Reso 2021-3185 - Laserfiche WebLink

Home Browse Search

DocuSign Envelope ID: ClAD950E-9B4C-4DE5-98D5-725EBB24CD9D Section 6.5 Safety Standards Section 6.8 Waiver Section 7.1 Workers' Compensation Insurance Section 7.2 General Liability Section 7.3 Florida Authorized Insurers Section 7.4 Performance Bond Section 7.5 Indemnfifcation Section 7.6 Limitation of Liability Section 11.3 Performance Delay Section 11.4 Force Majeure , Notice of Delay, and No Damages for Delay. G. The following sections of Exhibit B, Special Contract Conditions are hereby replaced in their entirety: a. Section 2.3.1, Suspension of Work The Department may, at its sole discretion, suspend any or all activities under the Contract, at any time, when it is in the best interest of the State of Florida to do so. The Customer may suspend a resulting contract or purchase order, at any time, when in the best interest of the Customer to do so. The Department or Customer will provide advance written notice of no fewer than 30 days outlining the particulars of the suspension. After receiving a suspension notice, the Contractor must comply with the notice and will cease the performance of the Contract or purchase order. Suspension of work will not entitle the Contractor to any additional compensation. The Contractor will not resume performance of the Contract or purchase order until so authorized by the Department. b. Section 2.3.2, Termination of Convenience The Contract may be terminated by the Department in whole or in part at any time subject to advance written notice of no fewer than 30 days, in the best interest of the State of Florida. If the Contract is terminated before performance is completed, the Contractor will be paid only for that work satisfactorily performed for which costs can be substantiated. Such payment, however, may not exceed an amount which is the same percentage of the Contract price as the amount of work satisfactorily performed. All work in progress will become the property of the Customer and will be turned over promptly by the Contractor c. Section 3.5, Travel Travel expenses are not reimbursable. d. Section 5.2, Dispute Resolution, Governing Law, and Venue In the event there is a dispute concerning performance of the Contract, except for disputed transactions, the parties shall discuss and seek to arrive at a resolution in good faith. In the event the parties are unable to arrive at a resolution, then the Department's designated Contract Manager shall reduce State's decision as to such dispute to writing and serve a copy on the Contractor. Exhaustion of this administrative remedy is an absolute condition precedent to the Contractor's ability to pursue legal action related to the Contract or any other form of dispute resolution. The laws of the State of Florida govern the Contract. The Parties submit to the jurisdiction of the courts of the State of Florida exclusively for any legal action related to the Contract. Further, the Contractor hereby waives all privileges and rights relating to venue it may have under Chapter 47, F.S., and all