Reso 2024-3718 - Laserfiche WebLink

Home Browse Search

EpdvTjho!Fowfmpqf!JE;!2193E418.88DB.5943.:22G.914D7G:28845EpdvTjho!Fowfmpqf!JE;!ED64EEGG.2G1:.5:C6.C4CB.73549671:658 or unenforceable by a court of competent jurisdiction, the annual rate of interest payable by SHERIFF under this Agreement, whether as prejudgment interest or for any other purpose, shall be, to the full extent permissible under applicable law, 0.25% (one quarter of one percent) simple interest (uncompounded). 12.19!Assignment Rights. This Agreement may not be assigned by CONTRACTOR without the prior express written consent form the SHERIFF. Such consent may be withheld for any reason and is discretionary on the part of the SHERIFF. SHERIFF may assign this Agreement to Broward County and/or the Board of Commissioners of Broward County at any time and provide CONTRACTOR with written notice of the same ARTICLE 13 - UNCONTROLLABLE FORCES Neither SHERIFF nor CONTRACTOR shall be considered to be in default of this Agreement if delays in or failure of performance shall be due to Uncontrollable Forces, the effect of which, by the exercise of reasonable diligence, the non-performing party could not avoid. The term "Uncontrollable Forces" shall mean any event which results in the prevention or delay of performance by a party of its obligations under this Agreement and which is beyond the reasonable control of the non-performing party. It includes, but is not limited to fire, earthquakes, storms, lightning, epidemic, war, riot, civil disturbance, sabotage, and governmental actions. Neither party shall, however, be excused from performance if nonperformance is due to forces which are preventable, removable, or remediable and which the non-performing party could have, with the exercise of reasonable diligence, prevented, removed, or remedied with reasonable dispatch. The non-performing party shall within a reasonable time of being prevented or delayed from performance by an uncontrollable force, give written notice to the other party describing the circumstances and uncontrollable forces preventing continued performance of the obligations of this Agreement. ARTICLE 14 PUBLIC RECORDS SHERIFF is a public agency subject to Chapter 119, Florida Statutes. To the extent CONTRACTOR is acting on behalf of BSO pursuant to Section 119.0701, Florida Statutes, CONTRACTOR shall: (a)!Keep and maintain public records required by SHERIFF to perform the services contracted for in this Agreement; (b)! public records, provide SHERIFF or designee with a copy of the requested records or allow the records to be inspected or option, within a reasonable time at no cost to SHERIFF; (c)!Ensure that public records that are exempt or confidential and exempt from public records disclosure requirements are not disclosed except as authorized by law for 27