Reso 2023-3503 - Laserfiche WebLink

Home Browse Search

City of Sunny Isles Beach 18070 Collins Avenue, Sunny Isles Beach, Florida 33160 (305) 947-0606 phone (305) 949-3113 Fax the City's Representative and the City written notice of such claim within three (3) days after the occurrence of the event, or the first appearance of the condition, giving rise to such claim. Such notice must be given by the Contractor before proceeding to execute any additional or changed Work. The failure by the Contractor to give such notice and to give such notice prior to executing the Work shall constitute a waiver of any claim for additional compensation. 8.3.4.1 In connection with any claim by the Contractor against the City for compensation in excess of the Contract Price, any liability of the City for the Contractor's cost shall be strictly limited to direct costs incurred by the Contractor plus a reasonable mark-up of fifteen percent (151/o) for overhead and profit consistent with Paragraph 10.3.3.4 below. Direct costs do not include the Contractor's home office overhead, loss of efficiency, consequential damages of the Contractor, or equipment costs in excess of actual equipment rental paid by the Contractor to a third party. The City shall not be liable to the Contractor for claims of third parties, including Subcontractors, unless and until liability of the Contractor has been established therefore in a court of competent jurisdiction. 8.3.5 Claims for Additional Time—If the Contractor is delayed in progressing any task which at the time of the delay is then critical or which during the delay becomes critical, as the sole result of any act or neglect to act by the City or someone acting in the City's behalf, or by changes ordered in the Work, unusual delay in transportation, unusually adverse weather conditions not reasonably anticipatable, fire or any causes beyond the Contractor's control, then the date for achieving Final Completion of the Work shall be extended upon the written notice and claim of the Contractor to the City and the City's Representative for such reasonable time as the City's Representative and the City may determine plus extended, documented general conditions expenses including, among other things, project management, supervision and project site overhead expenses. Claims for delay can only be submitted for consideration in the event they have a direct, documentable impact on the Critical Path of the project as evidenced on the (CPM) schedule. Concurrent delay events impacting the schedule will only be considered as a single impact and will be limited to a non -compensable time extension. Any notice and claim for an extension of time by the Contractor shall be made not more than three (3) days after the occurrence of the event or the first appearance of the condition giving rise to the claim and shall set forth in detail the Contractor's basis for requiring additional time in which to complete the Project. Said claim shall specifically include, among other things, an adjusted critical path (CPM) schedule reflecting precisely the delay and its claimed impact upon the Contractor's future performance. In the event the delay to the Contractor is a continuing one, only one notice and claim for additional time shall be necessary. If the Contractor fails to make such claim as required in this Subparagraph, any claim for an extension of time shall be waived. 8.3.5.1 In no event, and under no circumstances, shall the Contract Price be increased for, nor shall the Contractor claim, recover, or receive payment for, any cost, expense, damages, or compensation of any kind by reason of any delay to the Project, whether critical or non-critical, and whether caused in whole or in part by the City other than as set forth in Paragraph 8.3.5 above. The Contractor shall not be entitled to any direct, indirect, consequential, impact, or other costs, expenses, or damages, including 22