Reso 2024-3718 - Laserfiche WebLink

Home Browse Search

EpdvTjho!Fowfmpqf!JE;!2193E418.88DB.5943.:22G.914D7G:28845EpdvTjho!Fowfmpqf!JE;!ED64EEGG.2G1:.5:C6.C4CB.73549671:658 12.15!Scrutinized Vendor List: By signing this Agreement and the attached certification marked as Exhibit E, CONTRACTOR certifies that it is not on the Scrutinized Companies that Boycott Israel List, created pursuant to §215.4725, Florida Statutes, or engaged in a boycott of Israel; and, for bids, proposals or contracts for goods or services of one million dollars or more, that it is not on the Scrutinized Companies with Activities in Sudan List or the Scrutinized Companies with Activities in the Iran Petroleum Energy Sector List, or engaged in business operations in Cuba or Syria, per §287.135, Florida Statutes. If SHERIFF determines, using credible information available to the public, that CONTRACTOR has submitted a false certification, SHERIFF shall provide CONTRACTOR with written notice of its determination. CONTRACTOR shall have 90 days following receipt of the notice to respond in writing and to demonstrate that the determination of false certification was made in error. If CONTRACTOR does not make such demonstration within 90 days after receipt of the notice, SHERIFF shall bring a civil action against the CONTRACTOR. If a civil action is brought and the court determines that the CONTRACTOR has submitted a false certification, CONTRACTOR shall pay a civil penalty equal to the greater of $2 million or twice the amount of the contract for which the false certification was submitted, and all reasonable attorney fees and costs, including any costs for investigations that led to the finding of false certification; and, CONTRACTOR will be ineligible to bid on any contract with an agency or local governmental entity for 3 years after the date BSO determined that CONTRACTOR submitted a false certification, pursuant §287.135(5)(a) Florida Statutes. 12.16!Third Party Beneficiaries. Other than Broward County and the Board of Commissioners of Broward County if the Project or real property is owned by Broward County, neither CONTRACTOR nor SHERIFF intends to directly or substantially benefit a third party by this Agreement. Therefore, the Parties agree that there are no third party beneficiaries to this Agreement (other than Broward County and the Board of Commissioners of Broward County if the Project or real property is owned by Broward County). 12.17!No claim for damages or any claim, other than for an extension of time, shall be made or asserted against SHERIFF by reason of any delays except as provided herein. CONTRACTOR shall not be entitled to an increase in the contract price or payment or compensation of any kind from SHERIFF for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference or hindrance from any cause whatsoever, whether such delay, disruption, interference or hindrance be reasonable or unreasonable, foreseeable or unforeseeable, or avoidable or unavoidable. 12.18!SHERIFF shall not be liable to pay any interest to CONTRACTOR for any reason, whether as prejudgment interest or for any other purpose, and in furtherance thereof CONTRACTOR waives, rejects, disclaims and surrenders any and all entitlement it has or may have to receive interest in connection with a dispute or claim arising from, related to, or in connection with this Agreement. This section shall not apply to any claim for interest, including for post-judgment interest, if such application would be contrary to applicable law. If this section is inapplicable or is determined to be invalid 26