Reso 2024-3644 - Laserfiche WebLink

Home Browse Search

Contract Clauses for Solicitation 47QSMD20R0001 Refresh Number 19 Contract Number: GS -07F -0031W 52.203-3 GRATUITIES (APR 1984) (a) The right of the Contractor to proceed may be terminated by written notice if, after notice and hearing, the agency head or a designee determines that the Contractor, its agent, or another representative— (1) Offered or gave a gratuity (e.g., an entertainment or gift) to an officer, official, or employee of the Government; and (2) Intended, by the gratuity, to obtain a contract or favorable treatment under a contract. (b) The facts supporting this determination may be reviewed by any court having lawful jurisdiction. (c) If this contract is terminated under paragraph (a) above, the Government is entitled— (1) To pursue the same remedies as in a breach of the contract; and (2) In addition to any other damages provided by law, to exemplary damages of not less than 3 nor more than 10 times the cost incurred by the Contractor in giving gratuities to the person concerned, as determined by the agency head or a designee. (This subparagraph (c)(2) is applicable only if this contract uses money appropriated to the Department of Defense.) (d) The rights and remedies of the Government provided in this clause shall not be exclusive and are in addition to any other rights and remedies provided by law or under this contract. 52.207-5 OPTION TO PURCHASE EQUIPMENT (FEB 1995) (a) The Government may purchase the equipment provided on a lease or rental basis under this contract The Contracting Officer may exercise this option only by providing a unilateral modification to the Contractor. The effective date of the purchase will be specified in the unilateral modification and may be any time during the period of the contract, including any extensions thereto. (b) Except for final payment and transfer of title to the Government, the lease or rental portion of the contract becomes complete and lease or rental charges shall be discontinued on the day immediately preceding the effective date of purchase specified in the unilateral modification required in paragraph (a) of this clause. (c) The purchase conversion cost of the equipment shall be computed as of the effective date specified in the unilateral modification required in paragraph (a) of this clause, on the basis of the purchase price set forth in the contract, minus the total purchase option credits accumulated during the period of lease or rental, calculated by the formula contained elsewhere in this contract. (d) The accumulated purchase option credits available to determine the purchase conversion cost will also include any credits accrued during a period of lease or rental of the equipment under any previous Government contract if the equipment has been on continuous lease or rental. The movement of equipment from one site to another site shall be "continuous rental." 52.222-1 NOTICE TO THE GOVERNMENT OF LABOR DISPUTES (FEB 1997) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately give notice, including all relevant information, to the Contracting Officer. Page: 1 of 216 88