Aetna - Brown & Brown #1 - Laserfiche WebLink

Home Browse Search

• n U • B. The sole respondent may be rejected. C. If the City Manager determines in writing that the need for the supply or service continues, but that the price of the one respondent is unreasonable and there is not time for re- solicitation or re- solicitation would likely be futile, the procurement may then be conducted under Section 6(D) or Section 6(F), of Ordinance 2001 -101, as appropriate. 10. Taxes. The Respondent is responsible for paying any and all taxes associated with the agreement. 11. Termination of A -greement. If the respondent fails to perform the conditions of the agreement as specified and as interpreted by the Manager, the Manager shall provide written notice of such violation. 11.1 The City reserves the right to terminate the agreement, without cause, with a 30- day calendar written notice unless otherwise provided in the contract. 11.2 Termination and cancellation of any agreement will not relieve the respondent for work rest that was to be completed prior to the termination or cancellation of the agreement. 11.3 If the agreement is terminated for cause, respondent will be removed from the City's vendor list. 11.4 The City Commission shall have the right to terminate the agreement in the event the respondent files any petition or proceeding for bankruptcy relief or is adjudicated to be bankrupt or insolvent or fails to pay just debts as they ordinarily become due. 11.5 This agreement may not be terminated by the respondent unless otherwise provided in the contract. 12. Insurance Requirements. 12.1 General. The respondent, including service - related respondents, shall purchase and maintain for the entire life of the Project, including any and all approved time extensions, until its final acceptance by the City, such insurance as will protect the respondent from claims under Workers' Compensation, disability benefit laws or other similar employee benefit laws; from claims for damages because of bodily injury, occupational sickness or disease, or death of respondent employees; from claims insured by usual or unusual injury liability coverage; from claims or injury to or destruction of tangible property and from claims insured by usual Commercial General Liability coverage. This includes loss of use resulting therefrom, any or all of which may arise out of the respondent's operations under the Contract Documents, whether such operations be by the respondent, or any sub contractor, or by anyone directly or indirectly employed by any of them or for Rip No. 01 -I1 -01 Grp Health Ins. Bid Package -7—