarez Engineers, Inc Florida
CB Richard Ellis KM Plaza
Coreland Construction Corp Robertson Properties
Gamma Construction Tri-C Construction
YEMC Construction
CERTIFICATIONS
JVA Engineering's personnel maintain current qualifications in construction, safety, programs,
equipment, and other areas. The following are a few of the certifications held by various
personnel of JVA Engineering:
• OSHA Safety Training Course • US Army Corp of Engineers-Quality
• AutoCAD Control Manager
• Land Development • Traffic Control Supervisor
• FDOT Earthwork Level I • Traffic Control Technician
• FDOT Asphalt Level I
Pursuing Certification:
• Earthwork Level 2 • Asphalt Level 2
SERVICES
Concrete Division Pavement Division
• New Concrete Sidewalks & Walkways • Rotor Milling
• Sidewalk extension & repairs • Complete Asphalt Pavement
•ADA Compliance Updates • Complete New Roadway Base &
•All types of curbs and valley gutters Sub-base preparation
• Precast concrete structures • Complete Parking Area construction
• Precast concrete wheel stops • General existing Roadway restoration
• Stamped Concrete & Brick Pavers
Utility Division Striping& Signs Division
• Solid Pipes system • Complete installation of traffic sign
• Lift Station • Complete traffic striping paint or
• Pump Station thermoplastic
• Storm Drainage Systems
• Water and Sewer Connection Earthwork Division
• Sewer Force Main • Land Clearing and Grubbing
• Gravity Sewer Main • General Excavation
•Water Main • General Grading
•Culverts • Fill
• Levee • Environmental Remediation
• Dikes • Wetland Restorations
Equipment Rental Division Transportation Division
• Complete line of rentals equipment • Heavy equipment transportation & Dump Trucks for all your hauling needs
2